Engineering subcontract

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, following the principles of equality, voluntariness, openness, honesty and credit, and combining with the actual situation of this project, Party A and Party B have reached the following agreement on the owner's project construction through consultation:

I. Project name:

Second, the project site selection:

Three. Scope of contract:

Fourth, the construction period:? Start date: year month day.

Completion date: year month day? Duration: days

5. Contract price: this project is priced in () mode, with () yuan per ton.

The total contract price is

Six, quality requirements:

The quality of this project meets the standard. If it does not meet this standard, it shall be reworked according to Party A's requirements and bear all expenses arising therefrom.

Seven. Responsibilities of both parties:

1. Party A's responsibilities:

(1) is responsible for technical disclosure and quality inspection on the construction site.

(2) Be responsible for providing Party B with construction drawings in duplicate ().

(3) Timely supply of materials stipulated in the contract.

(4) Deal with the project settlement in time.

2. Party B's responsibilities:

(1) Construction shall be carried out in strict accordance with the requirements of construction specifications and national quality standards.

2 construction must be carried out according to the drawings.

(3) The time limit for a project shall be guaranteed, and the project shall be completed on schedule.

(4) Be responsible for providing Party A with the same invoice or receipt as the project settlement amount.

Eight, material supply:

1. Party A is responsible for providing the main materials.

2. The auxiliary materials are provided by Party A ().

Nine, material consumption:

The materials consumed in the project shall be subject to the actual occurrence, the loss shall be calculated according to (), and the waste shall be returned to ().

X. construction and acceptance:

1. Party B shall carry out the construction in strict accordance with the drawings and construction specifications, and accept the inspection and inspection of Party A's representatives and personnel appointed by relevant departments at any time.

2. After the completion of the project, organize relevant departments for acceptance.

XI。 Settlement method:

After signing the contract, Party A shall pay () yuan in advance to Party B, () yuan in the middle of the project and () yuan when the project is completed.

12. If the construction period is delayed due to Party A or Party B, the compensation party shall pay ()% of the total project price for each day of delay.

Thirteen. Others:

1. This Agreement is made in () copies, with () originals and () copies.

2. This agreement shall come into effect as of the date of signature by both parties.

3. This agreement will be automatically terminated upon completion.

Fourteen Supplementary terms:

Party A: Party B:

Entrusted by the legal representative or legal person; Entrusted by the legal representative or legal person;

Client: Construction Representative:

Tel: Tel:

Date:? Date:

Model Project Subcontract (2)

Employer: XX Industry and Trade Co., Ltd. (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In order to fix the economic relationship, clarify the responsibilities of both parties, and complete the construction task quickly, well and economically, Party A and Party B agree on this project. After friendly negotiation, both parties agree to sign the terms of this contract, and both parties will abide by it.

1. Contract basis: Party A and? (hereinafter referred to as the general contractor) signed "? 》。

2. Effective date of the contract: This contract shall come into effect after being signed and sealed by the legal representatives of both parties, and shall be implemented as of the date when Party A issues the commencement instruction.

3. Scope of contract:? The project under construction shall be subject to the construction drawings and written requirements provided by Party A's project department. Party A has the right to increase or decrease Party B's engineering quantity according to Party B's project progress and construction quality.

4. Contracting methods: labor, materials, small machinery, quality, safety, civilized construction, progress, construction period, material unloading and secondary handling.

5. Time limit: the commencement date shall be subject to the notice of Party A. The commencement and completion time of the system or unit project shall be subject to the commencement and completion time specified in the network table of Party A's construction progress. Projects completed ahead of schedule will not be rewarded; However, if the construction period is delayed due to Party B's reasons, it will be regarded as a breach of contract and compensation will be given. Party B shall not be exempted from the responsibility caused by the delay of the construction period on the grounds of force majeure such as weather. If the construction period is delayed due to the reasons of the general contractor or Party A, the construction period will be postponed after negotiation between Party A and Party B. ..

6. Project price: settlement price? . Construction water and electricity charges are deducted according to the electricity charges contained in the fixed machinery. The engineering quantity shall be subject to the actual engineering quantity completed by Party B (approved by Party A), and the engineering quantity shall be signed and confirmed by the project manager authorized by Party A. If the project manager is changed, the subsequent project manager must sign the confirmation form.

Price content: The price includes labor cost, material cost, small and medium-sized construction machinery cost except vertical and horizontal transportation, nondestructive testing and heat treatment machinery, management fee, construction organization transfer fee, profit, policy adjustment, various insurances, various taxes and fees, medical expenses, temporary facilities of Party B, risks of Party B, site factors and other related expenses.

7. Settlement method and payment method:

7. 1 settlement method: there is no advance payment for this project. On 25th of each month, Party B will submit the monthly workload report together with the settlement acceptance certificate to the planning department of Party A's project department, and the finance department of Party A's project department will pay 70% of this month's project payment within one month. Due to the delay of Party B's report or total monthly progress payment, Party A's payment will be delayed accordingly. If the general contractor delays the project completion settlement of Party A or Party A has completed the project completion settlement, and the general contractor fails to pay off the project payment, Party A's payment to Party B will be delayed accordingly. After the project is completed and accepted, the Planning Department of Party A's Project Department will submit all settlement materials to the business department of Party A's headquarters for review. After review, 20% of the project price will be paid, and the remaining 65,438+00% will be reserved as a quality deposit (the deposit does not include interest), which will be paid after the project warranty period expires.

7.2 Tax: The construction business tax is calculated from the project price and withheld and remitted by Party A according to the national regulations. ...

8. On-site security: Party A is responsible for the security of public facilities, and Party B is responsible for the security within its construction scope.

9. Supply of materials and machinery:

9. 1 The materials used in the project shall be supplied by Party A, and Party B shall submit the material use plan seven days in advance according to the construction drawing and relevant quota before the construction starts, and after it is approved by Party A, it shall be collected from Party A's on-site warehouse to the construction site. If the amount exceeds the approved amount, Party A has the right to deduct the excess material cost from Party B's project settlement price according to the market price. If the circumstances are serious, Party A has the right to terminate the contract and Party B has no right to compensation.

9.2 Party B shall take good care of the materials that have been taken out, and shall not get wet, throw them around, take them out of the factory without permission, waste them or give them away at will. Once found, Party A has the right to deduct the corresponding material costs from Party B's project settlement price. If the circumstances are serious, Party A has the right to terminate the contract and Party B has no right to receive compensation.

9.3 The materials used in the project shall be supplied by Party B, and the quality of the materials shall meet the requirements of the project, with inspection certificates. Before purchasing, Party A shall approve the installation before purchasing; otherwise, Party B shall bear all the expenses of rework and equipment dismantling, as well as the losses claimed by the general contractor due to the delay in construction period.

9.4 Party A shall provide Party B with vertical and horizontal transportation machinery, nondestructive testing and heat treatment machinery and other small and medium-sized construction machinery and tools contracted by Party B after calculation according to the drawings and Budget Quota for Electric Power Construction Projects (2002 edition).

10 responsibilities of party a:

10. 1 Responsible for preparing the project schedule according to the requirements of the general contractor and handling the relevant negotiations with the general contractor.

10.2 is responsible for construction technical disclosure, quality acceptance and site construction scheduling.

10.3 is responsible for providing Party B with construction design drawings and technical data of relevant equipment. Without Party A's permission, Party B shall not lend the materials provided by Party A to a third party without authorization.

10.4 is responsible for providing Party B with construction water and power supply points. The construction water and electricity charges shall be borne by Party B, and finally the water and electricity charges shall be deducted according to the quota content and unit price.

10.5 is responsible for solving Party B's construction site.

10.6 is responsible for the disbursement of project funds.

10.7 is responsible for the coordination between installation and civil engineering.

1 1 Party B's responsibilities:

1 1. 1 Organize engineering and technical personnel, quality inspectors, safety personnel and construction personnel according to the contract and Party A's requirements. ..

1 1.2 Complete the construction tasks in strict accordance with the construction progress requirements compiled by Party A. ..

1 1.3 carry out civilized construction in strict accordance with the standards stipulated in the contract, changes in the design of construction drawings and Party A's requirements, so as to ensure that the site is cleared after the work.

1 1.4 Be responsible for the personal insurance of the construction personnel during the construction period and bear relevant expenses.

1 1.5 is responsible for paying all taxes except construction business tax.

1 1.6 Submit all kinds of technical data required by Party A to Party A in time.

1 1.7 is subject to Party A's schedule.

1 1.8 If Party A fails to pay the project payment within two months, Party B shall guarantee to continue the construction.

1 1.9 organize, arrange and distribute the clothes, labor protection articles, safety facilities and construction tools of construction personnel according to the requirements of party a. ..

1 1. 10 shall bear the medical expenses of its own personnel.

11.11Responsible for the transfer of construction personnel and tools.

1 1. 12 shall be responsible for the construction of temporary facilities and the demolition after completion, and bear the expenses.

1 1. 13 shall bear the responsibilities and expenses for causing pollution to third parties.

12. project quality, acceptance and safety:

12. 1 Project execution quality standards and specifications: relevant standards/specifications currently in power industry or agreed between Party A and the general contractor. The standards and specifications for project quality and handover acceptance must be implemented in strict accordance with the relevant provisions of the Regulations on Quality Management of Construction Projects and the requirements of the contract (including attachments) and design drawings and documents signed by Party A and the general contractor. If there is any contradiction between the design drawings and the contract signed by Party A and the general contractor, the contract signed by Party A and the general contractor shall prevail. When acceptance is not stipulated in the contract signed between Party A and the general contractor, the standards stipulated by the general contractor/engineer and Party A shall be implemented.

12.2 During the construction period, Party B shall accept the guidance and quality inspection and supervision of the general contractor/engineer, the representative of Party A, the design institute and the representatives of relevant engineering schemes and equipment installation. If defects are found, Party B shall repair them in time until they are qualified.

12.3 concealed works: before concealed works are concealed, Party B shall notify Party A and the general contractor/engineer in writing 24 hours in advance to go to the site for inspection, that is, go through the concealment acceptance procedures, and the next working procedure can be started only after qualified signature.

12.4 if any project that does not meet the quality requirements is found in the construction process and acceptance, the responsibility shall be clearly defined. () For quality problems caused by Party B, Party A has the right to require Party B to rework, and all rework losses and other expenses arising therefrom shall be borne by Party B. ..

12.5 Construction safety: Party B must accept the safety supervision and management of Party A. Before Party B's construction personnel enter the site, they must carry out safety education and physical examination. Party B shall prepare safety technical measures according to the construction projects undertaken, and Party B must provide the construction personnel with occupational protective articles and appliances that meet the national regulations according to regulations. Party B shall take out accidental injury insurance for personnel engaged in dangerous operations on the construction site according to relevant national regulations. In the process of construction, Party B must strictly implement the Regulations on Safety, Health and Environment Management of Electric Power Construction, Safety Work Regulations of Electric Power Construction and all documents and regulations of the general contractor and the project department on safe and civilized construction, so as to achieve safe and civilized construction. During the construction period, all personal injury or death accidents caused by Party B's personnel or mechanical equipment damage accidents caused by Party B's responsibility and losses, responsibilities and expenses caused to third parties shall be borne by Party B. Before the construction, Party A shall sign a safety production management agreement (Annex II).

12.6 quality warranty period: during the warranty period, Party B shall undertake the quality warranty responsibility for the project quality delivered to Party A in accordance with laws, administrative regulations or national regulations on project quality warranty, and both parties shall sign the Project Quality Warranty (Annex 1).

12.7 quality deposit return: when the quality deposit expires and there is no construction quality problem of Party B, it will be paid in one lump sum; If losses are caused by Party B's construction quality, Party A shall deduct the actual losses; If the quality deposit is insufficient to repay the losses caused by Party B's construction quality, Party A reserves the right to claim further compensation.

12.8 technical and quality requirements: The specific technology and quality shall be subject to the construction drawings and written requirements provided by Party A's project department.

13. Risks undertaken by Party A

Information related to this project in Party A's project:

13. 1 War, hostile acts (whether declared war or not), invasion, acts of foreign enemies;

13.2 ionizing radiation, radioactive pollution caused by the explosion of any nuclear fuel or nuclear combustion waste or toxic radioactive substances or nuclear raw materials and nuclear components.

13.3 Shock wave pressure generated by aircraft and objects flying at sonic or supersonic speed.

13.4 riots or riots and disorder of order, unless these situations are limited to the employees of Party B and Party A or caused by the construction of the project.

14. Risks undertaken by Party B.

Party B's risks refer to all risks listed in Article 13 except those undertaken by Party A..

15. Very good:

15. 1 If Party B fails to complete the single project construction task within the time required by Party A, Party B shall bear the penalty of 2% of the single settlement price.

15.2 If Party A suffers losses due to Party B's construction mistakes, Party B shall bear the losses.

16. Site management:

16. 1 Party B shall attend the planning and dispatching meeting convened by Party A as required by Party A, and report the construction progress, project quality, cooperation requirements of all parties, existing problems and solutions on time.

16.2 Where Party B's various personnel involved in the project are irresponsible for their personal work, causing influence or loss, failing to cooperate with other units, buck-passing, making things difficult, and disobeying Party A's commanding personnel, Party A has the right to request replacement, and Party B shall actively cooperate.

16.3 All design changes agreed by the general contractor or Party A must be implemented by Party B. ..

16.4 after the completion of the project, Party B shall be responsible for cleaning up the site and ensuring the cleanliness of the work site.

16.5 both parties must do a good job in public security, fire prevention, theft prevention and health care within their respective scope on site to prevent casualties and equipment accidents.

17. Termination during contract execution:

17. 1 Party A has the absolute right to notify Party B in writing to terminate the contract for the following reasons.

17. 1. 1 Termination before commencement: When the general contractor terminates the contract with Party A before the commencement instruction is issued, Party A will terminate the contract with Party B. ..

17. 1.2' Termination after the notice of commencement: When the general contractor terminates the contract with Party A after the notice of commencement is issued, Party A will terminate the contract with Party B, and Party B has the right to accept the compensation equivalent to the following amount without further recourse.

17.2 when party a terminates this contract or some of its projects, party b shall immediately suspend all or part of its work related to this contract.

17.3 The contract is terminated due to Party B's breach of contract:

17.3. 1 According to the correct notice issued by Party A, the following situations are breach of contract:

(1) Party B refuses or fails to perform important parts of the project on time;

(2) Party B refuses or fails to provide enough skilled workers or fails to finish the work on time within the time limit required by Party A. ..

(3) Party B ignores or intentionally violates the laws or decrees of any public department with jurisdiction.

(4) Other acts of Party B's material breach of this contract.

17.3.2 whenever this contract is terminated due to Party B's breach of contract, Party B will not get more compensation before the project is completed and accepted, and Party B has no right to get more payment.

17.3.3 the termination of the contract due to party b's breach of contract does not affect party b's liability for breach of contract to party a. ..

Party A has the right to terminate this contract according to its actual situation. Party B understands this and agrees not to claim compensation from Party A. ..

19. Invalidation of the Contract: After the financial transactions between Party A and Party B are settled, the Contract will automatically become invalid.

Matters not covered in this contract shall be settled by both parties through consultation.

Dispute settlement: during the execution of the contract, if there is a dispute between the two parties, it can be settled through consultation. If negotiation fails, it shall be under the jurisdiction of the people's court of the place where the contract is signed. Signing place: Pingdingshan Hualong Industry and Trade Co., Ltd. or Zhanhe District, Pingdingshan City.

This contract is made in triplicate, 2 for Party A and 0 for Party B/KLOC. ..

Party A: XX Industry and Trade Co., Ltd. (seal) Party B:? (Seal)

Legal representative:

Or entrust an agent; Or entrusted agent:

Year? Month? What year and day? Month? sun

Model Project Subcontract (3)

Both parties to the agreement

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, fairness, justice and good faith, all the indoor plastering works of Building 98 in Jinhua West District of Shengli Oilfield were contracted out to Party B for construction. In order to speed up the construction progress, ensure the engineering quality and the safety of construction personnel, and clarify the responsibilities of both parties, the following agreement is reached through consultation.

First, the work content:

All indoor plastering works of building 98# in the first phase of Jinhua West Zone include: sand screening, mixing, wall watering before painting, installation of anti-crack net for wall joints, finished product maintenance and floor cleaning (except tower crane and mixer, all required gadgets are self-care).

Second, the responsibilities of both parties.

Before construction, Party A is responsible for providing technical disclosure and floor plan of each floor and household. After Party B signs and approves, it will control the room size of each household according to this drawing. Complete the project on time with good quality and quantity.

Third, the time limit for a project:

The construction period is calculated from the date of painting, and all the workload must be in? It was all over in a few days. If it is not completed, our project department will impose a fine of RMB Wu Bai Yuan for each day of delay. A delay of one week will result in a fine of 5000 yuan per day.

Fourth, the quality requirements:

Party B must ensure that the painted wall meets the requirements of Code for Construction Quality of Building Engineering and Code for Quality Acceptance of Building Construction Engineering; There shall be no cracks, empty shells, sand and small bays on the wall. During the construction process, Party A will conduct door-to-door acceptance of finished products, and rework unqualified products in time.

Five, the project household acceptance:

During the construction period, Party A shall follow up and check every day, and deal with any problems found in time to avoid material waste. When the project is handed over to households for acceptance, Party A and Party B shall organize the supervision unit, construction unit, quality supervision station and households to conduct household acceptance, and the acceptance must be fully guaranteed; If there is a quality problem that the tenant does not accept, Party B must solve it with the tenant within a time limit (no more than ten days): Does it involve rework? Party B must unconditionally rework until the tenants are qualified.

Six, civilized construction:

Party B's personnel must be strictly managed when entering the site, and there shall be no acts that damage Party A's image, such as fighting, stealing, making trouble after drinking, and disobeying the correct arrangement of Party A's management personnel. Everyone who fights will be fined 500- 1000 yuan, and those who steal will be compensated and dismissed according to their value 10 times. Party B is responsible for the sanitation and facilities of the living quarters.

All kinds of plastering materials should be cherished. It is forbidden to waste materials. For the materials wasted in the project, Party A has the right to deduct twice the material price from Party B's project payment. During the construction period, Party B must keep the materials clean and the machinery and hopper clean. After painting, there shall be no garbage on the construction site and on the ground. No defecation anywhere. Offenders found fined 200 yuan.

Seven, safety responsibility:

When entering the construction site, you must wear the safety helmet correctly, and the offender will be fined 50 yuan; It is forbidden to wear slippers and high heels, and offenders will be fined 50 yuan; It is forbidden to go to work after drinking, and offenders will be fined 100 yuan and expelled from the construction site; Non-working personnel are prohibited from operating machinery and connecting the power supply without permission, and firmly establish a good safety awareness to prevent safety accidents. If a safety accident occurs during the construction, all economic compensation and joint and several economic responsibilities have nothing to do with Party A. ..

Eight. Price and payment method:

The project is settled in 7 yuan according to the actual plastering finished product area per square meter. During the construction period, part of the living expenses will be paid according to 30% of the actual engineering quantity. After the construction is completed on time, 80% of the total engineering quantity will be paid after the initial inspection by the housing enterprise, supervision company and project department, and the balance will be settled one month after the project is completed and accepted by households.

In the course of construction, if Party B disobeys Party A's management or the quality is not up to standard, which causes workers to make trouble intentionally, stop work halfway or leave the site (plastering is not completed), Party A has the right to refuse to pay the remaining project funds, and all wages related to migrant workers will be settled by Party B itself, which has nothing to do with Party A. In addition, Party A will not bear any responsibility for emergencies that affect Party B's construction.

Nine. Implement:

This agreement shall come into effect as of the date of signature and seal by both parties, and shall be automatically terminated after the project is completed and the project payment is completed. It is hoped that both parties will jointly fulfill their responsibilities, otherwise the breaching party will bear the corresponding liquidated damages. In case of any dispute, it shall be settled through consultation on the principle of mutual understanding and accommodation. If negotiation fails, a lawsuit can be brought to Dongying People's Court.

This contract is made in quadruplicate, one for Party A and Party B, one for Engineering Department and one for Finance Department.

It will take effect after being signed and sealed.

Party A (signature):

Party B (signature):

Year? Month? sun