Hotel renovation contract Electronic Edition

Hotel renovation contract Model Electronic Edition (5 General Articles)

With the general improvement of people's legal awareness, contracts appear more and more times, and the signing of contracts is the best norm for the rights and obligations of both parties. So how to write a detailed contract? The following is the electronic version (5 articles in total) of the hotel renovation contract model I compiled for you. Welcome to read the collection.

Hotel renovation contract Electronic Edition 1 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Measures for the Administration of Interior Decoration and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and combining with the specific construction conditions of this decoration project, the two parties reached the following agreement through consultation.

Article 1 General situation of the project

1 Project location:

Project content: The total construction area is 2000 square meters.

3. Scope of contract; Labor cost of decoration;

4. Commencement date: year month day; Completion date: year month day; Total construction period (including legal holidays): working days.

Article 2 Contract Price

1 Total amount of decoration labor (RMB in words): one hundred and thirty-two thousand yuan; ￥:

2. On the day of signing the contract, Party A shall pay 30% of the total labor cost of the decoration project; ￥:

3. When the renovation project is 80% completed, Party A will pay 40% of the second cost, RMB;

4. After the project is completed and accepted, Party A shall pay 25% of the decoration expenses, RMB;

5, multiplied by 5% as the project quality deposit, the deposit shall be paid within one year after the project completion acceptance, ￥;

Article 3 Party A's responsibilities

1. Appoint _ _ _ _ _ _ _ _ as the representative of the Employer at the construction site, be responsible for the contract performance, and supervise and inspect the project quality, progress, material mobilization and other matters.

2, decoration engineering before construction, responsible for the examination and approval formalities to the relevant departments.

3. Provide the contractor with water and electricity needed for the construction, and explain the matters needing attention. Responsible for coordinating with the surrounding neighbors.

4. Before starting work, the construction drawings or instructions shall be confirmed, and on-site disclosure shall be made to the contractor.

5. Responsible for dealing with the garbage generated by decoration,

Article 4 Responsibility of Party B

1. Appoint _ _ _ _ _ _ _ as the contractor's on-site representative to be responsible for the performance of the contract. Organize the construction as required, and complete the construction task on time with good quality and quantity.

2, in strict accordance with the drawings for construction, completes the quality inspection records, strictly implement the construction specifications, safety operation procedures, fire safety regulations, environmental protection regulations.

3, strictly abide by the provisions of the decoration construction time, reduce construction noise, reduce environmental pollution. Deal with the disturbance caused by construction and the relationship with surrounding units and residents.

4. Be responsible for protecting all the facilities and finished products on site before the project is handed over to the owner.

5. Ensure the cleanliness of the decoration site, and do a good job of cleaning and handling before completion.

Article 5 Material supply

1 The materials and equipment used in the decoration project must meet the national standards, have quality inspection certificates and indicate the product name, specification, model, manufacturer's name and address in Chinese. It is forbidden to use building decoration materials and equipment that have been explicitly eliminated by the state.

2. If the materials and equipment supplied by the Employer have quality problems or differences in specifications, causing losses to the project, the responsibility shall be borne by the Employer.

3. All materials and equipment purchased by the contractor shall be purchased according to the requirements of design, specifications and samples. If the material does not meet the quality requirements or the specifications are different, it shall not be used. If it has been used, the contractor shall be responsible for the losses caused to the project.

Article 6 Safety responsibilities

1. All economic losses caused by the construction instructions provided by the confirmed drawings violating relevant safety operation regulations, fire prevention regulations and fire prevention design specifications shall be borne by the Employer.

2, the contractor for decoration activities, must strictly abide by the construction safety operation procedures, in accordance with the provisions, take the necessary safety protection and fire control measures, shall not use open flame and welding operations without authorization, to ensure the safety of workers and the surrounding houses and property.

3, because the contractor in the construction process in violation of the relevant safety operation procedures, resulting in safety accidents (including personal accidents), should bear all the responsibilities arising therefrom.

Article 7 Quality acceptance

1, this project is based on construction drawings, renderings and practice instructions, and is used as the acceptance standard for quality evaluation.

2. The contracting parties shall handle the concealed works and intermediate acceptance formalities in time. If the Employer fails to take part in the concealed works and intermediate acceptance on time, the Contractor may accept it by himself, and the Employer will recognize it.

3, after the completion of the project, the contractor shall notify the employer for acceptance, the employer shall organize acceptance within two days after receiving the acceptance notice, and go through the acceptance and handover procedures.

Article 8 Engineering changes

1. If the Employer needs to change the project and construction method, both parties shall communicate and sign in time before the construction, and the corresponding price and construction period can be changed accordingly.

2, the contractor put forward reasonable suggestions to change the design scheme and the use of materials, must be approved by the designer, the developer can change the scheme.

Article 9 Project Warranty

After the acceptance, the contractor shall issue a letter of guarantee for the quality of residential interior decoration. Engineering (one-year warranty).

Article 10 Liability for breach of contract

1. If the construction period is delayed or stopped halfway due to the reasons of the Employer, it shall be liable for breach of contract. The Owner shall pay the Contractor RMB 65,438+0,000 for each day of shutdown or shutdown. If the Employer fails to allocate the project funds as agreed in the contract, it shall pay a late fee of 5% of the project funds for each day overdue.

2. If the construction period is delayed due to the reasons of the contractor, the contractor shall pay the employer a penalty of 65,438+0,000 yuan for each day of delay. If the project quality fails to meet the quality standards agreed by both parties, _ _ _ _% of the total project price will be deducted.

3. The contractor shall properly protect the equipment provided by the employer and the furniture, furnishings and finished products stacked on the site. If losses are caused, compensation shall be made according to the price.

4, without the consent of the employer, the contractor dismantled the original building structure or equipment pipeline, resulting in losses or accidents (including fines) shall be borne by the contractor.

5. If the contractor recommends the use of decoration materials that do not meet the national standards to the employer, causing excessive air pollution, it shall be liable for compensation according to law.

6. Without going through the acceptance formalities, if the Employer uses it in advance or without authorization, the Employer shall be responsible for the losses caused.

7. If one party cannot continue to perform the contract due to reasons, it shall notify the other party to handle the contract termination agreement, and the responsible party shall compensate the other party for the resulting economic losses.

Article 1 1 Dispute settlement

1. This contract is made in duplicate, with the same effect, and the employer and the contractor hold one copy respectively.

2. Disputes arising in the course of performance shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it may be submitted to Dalian Arbitration Commission for arbitration; Or bring a lawsuit to the people's court where the project is located according to law.

Employer (seal): _ _ _ _ _ _

Contractor (seal): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Hotel renovation contract Electronic Edition 2 Entrusting Party (Party A):

Organizer (Party B):

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the facade house. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Rule number one. Project overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. The construction area is _ _ _ _ _ _ _ _ square meters.

3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1), the removal of the intermediate partition wall shall not affect the original fire fighting and load-bearing columns and beams of the main structure.

2) Decorate the ceiling, dado, floor tile, wood floor and decorative lines of the whole hall without destroying the original ceiling.

3) Add _ _ _ _ rooms and decorate the hall.

4) Party B shall reasonably plan and decorate the kitchen according to Party A's requirements.

5) The billboard and bar on the facade shall be decorated according to Party A's wishes.

6) A vegetable washing pond, fish pond and sunshade shall be built behind the kitchen.

7) Improve all water and electricity facilities in the store.

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2, the project price

The project price (amount in words) is _ _ _ _ _ _ _ _.

Article 3, Quality Requirements

Party B's construction must be carried out in strict accordance with Party A's requirements.

Article 4. terms of payment

After the project is completed and accepted by Party A, all the money shall be paid.

Article 5. responsibility for breach of contract

1. Party B must complete the project within the project period, otherwise Party A has the right to refuse to pay the project payment and hold Party B accountable.

2. If Party B's construction does not meet the quality requirements, Party A has the right to order Party B to take full responsibility.

Article 6. Modification of contract

After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation.

Article 7. Entry into force of contract

1. This contract shall be sealed by both parties and come into force after being signed.

2. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Hotel renovation contract Electronic Edition 3 Party A:

Party B:

In order to complete this project, Party A originally contracted this project to Party B for about square meters, and both parties signed this agreement based on the principles of equality, mutual benefit, consensus through consultation, equality, voluntariness, fairness and good faith, and combined with the specific conditions of this project.

I. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project address

Three. Building area: about _ _ _ _ _ _ _ _ square meters.

Verb (abbreviation of verb) Contract method: contracting for work and materials.

Construction cost of intransitive verbs: RMB _ _ _ _ _ _ _ _ _ yuan/square meter including tax.

Seven. Term of the contract: the total number of days is _ _ _ _ _ _ _ _ _, counting from the date when Party A issues the notice of commencement. Delay due to force majeure.

Eight. Project nature: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Nine, the final accounts of both parties are based on the actual acceptance of both parties.

10. Party B is responsible for the pressure test work and expenses of the materials needed for the project, and Party A is responsible for coordinating the test data and handing them over to Party A for unified management.

XI。 Specific requirements in construction

1. quality requirements: the quality of this project shall be subject to the signature and seal of the state and the owner, and the specific requirements of Party A, and shall be the acceptance standard of the owner, supervision company and relevant functional departments.

2. Safety responsibility: During the construction process, Party B shall carry out the construction in strict accordance with the relevant national safety technical standards, so as to achieve civilized construction, clean and tidy site and perfect and appropriate safety measures. During the construction, Party B shall be responsible for all safety accidents within its contracted scope.

3. Estimation and payment method: The estimation is based on the actual quantities collected by Party A and Party B on site. After signing this agreement, Party B will pay RMB _ _ _ _ _ _ _ _ _.

4. Time limit requirements: Due to the tight time limit and heavy tasks of this project, Party B must carry out the construction in strict accordance with the requirements of Party A's construction progress, and shall not stop work or delay the construction period under any excuse. If the above situation occurs, it will constitute a breach of contract, and Party B shall pay _ _ _% of the total project cost to Party A as liquidated damages, and Party A has the right to terminate the agreement, and all its losses shall be borne by Party B. ..

Twelve. When signing this agreement, Party B shall pay Party A a performance bond of RMB _ _ _ _ _ _ _ _.

Thirteen. Liability for breach of contract: If one party breaches the contract, the breaching party shall compensate the other party for all losses caused.

14. Matters not covered in this contract shall be settled by both parties through negotiation. This Agreement is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Hotel renovation contract Electronic Edition 4 Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of hotel decoration engineering construction, both parties (hereinafter referred to as Party A) have reached the following agreement on matters related to hotel decoration engineering on the basis of equality, voluntariness and consensus:

Article 1 General situation of the project

1. 1 Project location: _ _ _ _ _ _ _ _ _ _.

1.2 project contents and practices (see attached table 1: hotel decoration project construction project confirmation table for details). Schedule 2: List of Contents and Practices of Hotel Decoration Works).

1.3 project contracting mode: both parties agree to adopt the following contracting mode.

Article 2: Contract work and materials.

1.4 The construction period of this project is _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1.5 contract price: the project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3 Obligations of Party A

4. 1 Create conditions for Party B to enter the site for construction _ _ days before commencement. Including: demolition of indoor furniture and furnishings, or stacking and covering indoor furniture and furnishings that are not easy to move on the principle of not affecting construction;

4.2 Provide water and electricity supply during construction;

4.3 Responsible for coordinating the relationship between the construction team and the hotel departments;

4.4 During the construction period, Party B shall be responsible for the public security and fire control work on the construction site; 4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance.

Article 4 Obligations of Party B

5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;

5.2 Strictly implement the management regulations of the construction site, without disturbing the people and polluting the environment;

5.3 Protect the furniture and furnishings in the original hotel and ensure the smooth flow of water pipes and pipes in the hotel;

5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed.

Article 5 Engineering changes

If it is necessary to change the project and construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see the Annex Change Order for Hotel Decoration Project).

Article 6 Time limit for a project is delayed

6. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party B:

(1) engineering quantity change and design change;

(2) Force majeure;

(3) Other circumstances in which Party A agrees to postpone the construction period.

6.2 If the construction period is affected by Party B's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.

Article 7 Quality standards

Both parties agree that the construction quality standard of this project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer. Article 10 Project Acceptance and Warranty

7. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:

7.2 After the project is completed, Party B shall notify Party A for acceptance, and the Employer shall organize acceptance within two days after receiving the acceptance notice, fill in the project acceptance form, and handle the handover formalities after the project payment is settled.

7.3 The warranty period of this project is _ _ _ months from the date of acceptance and signature by both parties. After acceptance and signature, fill in the project warranty form.

Article 8 Payment method of project funds

8. 1 Both parties agree to pay the project payment according to the following option:

8.2 After the contract comes into effect, Party A shall directly pay the project payment to the contractor according to the following table: RMB yuan on the first commencement date and RMB yuan on the second acceptance by both parties.

8.3 After all the project funds are settled, Party B shall issue a project receipt to Party A. ..

Article 9 Liability for breach of contract

9. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for its economic losses.

9.3 If the performance of the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

9.5 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the construction period will not be postponed. 12.6 If the construction period is delayed due to Party B's reasons, Party B shall pay the liquidated damages of RMB yuan to the other party for each day of delay.

Article 9 Ways of settlement of contract disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:

(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;

(two) to bring a lawsuit to the people's court according to law.

Article 10 Some Specific Provisions

10. 1 The garbage generated by the project construction shall be transported out of the construction site by Party B and transported to the designated place.

Article 11 Other agreed matters: _

Article 12 Supplementary Provisions

12. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.

12.2 after the signing of this contract, the project shall not be subcontracted.

12.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

12.4 the annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

Party A:

Party B:

Date of signing:

Hotel renovation contract Electronic Edition 5 Party A

party B

In accordance with the State Council's spirit of adhering to and improving the economic contract responsibility system, the enthusiasm of employees has been effectively mobilized and the economic benefits of enterprises have been improved. Party A entrusts the decoration project to Party B for construction, and the comrade is the leader of the contracting team and organizes professional team members to carry out the construction. Through consultation, both parties have reached the following contract for mutual compliance.

I. Project name:

Second, the project site selection:

Third, the way of contracting:

Four. Scope of contract and work content:

Scope of contract:

Contract content: overall decoration, construction according to the drawing. It does not include (glass, stainless steel, baking parts, soft bags, external facade. ) and other devices.

Verb (abbreviation of verb) Contract price agreed by both parties: The total contract price is RMB. Intransitive verb project payment method: pay cash in installments according to the construction progress.

Seven. Project time limit: According to the national time limit quota and the actual construction progress, it is agreed to start from: month, month and day and finish it on time without delay. 8. Project quality requirements: ensure that the completion acceptance reaches the relevant national acceptance grade standards.

9. Materials and materials shall be provided by Party A, and Party B shall provide the purchase list in advance.

X. construction progress:

The construction period shall not be delayed and shall not affect the construction of related processes. If the construction period is delayed due to the following reasons, Party A shall negotiate with Party B to agree on the number of days to extend the construction period, subject to Party A's visa, and the construction period shall not be extended without a visa:

(1) Number of projects added or added;

② Delays, obstacles and work stoppage caused by Party A;

③ Force majeure;

④ What may happen is not caused by Party B's fault or breach of contract.

For reasons other than the above, if Party B fails to complete the project within the contract period, it shall be liable for breach of contract.

Eleven, project quality and completion acceptance methods and standards:

Party B must carry out the construction and acceptance in strict accordance with the current Standards for Quality Inspection and Evaluation of Construction and Installation Projects and the Code for Acceptance of Construction Management promulgated by the State, the relevant regulations of the higher authorities and Party A's quality management system, and accept the on-site inspection and supervision of Party A's quality and safety department.

Twelve, the project payment and payment method:

1. Payment method: within three days after the signing of the contract, Party A shall pay Party B 15 working days (month and day), and then pay 10000 yuan. Pay RMB again (month, day) and RMB again one week before the project is completed.

2. Pay the balance within three days after the completion acceptance.

Thirteen. Party A's responsibilities:

1. Check, guide and supervise Party B's project progress, project quality, production safety and financial management.

2. Provide construction drawings and technical data, organize disclosure, and handle various work negotiations.

3. Arrange site layout and provide production and living places and temporary housing.

4. Organize project quality inspection and completion acceptance.

5. Construction water and electricity shall be connected to the construction site, and the water and electricity charges shall be paid by Party A. ..

6. Go through all kinds of decoration declaration and application procedures.

7. Pay on time according to the contract time. If there is any delay in payment, the construction period will be postponed on time.

Fourteen Party B's responsibilities:

1, there must be a complete technology, quality and safety progress management system. Organize the quality, duration and safety of the project in strict accordance with the construction drawings and current construction specifications. Cooperate with each type of work and complete all projects on time and with good quality.

2. Carry out the construction in strict accordance with Party A's construction organization facilities and requirements.

3, prepare the subentry project construction progress plan, material equipment plan and project budget, settlement book.

4. Comply with Party A's management rules and regulations on the safety, security and site capacity of the construction site.

5. Assist Party A to go through the formalities of applying for decoration, and the expenses for applying for decoration shall be borne by Party A. ..

6. Party B must ensure the payment of the wages of migrant workers, and 80% of the monthly progress payment (labor cost) must be paid to migrant workers.

15. settlement and arbitration of contract disputes: in case of any dispute during the execution of the contract, both parties shall settle it through friendly negotiation; If negotiation fails, it may be submitted to a local arbitration institution for arbitration.

Sixteen. Liability for breach of contract:

This contract shall come into effect as of the date of signature and seal by both parties, and shall be terminated after the project is completed and both parties fully perform their obligations. Both parties shall fully perform this contract, and shall not unilaterally modify or terminate it unless otherwise agreed in this contract. In case of breach of contract, the economic losses caused thereby shall be borne by the responsible party.

Seventeen. Annex to the contract:

18. This contract is made in duplicate, with each party holding one copy.

Person in charge of Party A:

Person in charge of Party B:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

;