Traditional Culture Encyclopedia - Hotel accommodation - 3 pieces of marble project contract model

3 pieces of marble project contract model

Marble originally refers to white limestone with black patterns produced in Dali, Yunnan, so how much do you know about the marble project contract? What do you usually need to pay attention to? If you don't know, here is the marble project contract I compiled for you. Please refer to.

Marble engineering contract model 1

Party A:

Party B:

Party A and Party B shall, in accordance with the principles stipulated in the Economic Contract Law of the People's Republic of China and the Regulations on Construction Project Contracts, combine the actual situation of this project. Have reached the following agreement.

Article 1 General situation of the project

1. Project name: Wannan International Hotel

2. Project address: beside the viaduct in Jingxian Development Zone.

3. Contract scope: dry hanging on the wall of elevator room on floor 9- 17, elevator door cover, marble pavement on the ground, marble pavement on stairs, washboard in bathroom, floor of shower room, sill stone and window sill.

Article 2 Contract method: package materials, package materials, package installation, package quality, package safety and package progress.

Article 3 Quality grade: the excellent samples approved by Party A and the owner shall prevail; If the bulk materials are not in conformity with the samples, all losses arising therefrom will be borne by Party B. ..

Article 4 Construction drawing: The drawings provided by the owner shall prevail. If there is any change, Party A shall notify Party B in time. Party A shall provide a technical disclosure and construction drawings.

Article 5 The Permanent Representative of Party A:

Permanent Representative of Party B:

Article 6 Basic work:

Party A shall provide a safe site and provide temporary water and electricity (at its own expense). Party B shall provide marble samples for Party A to choose from. Provide a list of samples and a list of marble processing costs and installation labor costs.

Article 7 the project schedule

According to the general schedule requirements of the Owner and Party A, Party B shall provide the construction schedule.

Article 8 Project supervision

The employer, the employer and the contractor jointly supervise. The last procedure passed the acceptance;

And then proceed to the next process.

Article 9 Project Payment and Payment Methods

Basis of project payment settlement:

1, and the calculation of quantities shall be subject to the actual completion surface.

2. The marble price list submitted by Party B shall be subject to the price approved by Party A. ..

3. The temporary appraisal of this project is expressed in words;

4. Pay synchronously according to the contract payment method signed by Party A and the owner, and reserve 5% as the quality deposit.

Article 10 Project acceptance

Acceptance in accordance with the national building decoration industry standards; All losses caused by rework due to failure to meet the acceptance criteria shall be borne by Party B; If the delay in the construction period causes losses to Party A, it shall pay compensation of 1000 yuan per day.

Article 11 Final accounts

This contract and the increase outside the contract are also included in the final accounts.

The first guarantee

Party B shall undertake the maintenance obligation of the project within the construction scope within two years from the date of completion acceptance, and the expenses shall be borne by itself.

Article 11 Disputes

Both parties to the dispute shall settle it through consultation. If both parties fail to reach an agreement, they can submit it to the labor department for arbitration. If no agreement can be reached, you can appeal to the court.

Article 12 Liability for breach of contract

If Party A fails to perform the contract on time, it shall compensate Party B for a penalty of 5% of the total contract price. If Party B fails to perform the contract on time, it shall compensate Party A for a penalty of 5% of the total contract price. Article 13 This contract is made in the form of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

For matters not covered in this contract, both parties may sign a supplementary agreement through consultation. The supplementary agreement has the same effect as this contract.

Contract awarding party

Name of unit (seal)

Unit name:

Legal Representative: Name (seal) of the contractor Address: Legal Representative:

Tel: Tel:

Date:

Date:

Model contract for marble project II

Customer (Party A): ID card:

Contractor (Party B): ID card:

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to provide and install the contract contents. In order to ensure the smooth progress of the project, this contract (including its annexes and all supplementary contracts in the Ministry) is hereby signed for * * *.

Article 1: Project Overview

1. Project name:

2. Project address:

Article 2: Project Price

The material price negotiated by both parties is 1 10 yuan /m2, and the artificial paving fee is 45 yuan /m2. Payment for materials shall follow the following Article 6: Payment Method.

Article 3: Product Specification and Unit Price

Article 4: Project Construction

1. Provide Party A with the building materials and auxiliary materials needed by Party A as far as possible. If the construction period is deliberately delayed, Party B shall be responsible.

2. One party shall do its best to carry out the construction according to Party A's acceptance criteria and construction period.

3. In the process of Party A's construction, Party B shall be responsible for the lost time and material costs caused by Party B's material quality problems.

Article 5: Quality Requirements

1. The varieties and specifications of the main materials used in the project shall be approved by both parties.

2. The quality of materials shall be subject to the raw materials.

Article 6: Method of Payment

The contract comes into effect, and after the mall 10 opens, Party A and Party B shall pay off all the project funds on 1 1 month.

Article 7: Construction Period

Both parties shall negotiate according to the specific situation and complete it within 20 working days after entering the site.

Article 8: Other matters

Article 9: Settlement of disputes

In case of any dispute during the performance of this contract, both parties can settle it through negotiation; If negotiation fails, they can bring a lawsuit to the local people's court.

Article 10: Modification and Termination of the Contract

The modification and termination of the contract shall be negotiated by both parties; Any party who changes or terminates this contract without authorization shall bear the losses caused to the other party.

Article 11: Entry into force of the contract

1. This contract and its annexes shall come into force after being sealed or signed by both parties.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.

Party A: (signature and seal)

Party B: (signature and seal)

Date of signature: year month day.

Model contract for marble project 3

Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, through equal consultation between Party A and Party B, Party A agrees to reach an agreement on matters related to this project and conclude this contract for compliance.

I. Project Name: Marble Installation Project

Second, the project site selection:

Three. Project content: marble installation

4. Contracting method: single contractor. Party A is responsible for marble, cement, sand, installation, water and electricity supply and tower materials on the construction site.

6. Unit price of the project (excluding tax): dry-hanging labor for wall surface, square column and angle steel.

Seven. Payment method: Party A shall first pay Party B an entrance fee of RMB. The installation fee will be paid 80% according to the construction progress, and the rest will be paid in one lump sum after the completion and acceptance of the reception project.

VIII. The construction period shall be the date of signing the contract, and Party B shall complete the project with good quality and quantity within days.

Nine, this project is built according to national standards.

X. Party A's responsibilities

1, organize water and electricity supply and materials needed for construction in time, and shall not affect the normal construction.

2. Provide production water and electric field, and provide living quarters for Party B's employees.

3. Be responsible for providing Party B with construction design drawings, and assign special personnel to supervise Party B's construction according to technical specifications. Put forward adjustment opinions on the problems existing in Party B's construction to ensure that the project quality meets the specified requirements.

4. Responsible for raising project funds, timely paying the project funds according to the contract requirements, and ensuring the normal construction of the project. If Party A fails to cash the progress payment or provide the construction materials in time, Party B has the right to suspend the construction or wait for the payment to be cashed.

(II) Party B's responsibilities

1, responsible for organizing the construction in a planned way according to the technical specifications, and ensuring that the project is completed on time with good quality and quantity.

2, according to the relevant provisions of the state, standardize the construction site management, civilized construction, safe construction.

XI。 Precautions:

This contract is made in duplicate, one for each party. Matters not covered in this contract shall be settled by both parties through consultation.

Party A (seal): _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative (signature): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Three related articles on marble engineering contract model;

★ 3 Model stone processing contract

★ 3 Stone supply and construction contract

★ Marble engineering contract

★ Three model articles of marble supply contract are the latest.

Taken the project general contracting 3 templates.

★ 3 pieces of stone transaction contract model

★ Three sample project contracts are the latest.

★ Model stone construction contract

★ 3 samples of simple project contract

★ 3 Model construction contract