Traditional Culture Encyclopedia - Hotel accommodation - How to write renovation contract?

How to write renovation contract?

Employer (hereinafter referred to as Party A): _ _ _ _ _ Contractor (hereinafter referred to as Party B): _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _.

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, combined with the characteristics of family room decoration in this city, on the basis of equality, voluntariness and consensus, Party A and Party B reach the following agreement on matters related to Party B's contracting of Party A's family room decoration project (hereinafter referred to as the project):

Article 1: Project Overview

1. Project location: _ _ _ _ _ _ _ _ _ _ _ _

2. Decorative area of this project: _ _ _ _ _ _ _

3. Project apartment: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

4, project content and practice (see quotation and drawings)

5, project contracting, take the following first _ _ _ _ _ _ _.

(1) All materials contracted by Party B (see Annex 3)

(2) Part of the materials are contracted by Party B, and Party A provides the rest (see Attached Tables 2 and 3)?

6. The construction period is _ _ _ _ _ _ days (calculated according to actual working days);

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _。 ?

7. Project Payment and Quotation List

(1) project cost: the project cost of this contract is (RMB) _ _ _ _ _ _.

Amount in words: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(2) The quotation is based on the reference price of home decoration project in Beijing, and is determined by both parties through consultation according to the operation rules of market economy and the principle of high quality and good price, and is an annex to this contract.

(3) The quotation sheet shall be compiled together with material quality standards and safety manufacturing technology as the basis for determining the project price.

Article 2: Project Supervision Where Party A implements project supervision, it shall sign a project supervision contract with a project supervision company approved by the construction administrative department, and inform Party B of the name, unit, contact information and responsibilities of the supervision engineer.

Article 3: Pre-evaluation calculation of construction drawings and indoor environmental pollution control 1. The construction drawing shall be provided in the following form: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(1) If Party A designs by itself, it is required to provide the construction drawings and indoor environmental pollution control pre-evaluation calculation in triplicate, with Party A holding one copy and Party B holding two copies.

(2) Where Party A entrusts Party B with the design, Party B shall provide the construction drawings and indoor environmental pollution control pre-evaluation calculation in triplicate, one for Party A and two for Party B..

2. The construction drawings and pre-evaluation calculation of indoor environmental pollution control provided by both parties must meet the requirements of Code for Indoor Environmental Pollution Control of Civil Construction Projects.

3. Both parties shall sign and confirm the indoor environmental pollution control construction drawing and pre-evaluation calculation.

4. Both parties shall not copy or transfer the construction drawings, design schemes and other materials provided by the other party to a third party without authorization, nor shall they be used for projects other than this contract.

Article 4: Party A's Work

1. Three days before commencement, on the principle of not affecting the construction, create conditions for Party B to enter the site for construction.

2. Free water supply, power supply and winter heating during construction. ?

3. Be responsible for the commencement formalities of the property management department and the related expenses that should be paid by the owner.

4. Abide by the rules and regulations of the property management department.

5. Be responsible for coordinating the relationship between Party B's construction personnel and the neighborhood.

6. Don't do any of the following:

(1) Change the main body and load-bearing structure of the house at will.

(2) Open doors and windows on the external wall or expand the size of the original doors and windows, and dismantle the wall connecting the balcony doors and windows.

(3) Pave stones more than one centimeter indoors, build walls, and increase the floor load.

(4) Destroy the waterproof layer of the kitchen and bathroom floor, and tear down the heating, heating, gas and other pipeline facilities.

(5) Other behaviors that force Party B to operate illegally.

7. If the contents listed in Paragraph 6 must be involved, Party A shall apply to the housing management department, and the original design unit or design unit with corresponding qualification grade shall review the safety and availability of the change scheme and issue a written certificate, which shall be approved by the housing management department. ?

8. If Party A still needs to use part of the living room during the construction period, Party A has the responsibility to cooperate with Party B in safety and fire control. ?

9. Participate in the supervision of project quality and construction progress, and participate in project data, concealed works and completion acceptance.

Article 5: Party B's Work

1. In the construction process, the construction specifications, quality standards, safety operation procedures and fire prevention regulations shall be strictly implemented, and the project contents agreed in this contract shall be completed safely, with high quality and on schedule.

2. Strictly implement the regulations of the municipal administrative department of construction on construction site management: (1) Without the approval procedures and reinforcement drawings of the housing management department, the main building and load-bearing structure in the project shall not be demolished, the floor load shall not be increased, and the original indoor heating, heating, gas and other pipeline facilities shall not be changed.

(2) Do not disturb the people and pollute the environment. Do not engage in noisy decoration activities such as knocking, chiseling, planing and drilling from 12 to 14 and 18 to 8 o'clock the next day.

(3) Party B shall be responsible for the maintenance and compensation for the losses caused by pipeline blockage, water leakage, water cut-off and power failure of adjacent residents' houses due to decoration construction.

(4) Responsible for the protection of finished engineering products, equipment and living room furniture. ?

(5) Ensure that the plumbing in the room is unblocked and the bathroom is clean.

(6) Ensure the cleanliness of the construction site, and clean up the construction site after daily completion.

3. Provide Party A with the consultation conditions of various written materials such as standards, specifications, calculations and reference prices involved in the signing and performance of this contract through the notification website and unified publicity.

4. If Party A is a minority, Party B shall respect its national customs and habits during the construction.

Article 6 During the construction period, if it is necessary to change the contents of the project agreed in the contract, both parties shall reach an agreement through consultation.

Both parties to the contract * * * sign a written change agreement, and at the same time adjust the related project cost and time limit for a project.

Engineering change agreement, as the basis for completion settlement and extension of construction period.

Article 7: Supply of Materials

1. Party B shall provide materials according to the supply methods and contents specified in the list of materials and equipment for home improvement projects in this contract. ?

(1) For the materials and equipment to be provided by Party A, Party A shall notify Party B before the materials and equipment arrive at the construction site.

Both parties shall check and accept the quality of materials and equipment and environmental protection standards, and handle the handover procedures.

(2) Before the materials and equipment provided by Party B arrive at the construction site, Party B shall notify Party A..

Both parties shall accept the quality of materials and equipment and environmental protection standards, which shall be confirmed by Party A for the record.

(3) The building decoration materials provided by both parties must conform to the Limits of Harmful Substances in Interior Decoration issued by the General Administration of Quality Supervision, Inspection and Quarantine, and have qualified test reports issued by professional testing institutions recognized by relevant administrative departments.

(4) If one party disagrees with the materials provided by the other party and needs to re-inspect, the inspection fee shall be paid in advance; If the materials are really unqualified after testing, the testing expenses shall be borne by the other party.

(5) After the materials and equipment provided by Party A are accepted by Party B and the handover procedures are confirmed, Party B shall be responsible for the storage and quality control in the construction process.

Article 8: Delay in construction period

1. If the completion date is delayed due to the following reasons, the construction period will be postponed after being confirmed by Party A:

(1) engineering quantity change or design change;

(2) Force majeure;

(3) Other circumstances in which Party A agrees to postpone the construction period.

2. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly:

(1) Party A fails to complete its responsible work as agreed in the contract, which affects the construction period;

(2) Party A fails to pay the project payment as agreed in the contract, which affects the normal construction;

(3) Other circumstances that delay the construction period due to Party A's responsibility.

3. If the project cannot be completed on schedule due to Party B's responsibility, the construction period will not be postponed; The rework cost of the project quality problems caused by Party B shall be borne by Party B, and the construction period shall not be postponed.

4. Take the "written agreement recognized by both parties" as the basis for determining the responsibilities of both parties.

Article 9: Quality standard?

1, decoration indoor environmental pollution control, should be strictly in accordance with the "Code for Indoor Environmental Pollution Control of Civil Building Engineering" standards. ?

2, the project construction quality according to the following item _ _ _ _ _ _ _ standard:

(1) Beijing family room decoration engineering quality acceptance standard; ?

(2) Beijing advanced building decoration engineering quality acceptance standard.

3. If both parties dispute the project quality and indoor air quality at the time of completion and acceptance, they shall apply for certification to a professional testing institution recognized by the relevant administrative department; The expenses related to the certification process shall be paid by the applicant in advance and finally borne by the responsible party.

Article 10: Project acceptance?

1. During the construction process, the project quality will be jointly accepted in the following stages:

(1) Material acceptance;

(2) Acceptance of concealed works

(3) Completion acceptance. ?

2. After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within three days after receiving the completion acceptance notice.

After the acceptance, both parties shall go through the handover procedures, settle the final payment, sign the warranty, and Party B shall submit to Party A the hydropower transformation drawings of its construction part ...

3. Before the completion acceptance by both parties, Party B shall be responsible for protecting the safety of finished products and the project site.

4. If both parties fail to go through the acceptance formalities, Party A shall not move in. If Party A moves in without authorization, it will be deemed as qualified, and the losses caused thereby shall be borne by Party A. ..

5. Individual problems such as project quality, indoor air quality, economy, etc. not involved in the completion acceptance can also be settled by both parties through consultation (as an annex to the completion acceptance form). ?

6. The warranty period of this project is two years under normal use conditions, and the warranty period of the kitchen and bathroom anti-leakage project with waterproof requirements is five years from the date when both parties sign the project.

Article 1 1: payment method of project funds

1. After the contract comes into effect, Party A shall pay the project payment to Party B according to the agreement in the following table: three days before the commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

Pay half of the _ _ _ _ _ _ _ _ project progress.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ ?

2. More than half of the project progress means that all the water and electricity pipelines in the project have been laid, the wall and top foundation have been completed according to the technical requirements, and the basic installation of doors, windows and joinery products is completed as the standard definition project.

3. After the acceptance of the project, Party A shall review the project description submitted by Party B.

If there is no objection within two days from the date of submission, it shall be deemed that Party A agrees to pay the final payment of the project to Party B..

4. After all the project payment is settled, Party B shall issue a formal unified invoice to Party A as the project payment settlement certificate.

Article 12: Liability for breach of contract?

1. If one party fails to perform its contractual obligations as agreed, causing losses to the other party, it shall be liable for compensation; If you are punished for violating relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.

2. If one party cannot continue to perform the contract, it shall notify the other party in time, and the responsible party shall bear the losses caused by the termination of the contract. ?

3. If Party A fails to pay the second and third phases of the project payment within the time limit agreed in the contract without justifiable reasons, it shall pay Party B a penalty of 2‰ for each day overdue.

4. If the construction period is delayed due to Party B's responsibility, Party B shall pay Party A a penalty of 2‰ of the contract project cost for each day of delay. ?

5. If the project quality and indoor air quality are unqualified due to Party B's responsibility, Party B shall rework, repair, comprehensively treat and compensate according to the following agreement.

(1) Party B must completely rework and repair the unqualified parts of the project.

If the delivery of the project is delayed due to rework, it shall be regarded as the delay of the project, and the liquidated damages shall be paid according to the standard of 12.4. ?

(2) If the indoor air quality is unqualified, Party B must comprehensively treat it.

If the delivery of the project is delayed due to governance reasons, it shall be regarded as the project delay, and the liquidated damages shall be paid according to the standard of 12.4.

(3) If the indoor air quality is still not up to standard after treatment, it is really Party B's responsibility, and Party B shall return the full price of the contract project to Party A; If Party A is also responsible, Party B can reduce the return ratio accordingly.

Article 13: How to settle disputes?

In case of any dispute arising from this contract, both parties shall settle it through negotiation or apply to the market organizer and consumer association for mediation. If negotiation or mediation fails, the case shall be brought to the people's court of _ _ _ _ _ _ _, or applied for arbitration according to the arbitration clause or arbitration agreement reached separately.

Article 14: supplementary clause 1. This contract shall come into effect after being signed (sealed) by both parties. ?

2. After this contract is signed, the project shall not be subcontracted.

3. Both parties may modify or supplement this contract in written form, but if the modification or supplement reduces or exempts Party B from the responsibilities stipulated in this contract, this contract shall still prevail.

4. If the performance of the contract is affected or losses are caused due to reasons not attributable to both parties, both parties shall settle the matter through consultation based on the principle of fairness. ?

5. If Party B withdraws from the market, the market organizer shall be liable for compensation first; After assuming the responsibility, the organizer has the right to claim compensation from Party B. 6. This contract will be automatically terminated after the performance is completed. ?

Party A (signature) _ _ _ _ _ _ _ _ _? _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature) _ _ _ _ _ _ _ _ _? _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

A contract is an agreement between the parties or both parties to establish, change or terminate a civil relationship.

Contracts established according to law are protected by law. A contract in a broad sense refers to an agreement in all legal departments to determine the relationship between rights and obligations. Narrow contract refers to all civil contracts.

The narrowest contract only refers to the creditor's rights contract in civil contract.

Article 85 of General Principles of Civil Law of People's Republic of China (PRC): A contract is an agreement between the parties to establish, change and terminate a civil relationship.

Contracts established according to law are protected by law.

Article 2 of People's Republic of China (PRC) Contract Law: A contract is an agreement between natural persons, legal persons and other organizations with equal subjects to establish, change and terminate civil rights and obligations.

Other laws shall apply to the agreements on identity relations such as marriage, adoption and guardianship.

A contract, also known as a contract or agreement, is an agreement between equal parties to establish, change and terminate the relationship of civil rights and obligations. As a civil legal act, a contract is the product of the parties' agreement, and it is an agreement expressed by more than two parties.

A contract is legally binding only when the meaning expressed by the parties is legal. A legally established contract shall take effect from the date of its establishment and be legally binding.

References:

Renovation contract housing web page link.