General version of project cooperation contract mode 3.

Project contracting is a process in which the contractor is responsible for the construction of the project by signing a contract with the project legal person. So what should we pay attention to when signing the project contracting partnership agreement? The following is the project contracting partnership agreement I compiled. Please refer to.

General version of project cooperation contract agreement model 1

Partner:

Partner:

Based on the principle of fair and reasonable cooperation, Party A and Party B reached the following agreement through friendly negotiation:

I. Working rules of Party A:

1. Party A must carry out the construction in strict accordance with the drawings provided by Shenshuo Railway Company, and Party A shall be responsible for any quality problems (except drawing design problems and normal errors).

2. If there is any change in the construction process, Shenshuo Railway Company will issue a certificate to change the construction according to the certificate.

3. Party A must guarantee the quality of the project within the warranty period, and Party A shall be responsible for any quality problems.

4. Party A must complete the project according to the time limit for a project of Shenshuo Railway Company (in case of special circumstances, Party B shall negotiate and sign a supplementary agreement with Shenshuo Railway Company, except for safety issues):

1. In case of safety accidents (except for human reasons) during construction, Party A and Party B shall compensate according to their respective shareholding ratios.

2. Casualty accidents (except overtime) caused by the workers of Party A and Party B shall be settled by both parties through consultation, and both parties shall be responsible for each other.

Second, the workers' responsibilities:

1. When the project reaches the relative payment ratio, Shenshuo Railway Company shall pay the corresponding payment ratio.

2. After the project is completed and accepted, Party B must guarantee to pay all the project funds (except the quality deposit) within 12 working days. If Shenshuo Railway Company fails to pay the remaining project funds within 15 working days, Party B shall pay in advance.

3. Party B promises to negotiate with Shenshuo Railway Company to return the bid bond within 15 working days after the official start of construction.

4. In case of any dispute with Shenshuo Railway Company during the construction, Party B shall come forward to mediate.

Third, cooperative investment and proportion

1. Party A is responsible for the bid bond of this project.

2. Party B is responsible for the first fund (the amount is the same as the deposit) to start this project.

3. If Party A wins the bid, Party B will invest 65,438+06%-20% of the total project budget, and the profit dividend obtained by Party B will not be greater than 20% or less than 65,438+05%, and Party A will be responsible for the remaining funds of the project.

4. If Party B wins the bid, Party B will invest 65,438+05%-65,438+07% of the total project budget, and the profit dividend obtained by Party B shall not be more than 20% and not less than 65,438+07%, and Party A shall be responsible for the remaining funds of the project.

5. If Party B's qualification is used, no additional fees shall be charged. (Party A has equipment) The payment for transportation equipment shall be equally distributed by Party A and Party B. ..

6. In case of special circumstances (such as budget, bid renewal and bid increase, etc.). ), Party A and Party B shall negotiate separately.

7. If either party is short of funds due to special reasons, if conditions permit, either party may increase investment and change the investment ratio and dividend ratio accordingly.

8. Employee insurance is distributed according to the shareholding ratio.

9. Average distribution of contract notarization fees.

10. During the construction period, Party B shall not interfere with the normal construction of Party A (except for quality and safety accidents).

Fourth, financial management.

1. The cooperative project shall establish an independent account and conduct financial accounting, and all expenses and income of the cooperative project shall be operated from this account.

2. Finance is managed by Party A. ..

3. In case of financial and accounting disputes, either party has the right to hire a third-party accountant for accounting.

4. Party A and Party B shall not misappropriate the account of this project.

Verb (abbreviation of verb) breach of contract and dispute

1. During the partnership period, if one party withdraws from the partnership, it will seriously affect the construction of the partnership project.

2. If a partner withdraws from the partnership without the consent of the partner, which causes losses to the partnership, it shall make timely compensation (unless Party A withdraws without reason, it will not make compensation).

3. In the course of cooperation, if either party violates this agreement and causes losses to the other party, the breaching party shall compensate the other party in full.

4. In case of disputes between partners, they should be settled through consultation in a timely manner on the principle of being conducive to cooperation and development.

This agreement is made in duplicate, one for each party.

Seven. Matters not covered in this agreement shall be negotiated separately.

Party A:

ID number:

Party B:

ID number:

Project Partnership Contract Agreement Model II General Edition

Party A:

Party B:

According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Construction Law and other relevant laws, regulations and rules. Based on the principles of equality, voluntariness, fairness, honesty and credit, both parties have reached an agreement on this project and will abide by it together.

I. Overview of the Project

1, Project Name: Safety Maintenance Project of Flood Control Material Warehouse of Jiangsu Flood Control and Drought Relief Center.

2. Project location: Flood Control and Drought Relief Emergency Center.

Second, the time limit for a project:

1. Commencement and completion date: August 29 -20, 20001October 27 (subject to the commencement report).

2. The total duration of the contract is 60 working days. In case of irresistible special weather such as continuous rainstorm, the construction period can be postponed accordingly after being signed by Party A and the supervisor.

Four, the quality standard adopts the following contents:

Meet the national quality acceptance standards;

Verb (abbreviation of verb) contract price

The settlement of the project price in this contract adopts the following methods:

1. The fixed unit price is RMB/m2 (the workload is settled in real terms).

Terms of payment for intransitive verbs

1, the project payment will be paid to 90% of the approved price after review, and the retention money of the quality guarantee fund 10% will be paid one year later.

Seven, materials and equipment supply:

Eight, quality and acceptance

1. The quality of the project must meet the standards specified in Article 4 of this Agreement and be implemented according to the current national acceptance specifications. The quality guarantee period is years. If the project involves the main structure, it will be guaranteed for life.

2. Without the consent of Party A, all Party B's personnel entering the site shall not be replaced at will. If it is really necessary to change, an application shall be made to Party A in writing three days in advance, otherwise, if Party B arbitrarily changes 30% of the staff, Party A has the right to terminate the contract and Party B will leave unconditionally.

3, project quality acceptance must be carried out according to the specification, all engineering data must be synchronized with the engineering construction, for the relevant departments and personnel to consult, unqualified data timely correction.

5, subdivisional work acceptance, and concealed engineering acceptance, must be signed by Party A and supervision before the construction of next working procedure.

6. Party A shall complete the acceptance within hours after receiving Party B's inspection report and issue a written acceptance opinion. Usually, Party A conducts spot checks regularly or irregularly, and when quality problems are found, it issues written rectification opinions within a time limit, and Party B must rectify within a time limit according to Party A's requirements. If quality problems are found many times, or still fail to meet the requirements after two rectifications, Party A has the right to pay liquidated damages as appropriate, and if the circumstances are serious, Party A shall be ordered to withdraw from the market, and all losses shall be borne by Party B. ..

7. After completion, Party B shall notify Party A in writing for acceptance, and Party B shall provide the as-built drawings and all as-built materials that meet the requirements of the specification in duplicate within the day after completion.

8. Other agreements: The construction shall be carried out according to the drawings to meet the requirements of Party A, and it is forbidden to spill or dump it anywhere.

Nine, construction organization and time limit for a project

1. Party B shall submit a written construction organization plan to Party A within three days after receiving Party A's formal construction drawings, and Party B shall go through relevant formalities such as the commencement report, and Party A shall examine and approve Party B's construction organization plan and arrange technical disclosure of the drawings.

2. Party B must organize the construction according to the contract period and the approved schedule, and accept the supervision and inspection of the project progress by Party A and the supervisor. When the actual progress of the project is not in conformity with the plan, Party A and the supervisor have the right to order improvement within a time limit, and Party B shall put forward rectification measures according to the requirements of Party A and the supervisor, and report them to Party A and the supervisor for approval before implementation. During this period, Party B shall pay overtime. When the monthly progress is obviously behind schedule, Party A has the right to suspend the payment of project funds. If Party B obviously can't complete the project according to the agreed time limit, Party A has the right to change the construction team, and Party B shall unconditionally evacuate the site within 10 days after receiving the evacuation notice from Party A, and all personnel and equipment shall be evacuated, and the project payment shall be paid according to% of the actually completed project amount, otherwise, Party A will not pay any money, and shall bear a penalty of 2 ‰ of the total project amount for each day of delay, and compensate other losses in full.

4. Agreement on water, electricity, accommodation, tools and other facilities during the construction period: Party B shall solve it by itself.

Ten, safety and civilized construction and management

1. Party B shall strictly implement relevant safety operation management regulations.

2. Persons without ID cards, bad records, physical disabilities and child labor shall not be employed. Otherwise, the consequences are at your own risk.

3, special projects need to hold a license issued by the labor department, show certificates.

4. Party B shall handle industrial accidents or other internal disputes during the construction period and bear all economic responsibilities.

5. All mechanical equipment should meet the needs of engineering construction, and special equipment should have safety inspection certificate.

6. Party B shall conduct standardized management on the construction site according to the regulations of the relevant departments of the local government, and all penalties and losses caused by inadequate standardized management shall be borne by Party B. ..

7. Party B shall give priority to the payment of wages to the construction personnel, and shall not default, and properly handle labor disputes and related issues, so as not to affect the construction and cause any adverse impact to Party A, otherwise Party A shall.

Have the right to take measures such as canceling the contract, ordering to leave, demanding compensation for losses, and demanding payment of liquidated damages.

XI。 Party A's responsibilities

1. Provide drawings and information as agreed, and make technical disclosure of drawings.

2. Pay the project payment to Party B as agreed. If Party A fails to cash in time due to financial difficulties, it shall negotiate with Party B and bear part of the bank loan interest payable to Party B according to different situations.

4. Perform other obligations agreed in this agreement and be responsible for

Twelve. Party B's responsibilities

1. Complete the construction task with good quality and quantity as agreed, and meet the construction period and quality requirements.

2. Party B must obey Party A's on-site management, abide by laws and administrative regulations, abide by various rules and regulations, and safeguard Party A's reputation. If Party A is found to intentionally damage its reputation, seriously violate discipline or violate the contents of the agreement, Party A has the right to impose economic penalties until the contract is terminated.

3, should pay attention to protect the ecological environment, pay attention to the construction safety, do not cut down trees and damage other facilities, pay attention to forest fire prevention.

4. Party B shall not stop working or work passively for any reason, or take improper measures such as noise and threats, otherwise, Party A has the right to order him to leave, and all consequences shall be borne by Party B. ..

5. In case of quality problems during the warranty period, Party B shall enter the site for maintenance within days after receiving Party A's phone call or written notice, and complete the maintenance within days, otherwise the maintenance cost will be deducted from the warranty fund.

6. Party B shall, in accordance with relevant regulations, take the initiative to make a quality follow-up visit to the project. Thirteen. responsibility for breach of contract

1. Both parties shall strictly abide by the agreement. If there is any violation, it shall be liable for breach of contract according to the relevant provisions of this agreement.

2. If the construction period is delayed, Party B shall bear the liquidated damages according to the total contract price or pay the liquidated damages to Party A at a daily rate of 1 0,000 yuan.

3. In case of quality problems and violation of other agreements in this Agreement, Party B shall compensate all economic losses caused to Party A, and Party A may require Party B to bear the liquidated damages of 1%- 10% of the total contract price according to specific conditions.

Fourteen supplementary terms

1. This agreement shall come into effect after being signed and sealed by both parties.

2. Once this agreement is signed, both parties shall strictly abide by it. Any dispute arising from the execution of this agreement shall be settled by both parties through consultation. If negotiation fails, the people's court of the place where the agreement is signed shall make a ruling.

3. This agreement is made in quadruplicate, two for each party, with the same legal effect.

4. Matters not covered in this contract or disputes arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled by the people's court where the maintenance project is located.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

General version of project partner contract agreement mode 3

Partner: CertificateNo.: Tel: Partner: CertificateNo.: Tel: In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and on the principle of long-term cooperation, common development and mutual benefit, all partners have entered into a partnership contract through equal consultation.

I. The purpose of the partnership:

On the premise of legality and rationality, do a good job in engineering construction, maximize the profits of all parties, * * * enjoy the benefits and * * * bear the risks.

Second, the partnership project and scope

The partnership project is subject to the content and scope of the construction project confirmed by the company's bid-winning contract.

Three. Term of cooperation:

The duration of the partnership is from the completion of the partnership construction project, and all parties have settled accounts.

Four. Mode and proportion of investment:

The construction expenses and other expenses related to the project recognized by the partners shall be equally funded by the partners (that is, each partner shall bear 20% of the expenses). The capital contribution is RMB, and the capital contribution is RMB in words. V. Income distribution and debt commitment:

1. Income distribution: 20% of the income will be distributed equally by all parties (in case of default investment, the income will be distributed in proportion to the actual investment).

2. If the partnership enterprise generates debts, the partnership enterprise property shall pay them off first. If the partnership property is insufficient to pay off, it shall be borne in accordance with the proportion of capital contribution agreed by each partner.

Six, exit:

In principle, you may not quit the partnership during the partnership period; If it is really necessary to quit the partnership for special reasons, it shall be agreed by all parties through consultation;

Seven. Daily management of the project

1, XXX hires the chief engineer to be responsible for the technical work of the project;

2. The 30th day of each month is the settlement date agreed by both parties, and both parties will settle accounts with the accountant * * *, and all expenses can be settled only after being signed by both parties.

3. Major expenditures and major partnership matters shall be decided by both parties in advance. If they are decided by telephone, a written agreement shall be signed at the latest accounting date.

Eight, the scope of cost accounting.

The scope of construction cost accounting includes: project introduction fee, construction qualification subsidiary fee, tax, construction labor fee, construction machinery fee, salary of project department management personnel, construction electricity fee, temporary office equipment and house rental fee, and safety maintenance facility fee. Pre-settlement fee, execution fee, material fee and other expenses related to the project recognized by the partner.

Nine, the expiration of the partnership period:

Upon the expiration of the partnership, all parties shall carry out liquidation according to the partnership agreement, distribute and bear the profits and losses in proportion; The other party has the obligation to help recover the receivables distributed by one party.

X. Prohibition clauses on partner's behavior:

1. Partners are prohibited from cooperating with others in the same development zone.

2. It is forbidden for partners to quit when the partnership is unfavorable.

3. It is forbidden for partners to carry out acts that harm the interests of partners during the partnership.

XI。 Liability for breach of contract:

1. If a partner quits the partnership without the consent of the partner, it shall calculate the losses caused by compensation, and the losses shall be calculated as 15% of the total project price.

2. If one partner violates other agreements in this agreement and causes losses to the other party, it shall be liable for compensation.

Twelve. Others:

1. In case of disputes between partners, they shall be settled through consultation on the principle of benefiting the development of the partnership. If negotiation fails, it shall be handled by the people's court at the place where the contract is performed.

2. If it is necessary to change or modify the contract during the performance of the contract, it must be agreed by all partners and modified in writing. Other modifications are invalid.

3. For matters not covered in this contract, all parties can sign a supplementary contract through negotiation, which has the same legal effect as this contract.

Thirteen. This contract shall come into effect as of the date of signature by both parties. This contract is made in duplicate, one for each party.

Partner: Year Month Day

Partner: Year Month Day

Three articles on the general version of the project partnership model contract;

★ 3 copies of the latest version of the partnership contract model clauses in 2020.

★ 4 templates for general version of engineering contract.

★ The latest three project contracting model essays.

★ Three classic models of cooperative operation contract are the latest.

★ Concise version of three model clauses of the contract management cooperation agreement.

★ General Edition Project Construction Entrustment Contract 3.

★ General Edition of Engineering Contract

★ General Edition of Construction Project Contract

★ The latest version of 3 construction project contract templates.

★ Professional Engineering Contract General Edition 2020