Model contract agreement for excavator construction

6 excavator construction contract agreement model.

The opinions of all parties should be "combined" for consultation. If an agreement is reached, everyone agrees, thus forming a "contract". When signing a construction contract, we must abide by national laws and conform to national policies. Are you looking for "model contract agreement for excavator construction"? I have collected relevant information below for your reference!

Model contract agreement for excavator construction 1

Employer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Economic Contract Law of the People's Republic of China, the Construction Law of People's Republic of China (PRC), the Regulations on the Quality Management of Construction Projects and other relevant laws and administrative regulations, as well as the relevant construction project quality standards, norms and regulations, and the laws and regulations promulgated by _ _ _.

I. Overview of the Project

(1) Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the scope of project contracting

Safety maintenance and rectification

Third, the term of the contract.

_ _ _ _ _ days

Fourth, the project cost

The project cost is _ _ _ _ _ _ _ _ Yuan only.

Verb (abbreviation of verb) quality standard

5. 1 quality standard: in line with the current national or industrial quality evaluation standards.

5.2 Use standards and specifications (including but not limited to the following)

5.2. 1 The technical standards and specifications of this project shall conform to the national, ministerial and local construction technology (acceptance) regulations and specifications.

5.2.2 Local standards and regulations applicable to this project must conform to provincial standards and regulations.

Six, the way of contracting

Contract work, materials, quality, time limit for a project and safety according to the work contents listed in the scope of contract in Article 2 of this contract.

Seven. Project valuation

7. 1 The calculation and compilation principle of this project: according to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

7.2 Determination of labor and material prices: Labor wages are calculated according to the comprehensive wage unit price in document 1998. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

7.3 The specific quantity shall be subject to Party A's visa.

Eight, time limit for a project

In any of the following circumstances, the construction period can be extended after the visa is verified.

8. 1 Work stoppage caused by force majeure factors, including: national policy adjustment, war, turmoil, falling objects in the air or other explosions and fires not discovered by Party A and Party B, as well as natural disasters such as floods and earthquakes. The hourly rainfall is 200mm or above (with _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

8.2 If the construction period of key working procedures of Party B is delayed due to reasons other than Party B, the construction period may be extended according to the actual situation.

8.3 If the construction period is delayed due to Party B, the contract construction period cannot be postponed, and the expenses shall be borne by Party B. ..

8.4 If the project is delayed due to Party A's reasons, the contract period shall be postponed and the expenses shall be borne by Party A. ..

Nine. Payment of project funds

9. 1 After the project is completed, Party A shall pay Party B _ _ _ _ _% of the project budget price within _ _ _ _ _.

9.2 After the project settlement is completed, Party A shall pay _ _ _ _% of the total settlement price and keep _ _ _ _% of the total settlement price as the project warranty fund. There is no quality problem within _ _ _ _ _ days after one year from the date of acceptance of the project, and the warranty money will be returned in full without interest.

X. liability for breach of contract

10. 1 Default Scheme This contract shall be liable for breach of contract in the form agreed in this contract. If there is no agreement in the contract, the Contract Law and relevant laws and regulations shall prevail.

10.2 If the breaching party's breach of contract causes losses to the other party, if the breaching party's liability for breach of contract is still insufficient to make up for the other party's losses, it shall also be liable for compensation.

XI。 Safe production and civilized construction

Conscientiously implement the national and local laws and regulations on construction safety production and the relevant management requirements of the construction unit, do a good job in safety management, put an end to major safety accidents, and do a good job in comprehensive social management.

Twelve. Settlement of disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation or mediated by the local construction administrative department. If mediation fails, both parties agree to settle it by the people's court where the plaintiff is located, but the construction shall not be interrupted during the litigation.

Thirteen. others

Party B shall pay the wages of migrant workers in time according to relevant national regulations. If the project undertaken by Party B is delayed in the construction process, it will be handled by the government, and Party A has the right to pay the wages of migrant workers directly from the project funds. This contract is signed in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (official seal) _ _ _ _ _ _ _ _ _ Party B (official seal) _ _ _ _ _ _ _ _ _ _

Legal representative (signature) _ _ _ _ _ _ _ Legal representative (signature) _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model excavator construction contract II

Employer (full name): (hereinafter referred to as Party A)

Contractor (full name): (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this project and conclude this contract.

I. Overview of the Project

Project Name: Residential Street Lamp Project

Project location: Ronghe Community, Qingxiu District, Nanning, Guangxi

Project content: pipeline laying, lamp holder and lamp installation in the first phase of the community.

Second, the scope of project contracting

Scope of contract: equipment and material supply, pipeline installation, accessories installation, tube well masonry, high-rise building lighting and floodlighting debugging of the above projects.

Third, the term of the contract.

Commencement date: May 20, 2006 18 Completion date: June 20, 2006 18. The total calendar days for pipeline laying and lamp installation is 20 days.

Fourth, quality standards.

All engineering quality standards must be excellent (if the engineering quality does not meet the standards, Party B shall be responsible for rework losses).

Verb (abbreviation of verb) contract price

1. amount (in words): pipeline laying, installation and debugging cost: (fixed total price) ￥171.00 yuan.

2. Lamp price: Unless otherwise agreed, Party A reserves the right to increase the price, tentatively around (a supplementary agreement shall be signed separately for this fee).

Terms of payment for intransitive verbs

After the contract is signed, Party B will immediately carry out on-site actual surveying and mapping and lay various street lamp pipelines according to the drawings and Party A's opinions. After the pipeline and light pole (column) foundation are completed, Party B shall pay 20% of the contract price, 20% of the contract price after the lamps are installed in the site, and 20% of the contract price for the remaining engineering equipment.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model contract agreement for excavator construction 3

Party A:

Party B:

Party B hereby undertakes the "installation and construction" of Party A's street lamp installation project of Tongxin Road and Hexie Road in Huishui County, Guizhou Province, and * * * agrees as follows:

1, construction content

The construction length is about 3.2KM, and Party B undertakes excavation, foundation cage supply, foundation pouring, trenching, pipeline laying, cable supply, cable laying, protection, installation, debugging and correction of light poles, lamps and light sources.

2. Installation instructions

The length of Tongxin Road is about 1.47km, and the distance between street lamps is 30m. Install HXZX023 high school language lamp, numbered 5 1 on one side and 52/on the other. The two lamps are connected by cables, which are laid through pipes. The length of Harmony Road is about 1.78km, and the distance between street lamps is 30m. HXZX0 13 is equipped with 60 Chinese lamps on one side, namely 120 lamps on both sides. The two lamps are connected by cables, which are laid through pipes.

3. See the price list for related quantities and expenses:

4, the installation period

Under the condition that Party A's infrastructure and transformer are provided in time, at least 30 street lamps shall be installed and lit within 0/2 days of Tongxin Road/KLOC-; Before June 8, at least 30 street lamps on Harmony Road have been installed and turned on. However, during the installation period, if the construction period is delayed due to irresistible factors such as typhoon, flood, earthquake and other natural reasons, both parties shall negotiate to solve it.

5, quality standards and acceptance criteria

All engineering quality standards must be excellent (if the engineering quality does not meet the standards, Party B shall be responsible for rework losses).

The acceptance shall be conducted in accordance with the relevant national regulations, the quality requirements, technical indicators and commitments of Party A's design documents and the standards agreed in this contract.

6. Terms of payment

After the signing of the agreement, Party A shall pay the contract money in advance to Party B; When more than 50% street lamps are installed and lit, 45% of the contract price shall be paid; When more than 75% of the street lamps are installed and turned on, 70% of the contract price shall be paid; Pay 97% of the final settlement of Party B after the installation and debugging of street lamps are qualified, and the remaining 3% will be used as quality deposit. The warranty period is one year. If there is no quality problem in the project within one year, Party A will return it to Party B without interest. Party A shall provide the corresponding receipt after receiving the payment every time.

7. Others

Before the street lamps are delivered to Party A for use, Party B shall be responsible for the storage of important materials such as street lamps and cables. Construction personnel are composed of factory technicians and migrant workers.

8. This Agreement is made in triplicate, with Party A holding two copies and Party B holding one copy. It will take effect after both parties sign and pay the advance payment.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model agreement on excavator construction contract 4

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Based on the principle of equality and mutual benefit, Party A and Party B reached the following supplementary agreement through friendly consultation on matters related to the project construction:

First, the project cost

1, and the civil engineering cost will be charged at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. The installation project fee shall be charged according to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

3. The material price calculation is divided into two stages: civil structure calculation and installation of embedded materials calculation (from underground structure to main body capping). And the material calculation stage of building hydropower installation project (from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. The difference between the information price of engineering materials and the market price of engineering materials and equipment within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. Party B agrees not to charge the following fees: measures to rob work, measures to ensure project quality, measures to disturb people, measures for insufficient space and general technical measures for construction safety (if included in the quota project, it will not be deducted separately, but will not be added); On-site civilized construction measures shall be negotiated separately by both parties.

6. For the project subcontracted by Party A, Party B's project department will charge _ _ _ _ _% of the total subcontract cooperation fee and management fee (excluding the main equipment fee), and Party A will deduct it from the project funds of various disciplines and pay it to Party B's Celebration Garden Project Department.

7. The calculation basis of the project cost is the relevant provisions of this agreement, the construction drawings and minutes of the blue prints.the design of buildings, structures and devices designed by _ _ _ _ _ _ _ Design and Research Institute of the Ministry of Machinery Industry, the design changes confirmed by Party A's competent engineering department, design institute and supervision company, and the economic visas on the construction site confirmed by Party A and supervision company.

8. Design changes and economic visas shall be measured and priced according to the principles agreed in the relevant provisions of this agreement. Unless Party A agrees, Party B shall not refuse the construction, nor shall it be priced separately according to the total price as required.

2. Party A shall provide engineering materials, equipment and Party A's subcontracted projects.

1. The materials supplied by Party A are: steel bars and commercial concrete.

2. The equipment provided by Party A includes elevators, generators, high and low voltage distribution cabinets and water pumps.

3. The professional projects subcontracted by Party A include: aluminum alloy door and window security engineering, fire door security engineering (including entrance door), secondary interior and exterior decoration and installation engineering of podium, elevator security engineering, fire fighting engineering, gas engineering, air conditioning engineering, high and low voltage power distribution engineering, cable TV, telephone engineering, monitoring intercom system engineering, automatic meter reading and electricity meter system engineering.

Third, the project payment

1._ _ _ _ years ago, the payment and settlement of the pile foundation project.

2. Settlement of pile foundation works constructed after _ _ _ _ years: After the pile foundation construction is completed and passed the quality inspection, Party B shall prepare all engineering materials and settlement book, and Party A shall complete the audit within _ _ _ _ _ _ _ _ days after receiving all engineering materials. After Party B confirms the audit results of Party A, Party A shall _ _ _ _.

3. Within _ _ _ _ _ _ _ _ days after the completion of the basement project, Party B shall submit the settlement data to Party A for review, and Party A shall complete the review within _ _ _ _ _ _ _ _ _ _.

4. For the superstructure project, Party A shall, according to the structure construction progress, Every _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The main building decoration and water and electricity installation shall be regarded as a construction stage of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ At each stage after the completion of the above construction progress, Party B shall submit a visual progress report to Party A, and Party A shall complete the audit according to the requirements stipulated in the contract within _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. Pay _ _ _ _ _ _ _% according to the tentative cost of the project contract within _ _ _ _ _ days after the project completion acceptance. And the settlement time exceeds _ _ _ _ _ _ _ _ _ months, with an average of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four, construction permits and other procedures

All construction permits and other procedures for construction application, approval, inspection, quality supervision, quality inspection and safety inspection that need Party B's assistance in this contract project shall be completed and handed over to Party A within _ _ _ _ _ _ days after Party A provides relevant procedures.

Verb (abbreviation of verb) Matters not covered in this Agreement

Matters not covered in this agreement shall be discussed separately by both parties.

This agreement is an integral annex to the construction application contract. If the construction application contract is inconsistent with this supplementary agreement, this agreement shall prevail.

This Supplementary Agreement shall come into effect as of the date when both parties sign and seal it, the _ _ _ _ _ _ _ _ Project Department is formally established, and Party B completes the construction permit on schedule.

Party A (signature): _ _ _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _.

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Model contract agreement for excavator construction 5

Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In order to further clarify the responsibilities, rights and obligations of Party A and Party B, on the basis of the Construction Project Contract of Shuanglongyuan Commercial and Residential Building Project in Puding County, Anshun City, according to the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), and in combination with the specific conditions of this project, Party A and Party B sign this supplementary agreement on a voluntary basis.

I. Overview of the Project

1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

3. Building area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

4. Structural style: the bottom layer is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Design unit: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

6. Supervision unit: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the project content and contract scope

1._ _ _ _ _ _ _ has been changed to _ _ _ _ _ _ _.

2. _ _ _ _ _ _ _ Cancel.

3. This project has seven floors and the structure is inclined.

4. The stair tread is _ _ _ _ _ _ _ _.

5. The external wall _ _ _ _ _ _ _ was cancelled.

6._______________ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

7. The rest shall be constructed according to the original drawing.

Third, the term of the contract.

(All dates listed in this agreement are calendar days)

Commencement and completion dates:

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four. mode of payment

This project is a one-time lump sum project with a construction area of _ _ _ _ _ _ _ _ yuan/square meter; In the process of construction, if the engineering quantity is increased according to the requirements of Party A, it shall be calculated according to the price negotiated by both parties; This project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Verb (abbreviation of verb) The entry into force, termination and dispute settlement of a contract.

1. In addition to the normal quality assurance, this contract will be terminated after both parties have completed all the obligations stipulated in this contract.

2. This Supplementary Agreement shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. This Supplementary Agreement is an immaterial supplement to _ _ _ _ _ _ _

4. Any dispute arising from the performance of this Agreement shall be settled by both parties through negotiation. If negotiation fails, the case shall be submitted to the _ _ _ _ Arbitration Commission for arbitration.

5. This Supplementary Agreement shall take effect within _ _ _ _ _ days from the date of signing by both parties.

Party A (signature): _ _ _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _.

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Model agreement on excavator construction contract 6

Employer (full name): (hereinafter referred to as Party A)

Contractor (full name): (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this project and conclude this contract.

I. Project Overview Project Name:

Project location:

Project content: pipeline laying, lamp holder and lamp installation in the first phase of the community. Second, the scope of project contracting

Scope of contract: equipment and material supply, pipeline installation, accessories installation, tube well masonry, high-rise building lighting and floodlighting debugging of the above projects.

Third, the term of the contract.

Commencement date: May, 20__ 18.

Completion date: June 20th __ 18.

The total calendar days for pipeline laying is 20 days, and the calendar days for lamp installation is 30 days.

Fourth, quality standards.

All engineering quality standards must be excellent (if the engineering quality does not meet the standards, Party B shall be responsible for rework losses).

Verb (abbreviation of verb) contract price

1. Amount (in words): pipeline laying, installation and debugging fee: ￥.

2. Lamp price: Unless otherwise agreed, Party A reserves the right to increase the price, tentatively around (a supplementary agreement shall be signed separately for this fee).

Terms of payment for intransitive verbs

After the contract is signed, Party B will immediately carry out on-site actual surveying and mapping and lay various street lamp pipelines according to the drawings and Party A's opinions. After the pipeline and light pole (column) foundation are completed, Party B shall pay 20% of the contract price, 20% of the contract price after the lamps are installed in the site, and 20% of the contract price for the remaining engineering equipment.

VII. Composition of Contract Documents

The documents constituting this contract include:

1, this contract

2. Contract conditions

3, the tender documents

4, the book of tender and its attachments

5. Relevant national and municipal standards, specifications and relevant technical documents

6. Cartography

7. Written agreements or documents between the two parties on project negotiation and change.

Eight. The meanings of related words in this agreement are the same as those given to them in the terms of the contract.

Nine, the contractor promises to the employer to carry out construction and completion in accordance with the contract, and undertake the project quality warranty responsibility within the quality warranty period.

10. The Employer promises to the Contractor to pay the contract price and other payables according to the time limit and method agreed in the contract.

XI。 This contract is made in quadruplicate, with Party A and Party B holding two copies respectively.

Twelve. Entry into force of contract

Contract signing time:

Contract signing place:

This contract shall come into effect after being signed and sealed by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _