How to write a hotel decoration construction contract?

The entrusting party (Party A):

The undertaking party (Party B):

Project:

Party A and B After negotiation and negotiation, Party A decided to entrust Party B with the bedroom decoration. In order to ensure the smooth progress of the project, this contract is signed in accordance with the relevant national laws and regulations for mutual compliance.

Article 1: Project Overview

1. Project address: _______________________________

2. Bedroom specifications: Room type ______ floor (style) ______room_ _____hall______kitchen______bathroom, with a total construction area of ??____________ square meters.

3. Construction content: For details, please see attachment (1) of this contract, "Home Decoration Construction Content List" and construction drawings.

4. Entrustment method: ________________________________________

5. Project start date: ______year______month______day

6. Project completion date: ______year______month______day

Total number of project days: ________ days

Article 2: Project price

Project price (amount in capital letters )_______________ yuan, for details, please see Appendix (2) "Home Decoration Project Material Budget Sheet" to this contract.

1. Material cost __________ yuan; 2. Labor cost __________ yuan;

3. Design fee __________ yuan; 4. Construction clearance fee __________ yuan ;

5. Moving fee __________ yuan; 6. Management fee __________ yuan;

7. Other expenses (specify content) __________ yuan.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The project acceptance standards shall be implemented with reference to relevant national regulations.

3. During construction, if Party A has special construction projects or special quality requirements, both parties should confirm and sign a supplementary contract for the increased costs.

4. For all materials and equipment purchased by Party A, Party A is responsible for product quality; Party B is responsible for construction quality.

5. If Party A hires its own project supervisor, it must notify Party B before the project starts to facilitate work connection.

Article 4: Supply of Materials

1. Party B must strictly follow the relevant national price regulations and clearly price all materials used in this contract. The materials provided by Party A shall be used in the decoration projects stipulated in this contract and shall not be used for other purposes without the consent of Party A. If Party B misappropriates the materials for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from use. If it has been used, Party B will be responsible for any losses caused to the project.

3. Party A is responsible for purchasing and supplying materials and equipment, which should be qualified products that meet the design requirements and should be supplied to the site on time. If the arrival time is delayed, the construction period will be postponed and penalties will be imposed according to the delayed construction period. 10% of the total amount of materials provided by Party A will be paid to Party B as management fee. After the materials are accepted by Party B, Party B will be responsible for keeping them. Party B will be responsible for compensation for any losses caused by improper storage.

Article 5: Payment method

1. Once the contract is signed, Party A shall pay 100% of the project material payment and 50% of the construction cost; when the construction period is more than half (year and month) day), Party A will pay 40% of the construction cost for the second time. The remaining 10% of the balance will be settled after Party A accepts the completion of the project. (Note: Construction costs include labor costs).

Party A’s failure to pay on the due date is a breach of contract, and Party B has the right to stop construction. The project shall not be delivered for use if it has passed the acceptance inspection and the payment for the project has not been settled.

2. If there are additions, deletions, or changes to items during the construction of the project, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing a construction change order and notifying the person in charge of the construction site. The price of increased or decreased items will be settled on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, 1% of the unpaid project price will be paid to Party B for each day overdue.

4. If Party A obtains a mortgage from a bank during home decoration, the mortgage certificate and relevant documents (copies) must be handed over to Party B.

Article 6: Project duration

1. If the completion is delayed due to Party B’s reasons, 1% of the labor cost will be paid to Party A as liquidated damages every day until the labor cost Until all deductions are made. If the completion is delayed due to Party A's reasons, 1% of the labor cost of the decoration project price will be paid to Party B as a delay fee for each day of delay.

2. If the materials and equipment selected by Party A are of unqualified quality and affect the quality and construction period of the project, the rework costs will be borne by Party A. If a quality accident occurs due to Party B’s construction, the rework costs will be borne by Party A. Party B shall bear the responsibility and the construction period shall remain unchanged.

3. During construction, work stoppages due to project quality issues or disagreements between the two parties will not be treated as delays in work or delay in construction. Both parties should proactively request the relevant departments to mediate or arbitrate to coordinate and handle the matter as soon as possible. Resolve disputes to continue construction.

4. If the construction is required to be reworked due to Party A's reasons, or the construction period is delayed due to Party A's changes to the construction content, a visa is required, and Party A must bear all construction costs. If it is due to Party B's reasons, If rework occurs, Party B will be held responsible and the construction period will remain unchanged.

5. During construction, if Party A privately notifies the construction personnel to change the construction content without the consent of Party B, Party A will be responsible for any quality problems and delays in construction caused by the construction content.

Article 7: Project Acceptance

1. For project quality acceptance, except for concealed projects that require segmental acceptance, Party B will organize Party A to conduct completion acceptance after the entire project is completed. Both parties will handle project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. If it exceeds the deadline, Party A will automatically waive its rights and be deemed to have passed the acceptance. If there are any problems, Party A will Fang takes responsibility himself. Party A moves in on its own and is deemed to have passed the acceptance inspection.

3. If Party A cannot come for acceptance within the time limit specified by Party B, Party A shall promptly notify Party B and set another date. However, Party A shall acknowledge the completion date of the process or project and bear Party B's care fees and related expenses.

Article 8: Other Matters

1. Party A’s Responsibilities

1) Must provide the floor plan of the house and water, electricity and gas approved by the property management department Line diagrams, or Party A may provide house floor plans and water, electricity, and gas line diagrams, and make on-site explanations to Party B.

2) For secondary decoration projects, the house should be vacated entirely or partially, and obstacles affecting the construction should be removed. Necessary protective measures must be taken for the furniture, furnishings, etc. left in the house that can only be partially vacated, and Party B must go through the formalities and bear the costs.

3) If it is really necessary to dismantle or modify the original building structure or equipment or pipelines, you should go through the procedures with the local housing management department and bear the relevant costs. If public areas need to be used temporarily during construction, neighbors should be informed.

2. Party B’s responsibilities

1) Should take the initiative to present the business license, membership certificate or construction qualification; the handling salesperson must have the authorization certificate of the legal representative.

2) Assign a staff member as the construction site representative of Party B to be responsible for the performance of the contract, organize the construction according to the contract requirements, and complete the construction tasks on schedule with quality and quantity.

3) Responsible for the safety of the construction site, strictly prevent fires, wear certificates on duty, conduct civilized construction, and prevent pipeline blockage, water leakage, power outages, damage to items and other accidents caused by construction from affecting others. If it happens, you must be responsible for repair or compensation as soon as possible.

4) Strictly perform the contract and implement the credit construction period. If the completion is delayed due to material removal, delayed work or any excuse to induce Party A to advance funds, it will be treated as a breach of contract after investigation.

5) Bear the warranty responsibility within the scope of decoration construction. The warranty period is 12 months from the date when the project is completed and Party A passes the inspection.

Article 9: Liability for breach of contract

After the contract takes effect, if the party terminates the contract without authorization during the performance of the contract, 5% of the total contract amount shall be paid to the other party as liquidated damages. If the actual losses caused by the other party due to unauthorized termination of the contract exceed the liquidated damages, compensation shall be made.

Article 10: Dispute Resolution

If a dispute arises between the two parties during the performance of this contract, the two parties shall resolve it through negotiation without affecting the progress of the project.

If the parties are unwilling to resolve the dispute through negotiation, or if the negotiation fails, they may file a lawsuit with the People's Court in accordance with the provisions of this contract.

Article 11: Change and Termination of Contract

1. After the contract is signed by both parties and becomes effective, both parties must strictly abide by it. If either party needs to change the content of the contract, a supplementary agreement must be signed after consensus reached by both parties. If the contract needs to be terminated, the party who proposes to terminate the contract must do so in writing, pay liquidated damages equal to 10% of the total contract price, and go through the procedures for terminating the contract.

2. If any party proposes to terminate the contract during the construction process, it must submit it in writing to the other party. After both parties agree to go through the liquidation procedures and enter into a termination agreement, this contract can be deemed to be terminated.

Article 12: The contract takes effect

1. This contract and the contract attachments shall be stamped with the seals of both parties and shall take effect after signature.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including contract attachments and supplementary contracts) is made in duplicate, and Party A and Party B each hold copies.

Party A (owner): (Signature and seal) Party B: (Signature and seal)

Residence address: Business address:

Postal code: Postal code:< /p>

Working unit: Legal representative:

Appointed agent: Appointed agent:

Tel: Telephone:

Signing address: Signing date :