Hotel demolition, how to write renovation contract?

Domicile: domicile:

Authorized Agent: Business LicenseNo.:

Tel: Legal Representative: Tel:

BP extension number: entrusted agent: Tel:

Designer of this project: Tel:

Person in charge of construction team: Tel:

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of family room decoration project construction, on the basis of equality, voluntariness and consensus, both parties reached the following agreement on matters related to the employer's family room decoration project (hereinafter referred to as the project):

Article 1 General situation of the project

1. 1 Project location: _ _ _ _ _ _ _ _ _ _.

1.2 contents and practices of the project (see attached table 1: confirmation form of family room decoration project for details). Schedule 2: List of Contents and Practices of Family Room Decoration Project).

1.3 project contracting method: both parties agree to adopt the following _ _ _ contracting method.

Works and materials contracted by the contractor (see Schedule 5: List of Decorative Materials Provided by the Contractor for details);

The contractor contracts some materials and the employer provides some materials (see Schedule 4: List of Decorative Materials Provided by the Employer for details). Schedule 5: List of Decorative Materials Provided by the Contractor);

The contractor contracts the project and the employer contracts the materials (see Schedule 4: List of Decorative Materials Provided by the Employer for details).

1.4 The construction period of this project is _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1.5 contract price: the project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ (for details, please refer to Annex III: Quotation for Decoration of Family Rooms).

Article 2 Project supervision

For the project subject to project supervision, the employer and the supervision unit shall separately sign a project supervision contract, and notify the contractor of the name, unit, contact information and responsibilities of the supervision engineer.

Article 3 Construction drawings

Both parties agree to provide construction drawings in the following ways:

The Employer shall design and provide the construction drawings in duplicate, one for the Employer and one for the Contractor (see Annex 6: Design Drawings of Family Room Decoration Project for details);

The employer entrusts the contractor to design and construct the drawings in duplicate, one for the employer and one for the contractor (see Annex 6: Design Drawings of Family Room Decoration Project for details), and the design fee is (in words) yuan, which shall be paid by the employer (this fee is not included in the project price).

Article 4 Obligations of employers

4. 1 _ _ days before construction, create conditions for the contractor to enter the site for construction. Including: demolition of indoor furniture and furnishings, or stacking and covering indoor furniture and furnishings that are not easy to move on the principle of not affecting construction;

4.2 Provide water and electricity supply during construction;

4.3 Responsible for coordinating the relationship between the construction team and the neighborhood;

4.4 The indoor load-bearing structure shall not be dismantled. If it is really necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments;

4.5 During the construction period, if the Employer still needs to use the bedroom partially, it shall be responsible for the public security and fire control of the construction site.

4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance.

Article 5 Obligations of the Contractor

5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;

5.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment;

5.3 Protect the furniture and furnishings of the original bedroom, and ensure that the water pipes in the bedroom are unblocked;

5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed.

Article 6 Engineering changes

If it is necessary to change the project and construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see Schedule 7: Family Room Decoration Project Change Order).

Article 7 Provision of materials

7. 1

For the materials and equipment provided by the Employer (see Schedule 4: List of Decorative Materials Provided by the Employer), the Employer shall notify the Contractor before the materials arrive at the construction site, and both parties shall accept them and handle the handover procedures;

7.2 For the materials and equipment provided by the Contractor (see Schedule 5: List of Decorative Materials Provided by the Contractor), the Contractor shall notify the Employer before the materials are transported to the construction site and accept the inspection by the Employer.

Article 8 Time limit for a project is delayed

8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by the Employer:

Engineering quantity change and design change;

Force majeure;

Other circumstances in which the Employer agrees to postpone the construction period.

8.2

If the time limit for a project is affected by the failure of the Employer to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the quality of the project is affected by the unqualified materials and equipment provided by the employer, the cost of rework shall be borne by the employer, and the construction period shall be postponed.

8.3 If the Employer fails to pay the project payment on schedule, the contract period shall be postponed accordingly.

8.4 If the construction period is affected due to the contractor's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem with the project quality due to the contractor, the cost of rework shall be borne by the contractor, and the construction period shall not be postponed.

Article 9 Quality standards

Both parties agree that the construction quality standard of this project is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer.

Article 10 Project Acceptance and Warranty

10. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:

_________________________;

_________________________;

_________________________.

The contractor shall notify the owner of the acceptance two days in advance, and fill in the project acceptance form after the stage acceptance is qualified (see Schedule 8: Acceptance Form for Family Room Decoration Project).

10.2

After the completion of the project, the Contractor shall notify the Employer for acceptance, and the Employer shall organize the acceptance within two days after receiving the acceptance notice, and fill in the project acceptance sheet (see Schedule 8: Acceptance Sheet for Family Room Decoration Project). After the project payment is settled, handle the handover procedures (see Schedule 9: Statement of Family Room Decoration Project for details).

10.3 The warranty period of this project is _ _ months from the date of acceptance and signature by both parties. After the acceptance and signature, fill in the project warranty form (see attached table 10: warranty form for family room decoration project).

Article 11 Method of payment for project funds

1 1. 1 Both parties agree to pay the project payment according to the following method:

After the contract comes into effect, the Employer shall directly pay the project payment to the Contractor as agreed in the following table:

-

| Payment Times | Payment Time| Payment Amount |

|——|——|——|

| Pay RMB for the first time | three days before the start of school |

| The second time | More than half of the project progress | Yuan paid | Yuan

| Third time | Acceptance by both parties | Paid yuan |

-

More than half of the project progress means: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Other payment methods: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1 1.2

After the acceptance of the project, the contractor shall propose the project settlement to the employer and send the relevant information to the employer. If the employer has no objection within _ _ _ days after receiving the information, it shall be deemed as consent. Both parties shall fill in the project settlement form (see Schedule 9: Settlement Form of Family Room Decoration Project) and sign it. The Employer shall settle the final payment of the project with the Contractor when signing the contract.

1 1.3 After all the project funds are settled, the contractor shall issue a formal unified invoice to the employer.

Article 12 Liability for breach of contract

12. 1

If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibility and compensate the other party for the economic losses caused.

12.2 The Employer shall be responsible for the losses caused by the Employer's use of the completed project in advance or without going through the acceptance formalities.

12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

12.4 If the Employer fails to pay the second (third) project payment on schedule, it shall pay the other party RMB as penalty for each day of delay.

12.5 if the quality of the project fails to meet the quality standards agreed by both parties due to the contractor, the contractor shall be responsible for the repair, and the construction period will not be postponed.

12.6 If the construction period is delayed due to the contractor's reasons, the contractor shall pay the other party RMB as liquidated damages for each day of delay.

Article 13 Settlement of Contract Disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:

(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;

(two) to bring a lawsuit to the people's court according to law.

Some specific provisions of Article 14

14. 1

The contractor is responsible for transporting the garbage generated by the project construction out of the construction site and to the designated place, and the employer is responsible for paying the garbage removal fee of (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (this fee is not included in the project price).

14.2 during the construction period, the employer will give the key of the outhouse to the contractor for safekeeping. After the project is completed and accepted, the employer is responsible for providing new locks, and the contractor is responsible for site installation and delivery.

14.3 During the construction period, the contractor's daily working hours are: from _ _ _ to _ _ _ and from _ _ _ to _ _ _ in the afternoon.

Article 15

Other agreed items: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 16 Supplementary Provisions

16. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.

16.2 after the signing of this contract, the project shall not be subcontracted.

16.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

Employer (signature): Contractor (seal):

Legal representative:

Entrusted agent:

Year, month, sun, moon, sun.

Editor in charge: Mi and Xiao Yang