Simple factory construction contract

With the deepening of people's understanding of the law, contracts appear more and more times, and the signing of contracts is the best norm for the rights and obligations of both parties. So what should we pay attention to when concluding a contract? The following is a simple factory contract template (5 in total) that I have compiled for you. I hope it will help you.

Simple workshop construction contract 1 construction unit (party a):

Contractor (Party B):

In accordance with the spirit of People's Republic of China (PRC) Contract Law and relevant laws and regulations, Party A and Party B agree to sign this contract through friendly negotiation on the principle of equality and mutual benefit.

I. The rights and responsibilities of Party A are as follows:

1. From the date when Party A and Party B sign this contract, the amount of advance payment is RMB 10,000 Yuan only.

2. Party A shall be responsible for the procurement and acceptance of materials, while Party B shall build the plant without contracting materials and pay according to the progress of the project. (Construction according to the drawings provided by Party B)

3. Party A helps Party B to provide accommodation facilities for workers (meals are charged according to actual expenses).

4. Party A requires Party B to complete the project before the completion date of 20xx65438+February 3 1. If Party B fails to complete the project on time, Party A has the right to demand compensation from Party B for the economic losses caused by the delayed use and production.

Two. The rights and responsibilities of Party B are as follows:

1. Party B shall take full responsibility for the safety during the construction period, and Party A shall not bear any relevant responsibilities.

2. Party B shall design, manufacture and install according to the sample drawings. If there is any inaccuracy, Party A has the right to reduce the project cost and require Party B to carry out the construction again until it reaches the standard.

3. Party B requires the construction personnel to respect the living system of employees in the factory, not to make noise, gamble, make trouble or throw cigarette butts in the factory, and to keep the production and living areas safe, hygienic and tidy.

4. Party B shall complete the project and deliver it before the date of signing the contract by both parties: 20xx65438+February 3 1.

Third, the construction project and unit price

1. The curved roof workshop shall be constructed according to the drawings confirmed by both parties. If there is any change in the construction, it will be settled according to the actual engineering quantity after the change is completed, and the unit price will remain unchanged.

2. The quantity is about 20xx square meters, and the unit price is 425 flat yuan/square, which is settled according to the actual projected area after completion * unit price.

Four. Payment method:

1. Through negotiation between both parties, Party A pays according to the following table:

2. After the installation is completed, the ownership of this steel structure construction project shall be owned by Party B before Party A pays off the money.

3. If Party A fails to pay on time, Party B has the right to dismantle the demolished construction project after 30 days overdue, and all expenses shall be paid by Party A, and a fine of 3% of the total contract price shall be imposed for each overdue 1 day, and all losses shall be compensated to Party B..

Verb (abbreviation for verb) Installation, layout and acceptance procedures

1. Production and installation period: After signing the contract, after Party B receives the advance payment, Party B will enter the site for production and installation, and Party A will carry out production and installation within the second working day after Party B delivers the buildable site and the power is in place; In case of rainy days, natural disasters or Party A's factors, Party B shall make up the corresponding construction period according to the corresponding working days.

2. On the day when the installation is completed, Party A shall send relevant person-in-charge to cooperate with the person-in-charge of Party B to handle relevant acceptance procedures and check the engineering quantity. If Party A fails to send the relevant person in charge to inspect and check the engineering quantity for more than 3 working days, it will be regarded as Party B's breach of contract, and the construction of the project built by Party B is qualified, and the settlement will be made according to the engineering quantity issued by Party B. ..

3. The remaining100,000 yuan is used as the quality guarantee, which will be paid after half a year of normal use.

Six, engineering quality standards and warranty conditions

1. Party B must bear the safety responsibility in the steel structure construction (except for those not caused by Party B); The projects built by Party B shall have certain ability to resist external damage. The quality warranty period of the main project is half a year. During the warranty period, quality problems will always be repaired by Party B free of charge, and will be negotiated separately for reasons other than Party B's.

2. Damage to the steel structure construction project caused by Party B's quality problems shall be borne by Party B; Party B shall not bear any relevant responsibilities for the damage caused by natural disasters, force majeure and man-made reasons.

Seven. Matters not covered in this contract shall be supplemented by both parties through consultation in the spirit of friendly cooperation, and the supplementary agreement shall have the same legal effect as this contract.

Eight. This contract shall come into effect as of the date of signature by both parties. In case of any dispute during the performance of this contract, both parties shall settle it through consultation. If negotiation fails, it shall be submitted to the court where Party B is located for litigation.

Nine. This contract is made in duplicate, one for each party.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contract II of Simple Workshop: Owner (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on this construction project and conclude this contract.

I. Overview of the Project

1. Project name: Shiyan Beili Industry and Trade Co., Ltd. Phase III Factory Building.

2. Project location: No.33 Bailang East Road, Shiyan High-tech Industrial Development Zone.

3. Project content: The list of the third-phase workshop (steel structure+civil work+decoration) is as follows:

(1) Sub-items of ground beam, ground and earthwork.

(2) The civil engineering quantity of the external wall of the building above 0.00 in the drawing includes: masonry wall of axis a-d* 1-12 * A and decoration of internal and external walls; Outdoor aproll and ramp;

(3) In steel structure engineering, in addition to external wall enclosure (including color steel plate, wall beam, etc. ) elevation of 4.65m below the axis 12*a-g, G * 5*d-g 1-5, and the rest shall be within the scope required by the drawings and the written notice of the blue prints.the design submitted by party a. ..

Second, the construction period

From the third day after signing the contract, the total effective working days of this project are 60 days, and the specific construction period is as follows:

(1) foundation works for 30 days;

② Installation of main steel structure 15 days;

(3) Roof and roof drainage system shall be installed for 5 days;

(4) Installation of doors and windows and enclosure system 10 day.

⑤ Other auxiliary and finishing works are 10 days.

Party B must complete the project as scheduled within the agreed time limit, and delay for 65,438+0 days without reason, and be fined 65,438+0,000 yuan, with the upper limit of the fine being 65,438+0, 500 yuan. If the delay exceeds 15 days, Party A may find another unit for construction because Party B gives up the construction, and the completed project shall be settled according to 50% of the actual completed project quantity. Under the following circumstances, the extension can be extended after being signed by the on-site representative of Party A:

1, rainy and snowy weather is not suitable for installation.

2. Spring Festival.

3. Design errors, inaccurate data and engineering changes proposed by Party A. ..

4. Construction stops due to reasons of Party A and the third party.

5. Work consultation that may affect Party A's normal production.

Three. Contract price and payment method

1. Contract price:

The contract content of this project is RMB eight hundred and fifty thousand Yuan only (￥ 850,000.00).

2. Payment method:

Party A prepays 30% of the total project amount; Pay 20% of the total project amount after the completion of the roof and enclosure system; Pay 15% of the project payment after all the finishing work is completed and accepted; The balance (5% of the total project amount) is used as the quality guarantee.

3. Project price change: for new projects involving engineering technology changes other than the contract projects, the engineering technology change notice and construction visa jointly signed by the site representative and the project manager shall prevail, and the main raw materials shall be accounted based on the market price quotation. The change fees shall be agreed by both parties through consultation, and tax-related matters shall be implemented with reference to national regulations.

Fourth, material supply.

1. Party A has clear regulations on the supply of raw materials for the main steel structure and enclosure system, that is, the medium plate used for the main steel structure must be purchased from WISCO original factory, and the color plate must be produced by Baosteel. Before steel structure assembly and color plate rolling, Party B must provide Party A with the manufacturer's valid factory certificate, and promptly notify Party A to witness and sample the materials used in the main steel structure. Welded components of the main steel structure must be inspected by weld flaw detection according to national regulations, and a test report shall be issued. Solder, welding process, welder's technical grade certificate and inspection method used must meet the requirements of relevant national mandatory regulations.

2. The remaining materials shall be purchased by Party B itself, and all purchased materials must meet the requirements of the design and construction unit and various technical standards. Moreover, the quality certificate and factory certificate must go with the goods, and the materials must be witnessed and accepted by the on-site representative of Party A before they can be used. If the purchased materials are used by Party B without acceptance, and the quality of the project is unqualified, Party B shall be responsible for repairing or dismantling, and bear all the expenses arising therefrom. The delayed construction period shall not be postponed, and Party A shall be compensated for the economic losses caused thereby.

Verb (abbreviation for verb) project quality

1. project acceptance: the project quality must meet the requirements of standards and specifications stipulated in the contract. If the acceptance is not organized within 30 days after the completion of the project (counting from the date when Party B submits the acceptance notice of the main project to Party A), the project shall be deemed as qualified.

2. Party B must carefully organize the construction according to the design drawings approved by Party A. In case of special circumstances, it needs to be changed, and it can only take effect after it is agreed and signed by the site representative of Party A and the project manager.

3. Party B must accept the quality supervision and normal work inspection of the on-site representative of Party A, and shall not obstruct it without reason.

4, project acceptance basis:

A. Construction drawings, construction change notice, construction visa, atlas of relevant building standards and records of blue prints.the design signed by Party A. ..

B. Relevant national standards:

Unified standard for construction quality acceptance of building engineering (gb50300-200 1)

Code for Acceptance of Construction Quality of Building Foundation Engineering gb50202-2002

Code for Quality Acceptance of Masonry Engineering (gb50203-2002)

Code for Acceptance of Construction Quality of Concrete Structure Engineering (gb50204-2002)

Code for Acceptance of Construction Quality of Steel Structure Engineering (gb50205-200 1)

Code for quality acceptance of roofing engineering gb50207-2002

Code for Quality Acceptance of Underground Waterproofing Engineering (gb50208-2002)

Code for Acceptance of Construction Quality of Building Ground Engineering (gb50209-2002)

Code for Quality Acceptance of Building Decoration Engineering (gb502 10-2002)

C. For the parts not specified or detailed in the drawing specifications, the acceptance can be made with reference to the practices of Party A's existing first-phase workshop. Engineering projects that have not been confirmed by Party A's site representative and project manager are regarded as unqualified projects.

Six, safety in production

Party B shall strictly abide by the operating rules for safe production, hold relevant certificates, and put an end to safety and quality accidents. If Party B has a safety accident during the construction process, causing personal and property losses to himself and others, Party B shall be responsible. Seven. Rights and obligations of both parties

1. Party A

A. provide necessary construction conditions for party b. For example, on-site water supply and power supply, smooth roads, flat construction site, hoisting conditions, etc.

Party B shall provide Party B with two design drawings and technical data related to the project. Organize relevant units to participate in the joint review of construction drawings and project disclosure three days before commencement.

C. Be responsible for examining and approving the construction organization design (construction scheme) prepared by Party B, and have the right to stop Party B from violating the examined construction organization design.

D, responsible for handling the necessary construction site access certificates for Party B, and ensuring the passage of Party B's main and auxiliary materials, construction machinery and personnel. E, timely organize relevant parties to participate in the project acceptance.

F, timely draw project funds according to the schedule.

2. Party B

A. Party B foresees that some construction factors that restrict the entry and exit of Party A's subordinate members unrelated to this project may affect Party A's production, and shall immediately notify Party A and discuss solutions. If Party B fails to notify in time, all losses caused by Party A's production impact shall be borne by Party B. Unless it is necessary for construction, Party B's construction personnel and construction equipment shall not enter or leave Party A's production site at will.

B, prepare the construction organization design (construction scheme) three days before the start of construction, and submit it to Party A for approval in time. After examination and approval, the construction will be carried out in strict accordance with the construction organization design.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contract III of Simple Factory Building: Employer (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Project name:

Project location:

Reasonable service life of project design:

Design certificate level:

Contract signing time:

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations on the Administration of Survey and Design of Construction Projects and the Measures for the Administration of Quality and Market of Survey and Design of Construction Projects in Guizhou Province, Party A and Party B reached an agreement through consultation.

Article 1 Party A entrusts Party B to undertake the engineering design of the above-mentioned factory building project, and Party A pays the corresponding remuneration (design fee).

Article 2 The project design includes:

1, general layout design;

2. Architectural design of complex building, factory building and warehouse;

3, fire water and electricity construction design;

4. 1 Effections of wastewater treatment facilities design and workshop overall design.

Article 3 On the day of signing the contract, Party A shall provide Party B with the land red line map 1 copy approved by the competent government department.

Article 4 Within 65,438+00 days after the signing of this contract, Party B shall submit all the design materials required for the first examination and approval, and ensure the approval of the planning department. Within 65,438+00 days after the first examination and approval, Party B shall deliver to Party A all the design materials approved by the planning department (4 civil construction drawings, 4 fire-fighting and hydropower construction drawings, 4 standard design scheme binding texts, and 65,438+0 overall design renderings). ..

Article 5 The design fee is based on the total construction area (including the construction area of workshop, complex building, warehouse and duty room) in the scheme adopted by the planning examination and approval department, and is calculated as 10 yuan/m2. Within 3 days after the signing of the contract, Party A shall pay Party B a design fee of 20,000 yuan in advance, and within 3 days after the design scheme is first approved by the planning approval department, Party A shall pay Party B a design fee of 24,000 yuan in advance, and all design materials shall be approved by the planning department.

Article 6. Party B is responsible for coordinating the planning examination and approval department to handle related matters, and ensuring that the design materials pass the examination and approval smoothly. The coordination fee shall be borne by Party B, and Party A agrees to compensate the coordination fee of RMB. If the planning approval department refuses to approve the documents and materials designed by Party B, Party A has the right to refuse to pay the design fees paid by Party B, and Party A has the right to claim the paid design fees.

Article 7 After the project starts, if Party A fails to solve the technical problems related to the design, Party B has the obligation to cooperate with Party A to solve them. If relevant departments require Party B to participate in activities related to the project according to regulations, Party B shall send personnel to participate.

Article 8 During the performance of the contract, if Party A changes or increases the design content, which leads to the rework of Party B's design, Party A shall pay corresponding remuneration according to the workload previously consumed by Party B, and the payment amount shall be negotiated by both parties separately.

Article 9 During the performance of the contract, Party A shall provide necessary working and living conditions, transportation and other convenient conditions for the personnel sent by Party B to the site to deal with design problems. Article 10 Without the consent of Party B, Party A shall not modify the design data and documents delivered by Party B without authorization, nor transfer them to a third party or use them for projects other than this contract. In case of the above situation, Party B has the right to claim compensation from Party A. ..

Article 11

Party B shall not disclose or transfer the information and documents in this contract to a third party. In this case, Party A has the right to claim compensation from Party B. ..

Article 12 If Party A fails to pay the design fee according to Article 5 of this contract, and Party B has completed the design data according to Article 4 of this contract and submitted it to the planning department for examination and approval, Party A shall pay Party B a penalty of RMB 5,000, and have the right to require Party A to continue to perform the contract; If Party B has completed all the design materials agreed in Article 4 of this contract and passed the examination and approval of the planning department, but Party A has not paid the design fee, Party A shall pay Party B a penalty of 20% of the total design fee, and shall have the right to demand Party A to pay the balance of the design fee and the compensation specified in Article 6 of this contract.

Article 14 Party A agrees that Party B entrusts Bijie Branch of Sichuan Meicheng Architectural Planning and Design Co., Ltd. Guizhou Branch to perform this contract, complete the design work and post-service with the invoice issued by Bijie Branch and the design fee charged by the branch account.

Article 15 During the performance of the contract, if either party requests to terminate the contract, it shall obtain the consent of the other party, otherwise the contract shall not be terminated. Article 16 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties can only choose to bring a lawsuit to the People's Court of Zheng 'an County where the contract is signed.

Article 17 For matters not covered, both parties may sign a supplementary agreement, which is an integral part of this contract.

Article 20 If it is due to Party A's reasons (what reasons? If the completion time of design results conflicts, the delivery completion time of related design results will be postponed.

Article 21 After delivering the design data and documents, the designer shall participate in the relevant design review as required, and be responsible for making necessary adjustments and supplements to the contents not exceeding the original scope according to the review conclusion, and the review fee shall be drawn up by Party A (what other reviews will be conducted after the data is completed? )。

Article 22 This contract is made in sextuplicate, three for the Employer and three for the Contractor. The design fee paid by Party A to Party B in accordance with Article 4 of the Contract shall come into effect.

Employer:

Contractor:

Date:

Contract 4 for Simple Workshop Construction Unit: (hereinafter referred to as Party A)

Employer: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, Party A and Party B reach an agreement on relevant matters and conclude this contract. * * * Same as compliance.

I. Overview of the Project

Project Name: Enterprise Exhibition Hall of Henan Fengyuan Hepu Feed Co., Ltd.

Project location:

Second, the scope of project contracting

According to the needs of engineering construction, Party A entrusts Party B with full responsibility for the construction of Fengyuan enterprise exhibition hall, subject to the actual drawings. (including civil works, floors, embedded parts, steel structures, doors and windows, etc.). ). The engineering steel structure is given priority to, the wall is filled with hollow bricks, painted inside and outside, and the front glass curtain wall.

Three. Project contracting mode: Under the unified supervision and coordination of Party A's supervision, Party B shall contract for the work and materials, guarantee the quality, duration, safety, civilized construction and qualification (materials shall ensure that Party A can pass the quality acceptance), and shall not subcontract.

IV. Term of the contract:

Party B promises to complete the steel structure construction within calendar days from the date of signing this contract. The completion date is 20 15.

Verb (abbreviation of verb) quality standard

The quality requirement standard of this project is: qualified.

Therefore, Party A requires Party B to use standard materials for all building construction, and the whole project conforms to national building standards. And should be able to pass the acceptance of relevant quality inspection departments.

Contract price of intransitive verbs

The project includes materials, labor, production, transportation, installation, loading and unloading fees, invoices and various unforeseen expenses arising therefrom (if there is no major design change, the total price will not be adjusted; If there is any major design change, it can be adjusted through negotiation if it exceeds 5% of the total price).

The total fixed contract price of this project is RMB 10,000 Yuan only.

(1) Take the design drawings of this project as the annex of this contract.

(2) In case of major changes, both parties shall take signature as the settlement basis.

Seven. terms of payment

After the signing of this contract, RMB 10,000 Yuan (65,438+00% of the total cost) shall be paid in advance within one week after the completion of civil works.

Pay the project cost 10000 yuan (30% of the total cost) within one week after the steel column and steel beam enter the site. Pay RMB 10000 yuan (20% of the total cost) within one week after the wall painting is completed. Pay ten thousand yuan (20% of the total cost) within one week after the project is completed. Ten thousand yuan (65438+ 05% of the total cost) will be paid within one week after the project is accepted, and the remaining 5% will be used as the quality deposit, that is, ten thousand yuan, and the balance will be paid after one year when there is no quality problem.

Eight, Party B promises to carry out the construction in accordance with the contract, and undertake the project quality warranty responsibility during the quality warranty period. Within one year after the delivery of the project, Party B shall be responsible for the free maintenance of the quality problems of the steel structure project not caused by Party A; Within five years, Party B will maintain the waterproofing of the existing projects free of charge (except for force majeure factors). After the completion of the project, Party B is responsible for the lifelong paid maintenance and service of the project, and only charges fees, and is responsible for the decoration of Party A's project.

Nine. Party A promises to Party B to pay the fees according to the time limit and method agreed in this contract.

X party b promises to party a that it will fully perform the contents of this contract. If it cannot be completed on time, Party A shall be liable for breach of contract at a rate of 2‰ per day. If the quality fails to meet the requirements, Party A will be liable for breach of contract voluntarily according to the 50 yuan per square meter. Party B also promises that the payment of the above liquidated damages will not affect Party B's other compensation requirements for losses caused by project construction delays and quality problems.

1 1. Party A designates comrades to be in charge of this project, and Party B designates comrades as site construction leaders to coordinate and solve relevant problems in construction.

12. Implement the national regulations on production safety to ensure safe construction, and Party B shall be responsible for the work-related accidents during construction. Party B must purchase industrial accident insurance.

13. The right to interpret this contract belongs to Party A.. Matters not covered can be settled through negotiation. In case of any dispute, it can be settled through arbitration by the arbitration commission in the place where the contract is signed or brought to the people's court.

Thirteen. Entry into force of contract

Contract signing time:

Contract signing place:

This contract shall come into effect after being signed and sealed by both parties.

Employer (Party A): Contractor (Party B)

(official seal) (official seal)

Legal representative:

Authorized Agent: Authorized Agent:

Simple workshop contract 5 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

Through negotiation, Party A and Party B reach the following agreement:

1. Because Party A needs to build a factory building (steel frame house), it is contracted to Party B at a unit price of 80 yuan per square meter. The materials are composed of angle steel, round pipes and steel bars, all of which are provided by Party B. ..

2. Steel specification: Party A requires Party B to use No.6 round pipe with a thickness of 2.3 mm, 4×4 GB angle steel, 8 kg steel tile with a thickness of 0.326 mm each, and steel bars from 0.8 yuan.

3. When the steel is pulled to the construction site, Party A will pay 30% to Party B first, 30% when laying bricks, and the balance will be settled after acceptance.

4. Work quality and personal safety: If the steel specification and working attitude do not meet Party A's requirements, Party A may ask Party B to stop the construction and replace the construction personnel. If Party B has a safety accident, the responsibility shall be borne by Party B, and all consequences have nothing to do with Party A. The workshop shall be built according to Party A's requirements, and Party B shall be responsible for the quality assurance for three years after completion. In case of water leakage, factory collapse and other casualties, as well as mechanical damage that prevents Party A from producing, Party B shall bear all responsibilities and compensate. (Note: Except for natural and man-made disasters or heavy snow, Party B will not be responsible for the collapse of all steel sheds.

5. Except in special circumstances, Party B shall not ask for leave or stop work from the date of commencement, and settle accounts after Party A's acceptance.

6. This contract is made in duplicate and shall come into effect after being signed by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _