Who has a hotel renovation contract model?

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Measures for the Administration of Interior Decoration and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and combining with the specific construction conditions of this decoration project, the two parties reached the following agreement through consultation.

Article 1; Project overview

1 project location: XX.

Project content: The total construction area is 2000 square meters.

3. Scope of contract; Labor cost of decoration;

4 Commencement date: 2065438+03; Completion date: 2065438+03; Total construction period (including legal holidays): 29 working days.

Article 2; Contract price

1 Total amount of decoration labor (RMB in words): one hundred and thirty-two thousand yuan; ￥:。

2. On the day of signing the contract, Party A shall pay 30% of the total labor cost of the decoration project; ￥:。

3. When the renovation project is 80% completed, Party A will pay 40% of the second cost, RMB:.

4. After the project is completed and accepted, Party A will pay 25% of the decoration fee, RMB:.

5. Take 5% times as the project quality deposit, and pay it within one year after the project is completed and accepted, ￥:.

Article 3; Party A's responsibilities

1 Appoint _ _ _ _ _ _ _ _ as the representative of the Employer at the construction site, responsible for contract performance, supervision and inspection of project quality, progress, material mobilization and other matters.

2 before the decoration project starts, be responsible for the examination and approval procedures with relevant departments.

3. Provide the contractor with water and electricity needed for the construction, and explain the matters needing attention. Responsible for coordinating the relationship with the surrounding neighbors.

4 Before starting work, the construction drawings or work instructions shall be confirmed, and on-site disclosure shall be made to the contractor.

Responsible for handling the garbage generated by decoration,

Article 4; Party B's responsibilities

1 Appoint _ _ _ _ _ _ _ as the contractor's on-site representative to be responsible for the performance of the contract. Organize the construction as required, and complete the construction task on time with good quality and quantity.

2. Carry out the construction in strict accordance with the drawings, make records of various quality inspections, and strictly implement the construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations.

Strictly abide by the stipulated decoration construction time, reduce construction noise and reduce environmental pollution. Dealing with the nuisance caused by construction and its relationship with surrounding units and residents.

Be responsible for protecting all facilities and finished products on site before the project is completed and handed over to the owner.

5. Ensure the cleanliness of the decoration site, and do a good job of cleaning and handling before completion.

Article 5; Material supply

1 Materials and equipment used in decoration engineering must meet national standards, and have quality inspection certificates and product names, specifications, models, manufacturer names and addresses indicated in Chinese. It is forbidden to use building decoration materials and equipment that have been explicitly eliminated by the state.

2. If the materials and equipment supplied by the Employer have quality problems or differences in specifications, thus causing losses to the project, the responsibility shall be borne by the Employer.

All materials and equipment purchased by the contractor shall be purchased according to the requirements of design, specifications and samples. Do not meet the quality requirements or different specifications, it is forbidden to use. If it has been used, the contractor shall be responsible for the losses caused to the project.

Article 6; Safety responsibility

1 If safety or fire accidents are caused due to violation of relevant safety operation regulations, fire prevention regulations and fire prevention design specifications, the Employer shall bear all economic losses.

2 The contractor shall strictly abide by the construction safety operation rules when carrying out decoration activities, take necessary safety protection and fire control measures in accordance with the regulations, and shall not use naked flame and carry out welding operations without authorization to ensure the safety of workers and surrounding houses and property.

3. The contractor shall bear all responsibilities for safety accidents (including personal accidents) caused by his violation of relevant safety operation procedures during construction.

Article 7; Quality acceptance

1 The construction drawing, effect drawing and practice description are the acceptance criteria for quality evaluation of this project.

Both parties shall handle concealed works and intermediate acceptance formalities in time. If the Employer fails to take part in the concealed works and intermediate acceptance on time, the Contractor may accept it by himself, and the Employer will recognize it.

3 After the completion of the project, the Contractor shall notify the Employer for acceptance, and the Employer shall organize acceptance within two days after receiving the acceptance notice, and go through the acceptance handover procedures.

Article 8; Changes in work

1 If the Employer needs to change the project and construction method, both parties should communicate in time before construction, and the price and construction period can be changed accordingly.

2 The contractor puts forward reasonable suggestions for changing the design scheme and replacing materials, and the scheme can only be changed with the consent of the designer and the employer.

Article 9; Engineering warranty

1 After the acceptance, the contractor shall issue a guarantee for the quality of residential interior decoration. Engineering (one-year warranty).

Article 10; responsibility for breach of contract

1 If the construction period is delayed or stopped halfway due to the reasons of the Employer, it shall be liable for breach of contract. The Owner shall pay the Contractor RMB 65,438+0,000 for each day of shutdown or shutdown. If the Employer fails to allocate the project funds as agreed in the contract, it shall pay a late fee of 5% of the project funds for each day overdue.

2 If the construction period is delayed due to the contractor, the contractor shall pay the liquidated damages of 65,438 yuan+0,000 yuan to the employer for each day of delay. If the project quality fails to meet the quality standards agreed by both parties, _ _ _ _% of the total project price will be deducted.

3 The Contractor shall properly protect the equipment provided by the Employer and the furniture, furnishings and finished products stacked on the site. If losses are caused, compensation shall be made according to the price.

4. Without the consent of the employer, the contractor changes the original building structure or equipment pipeline without authorization, and the resulting losses or accidents (including fines) shall be borne by the contractor.

5 If the contractor recommends the use of decoration materials that do not meet the national standards to the employer, causing excessive air pollution, it shall be liable for compensation according to law.

6. The employer shall be responsible for the losses caused by the use in advance or the unauthorized use without going through the acceptance formalities.

If one party cannot continue to perform the contract due to reasons, it shall notify the other party to handle the contract termination agreement, and the responsible party shall compensate the other party for the economic losses caused thereby.

Article 11; settlement of dispute

1 The original of this contract is in duplicate, with the same effect, and the employer and the contractor hold one copy respectively.

2. Disputes arising during the performance shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it may be submitted to Dalian Arbitration Commission for arbitration; Or bring a lawsuit to the people's court where the project is located according to law.

Employer (seal): _ _ _ _ _ Contractor (seal): _ _ _ _ _ _

Telephone number of owner and contractor

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _