Traditional Culture Encyclopedia - Hotel franchise - Hotel renovation contract model

Hotel renovation contract model

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In accordance with the provisions of the Civil Law of People's Republic of China (PRC), the Building Law of People's Republic of China (PRC), the Measures for the Administration of Interior Decoration and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and combining with the specific construction conditions of this decoration project, both parties reached the following agreement through consultation.

Article 1; Project overview

1. Project location: _ _ _ _ _ _ _.

2. Project content: the total construction area is _ _ _ _ _ square meters.

3, the scope of contracting _ _ _ _ _; Decoration labor costs _ _ _ _ _;

4. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _; Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2; Contract price

1. Total renovation labor cost (RMB in words): _ _ _ _ _.

2. On the day of signing the contract, Party A shall pay 30% of the total labor cost of the decoration project.

3. When the decoration project is 80% completed, Party A will pay 40% of the second cost, RMB.

4. After the project is completed and accepted, Party A will pay 25% of the decoration expenses, namely RMB.

5. Multiply 5% as the project quality deposit, and pay it within one year after the project is completed and accepted, RMB: _ _ _ _ _ _.

Article 3; Party A's responsibilities

1. Appoint _ _ _ _ _ _ _ _ as the representative of the Employer at the construction site, be responsible for the contract performance, and supervise and inspect the project quality, progress, material mobilization and other matters.

2, decoration engineering before construction, responsible for the examination and approval formalities to the relevant departments.

3. Provide the contractor with water and electricity needed for the construction, and explain the matters needing attention. Responsible for coordinating the relationship with the surrounding neighbors.

4. Before starting work, the construction drawings or instructions shall be confirmed, and on-site disclosure shall be made to the contractor.

5. Responsible for handling the garbage generated by decoration,

Article 4; Party B's responsibilities

1. Appoint _ _ _ _ _ _ _ as the contractor's on-site representative to be responsible for the performance of the contract. Organize the construction as required, and complete the construction task on time with good quality and quantity.

2, in strict accordance with the drawings for construction, completes the quality inspection records, strictly implement the construction specifications, safety operation procedures, fire safety regulations, environmental protection regulations.

3, strictly abide by the provisions of the decoration construction time, reduce construction noise, reduce environmental pollution. Dealing with the nuisance caused by construction and its relationship with surrounding units and residents.

4. Be responsible for protecting all the facilities and finished products on the site before the project is handed over to the owner.

5. Ensure the cleanliness of the decoration site, and do a good job of cleaning and handling before completion.

Article 5; Material supply

1 The materials and equipment used in the decoration project must meet the national standards, have quality inspection certificates and indicate the product name, specification, model, manufacturer's name and address in Chinese. It is forbidden to use building decoration materials and equipment that have been explicitly eliminated by the state.

2. If the materials and equipment supplied by the Employer have quality problems or differences in specifications, causing losses to the project, the responsibility shall be borne by the Employer.

3. All materials and equipment purchased by the contractor shall be purchased according to the requirements of design, specifications and samples. If the material does not meet the quality requirements or the specifications are different, it shall not be used. If it has been used, the contractor shall be responsible for the losses caused to the project.

Article 6; Safety responsibility

1. All economic losses caused by the construction instructions provided by the confirmed drawings violating relevant safety operation regulations, fire prevention regulations and fire prevention design specifications shall be borne by the Employer.

2, the contractor for decoration activities, must strictly abide by the construction safety operation procedures, in accordance with the provisions, take the necessary safety protection and fire control measures, shall not use open flame and welding operations without authorization, to ensure the safety of workers and the surrounding houses and property.

3, because the contractor in the construction process in violation of the relevant safety operation procedures, resulting in safety accidents (including personal accidents), should bear all the responsibilities arising therefrom.

Article 7; Quality acceptance

1, this project is based on construction drawings, renderings and practice instructions, and is used as the acceptance standard for quality evaluation.

2. The contracting parties shall handle the concealed works and intermediate acceptance formalities in time. If the Employer fails to take part in the concealed works and intermediate acceptance on time, the Contractor may accept it by himself, and the Employer will recognize it.

3, after the completion of the project, the contractor shall notify the employer for acceptance, the employer shall organize acceptance within two days after receiving the acceptance notice, and go through the acceptance and handover procedures.

Article 8; Changes in work

1 If the Employer needs to change the project and construction method, both parties should communicate in time before construction, and the price and construction period can be changed accordingly.

2 The contractor puts forward reasonable suggestions for changing the design scheme and replacing materials, and the scheme can only be changed with the consent of the designer and the employer.

Article 9; Engineering warranty

After the acceptance, the contractor shall issue a letter of guarantee for the quality of residential interior decoration. Engineering (one-year warranty).

Article 10; responsibility for breach of contract

1. If the construction period is delayed or stopped halfway due to the reasons of the Employer, it shall be liable for breach of contract. The Owner shall pay the Contractor RMB 65,438+0,000 for each day of shutdown or shutdown. If the Employer fails to allocate the project funds as agreed in the contract, it shall pay a late fee of 5% of the project funds for each day overdue.

2. If the construction period is delayed due to the reasons of the contractor, the contractor shall pay the employer a penalty of 65,438+0,000 yuan for each day of delay. If the project quality fails to meet the quality standards agreed by both parties, _ _ _ _% of the total project price will be deducted.

3. The contractor shall properly protect the equipment provided by the employer and the furniture, furnishings and finished products stacked on the site. If losses are caused, compensation shall be made according to the price.

4, without the consent of the employer, the contractor dismantled the original building structure or equipment pipeline, resulting in losses or accidents (including fines) shall be borne by the contractor.

5. If the contractor recommends the use of decoration materials that do not meet the national standards to the employer, causing excessive air pollution, it shall be liable for compensation according to law.

6. Without going through the acceptance formalities, if the Employer uses it in advance or without authorization, the Employer shall be responsible for the losses caused.

7. If one party cannot continue to perform the contract due to reasons, it shall notify the other party to handle the contract termination agreement, and the responsible party shall compensate the other party for the resulting economic losses.

Article 11; settlement of dispute

The original of this contract is in duplicate, both of which are equally authentic, and the employer and the contractor hold one copy respectively.

Disputes arising in the course of performance shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it may be submitted to the _ _ _ _ _ _ _ _ Arbitration Commission for arbitration; Or bring a lawsuit to the people's court where the project is located according to law.

Employer (seal): _ _ _ _ _ Contractor (seal): _ _ _ _ _ _

The Employer's Tel: _ _ _ _ _ The Contractor's Tel: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _