Traditional Culture Encyclopedia - Weather inquiry - Paving construction contract
Paving construction contract
Pavement Construction Contract 1 Entrusting Party (Party A): _ _ _ _ _ _ _
Organizer (Party B): _ _ _ _ _ _
Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project: _ _ _ _ _ _ _ _ _ _ _ _ _
Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.
Article 1: Project Overview
1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Total days of the project: _ _ _ _ _ _
Article 2: Project Price
Project Price (amount in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 3: Warranty Period
The warranty period is _ _ months from the date of project completion and acceptance by Party A. ..
Article 4: Liability for breach of contract
1. After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
2. During the warranty period, Party B shall guarantee to provide on-site service within 24 hours after Party A notifies the maintenance by telephone or in writing. In case of breach of contract, Party B shall pay a penalty of 5% of the total contract amount.
Article 5: Settlement of disputes
1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress.
2. If both parties are unwilling to solve the problem through negotiation or mediation, or negotiation or mediation fails, they can bring a lawsuit to Wuchang District People's Court according to this contract.
Article 6: Entry into force of the contract
1. This contract shall come into effect after being sealed by both parties.
2. Party A and Party B each hold one copy of this contract.
Party A (owner): _ _ _ _ _ (signature) Party B: _ _ _ _ _ _ (signature)
Domicile address: _ _ _ _ _ _ Business address: _ _ _ _ _ _ _ _
Postal Code: _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
& gt Regular Renovation Contract 5
Employer (Party A):
Contractor (Party B): _ _ Waterproof Decoration Engineering Co., Ltd.
In accordance with the provisions of the Economic Contract Law of the People's Republic of China and the Regulations on Contracts for Construction and Installation Projects, and in combination with the specific conditions of this project, both parties have reached the following agreement.
Article 1 General situation of the project
1. 1 project name: waterproof and plugging maintenance project
1.2 project site:
1.3 scope of contract: toilet
1.4 contract mode: contract work, contract materials, contract quality, contract management, contract safety and other general modes.
1.5 time limit for a project: the project started on, and was completed on.
1.6 project quality: Party B shall ensure that Party A's bathroom waterproofing works reach excellent standards, and carry out the construction in strict accordance with the new standards of Hainan waterproofing works and Party A's requirements. The coating project shall ensure no peeling, hollowing, delamination, dew point and flatness, and have certain adhesion with the base to meet the design thickness and other quality requirements.
1.7 project cost: the toilet is waterproof at RMB per square meter, and the settlement shall be made according to the actual area.
Article 2 Work of Party A
2. 1 Put forward the construction plan in advance, arrange the working face to meet the waterproof construction standard, and submit it to Party B for construction.
2.2 The construction period plan should be put forward, but the inevitable factors such as weather and manpower should be considered, and the construction period should be postponed.
2.3 Party A has the right to supervise and inspect the quality of Party B's project during the construction process, and if problems are found, Party A has the right to require Party B to rectify.
Article 3 Party B's Work
3. 1 Participate in the on-site disclosure of construction quantities and directions or practices organized by Party A, draw up the construction plan and schedule, and submit it to Party A for approval.
3.2 Party B is appointed as the on-site representative of Party B to be responsible for the performance of the contract. Organize the construction according to the requirements, ensure the quality and quantity, complete the construction tasks on schedule, and solve all matters that Party B is responsible for.
3.3 Strictly implement the construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations. Participate in the completion acceptance and prepare the project settlement.
3.4 Before the completion of the project is handed over to Party A, be responsible for protecting all facilities and finished products at the site.
3.5 Construction shall be carried out in strict accordance with waterproof engineering standards. When problems are found, solve them in time to ensure the quality of the project to reach excellent standards, and the project is guaranteed for five years. In case of leakage within five years, Party B shall be responsible for all losses. (including the losses caused to the downstairs)
Article 4 This contract is made in duplicate, each party holds one copy, which has the same legal effect. When the five-year warranty expires, the contract will automatically become invalid. Matters not covered in this contract shall be settled by both parties through consultation.
Party A (seal): Party B (seal):
Representative: representative:
Company address: Company address:
Tel: Tel:
Year, month, sun, moon, sun.
Paving Construction Contract 2 Party A:
Party B:
Party A has contracted _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ to Party B for the construction. In order to clarify the responsibilities of both parties and ensure the smooth progress of the construction, this contract is signed by both parties through full consultation, and both parties shall abide by it.
Article 1 Project name:
Article 2 Project Location:
Article 3 Contents of the Project:
Article 4 Project Cost and Settlement Method
1. The flat coating area of this project is _ _ _ _ m2, and the unit price is _ _ _ _ yuan /m2 (this unit price does not include tax and cooperation fee).
2. The total project cost is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5 Term of Contract
Party B must arrange workers to enter the site for construction within _ _ _ _ _ days after Party A sends the notice of entry, and the effective construction period is _ _ _ _ _.
In the process of construction, in case of any of the following circumstances, the construction period will be postponed:
1. Encountered an irresistible disaster or accident.
2. Party A requests to change the design drawings, project contents or add projects.
Article 6 Payment of project funds
Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ USD _ _ _ _ _ _ The project of Party B is divided into four quantities (first pass putty powder, second pass putty powder, first pass wall paint and second pass wall paint), and Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 7 Scope of Responsibility of Party A and Party B
I. Responsibility of Party A
1. Party A shall provide water, electricity and workers' accommodation, and the expenses shall be borne by Party A..
2. Pay the progress payment to Party B according to Article 6.
3, responsible for providing construction related information.
4. Party A appoints _ _ _ _ _ _ _ _ _ as the site representative to assist Party B to solve the problems that Party A should be responsible for, negotiate with Party B to solve the problems arising in the construction, and handle the site visa of the project progress delivered by Party B in time. ..
5. Responsible for organizing the completion acceptance of the project.
II. Responsibility of Party B
1. Carry out the construction in strict accordance with the construction drawings and instructions determined by Party A, ensure the quality and complete the delivery on time.
2. Party B shall appoint _ _ _ _ as the on-site representative to exercise Party B's rights and obligations.
3. Personnel entering Party B's site shall be managed by special personnel and subject to the unified management of Party A. ..
4, do a good job in civilized construction, to do a good job of site cleaning.
Article 8 Liability for breach of contract and dispute settlement methods
1. Party B shall carry out the construction according to the quality standards stipulated in the contract. In case of construction quality problems caused by Party B's responsibility, Party B must rework, and all expenses arising therefrom shall be borne by Party B. ..
2. In case of any dispute during the performance of this contract, both parties shall settle it through consultation; If no agreement can be reached, it shall be submitted to the relevant arbitration institution or submitted to the court for settlement.
Article 9 Other matters
1. For matters not covered in this contract, both parties shall sign a supplementary agreement separately, and the supplementary agreement shall have the same legal effect.
2. This contract is made in triplicate, one for Party A and two for Party B.. It will take effect after being signed and sealed by both parties, and will automatically become invalid after the project price is fully settled.
3. Place of signing the contract:
Party A: Party B:
Representative of Party A: Representative of Party B:
Tel: Tel:
Address: Address:
_ _ _ _ _ _ _ _ _ _ _
Pavement Construction Contract 3 _ _ _ _ _ _ _ _ Co., Ltd. (hereinafter referred to as Party A)
_ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
In order to unify and enhance the image of the store and products, and create a better sales environment for Party B, both parties have reached the following contract through consultation based on the principles of voluntariness, equality and mutual benefit:
From the date of signing this contract, Party A shall be responsible for providing Party B with the overall design and decoration of the store. Decoration contents include:
Design, manufacture and installation of doorplates;
Design, manufacture and installation of product image wall;
Design, manufacture and installation of product display racks;
The formula and painting of the main color in the shop;
Design, manufacture and install hanging flags on the roofs of shops;
Party A shall provide Party B with a set of models, four sets of work clothes and various certificates and product descriptions free of charge.
Party B shall pay Party A a renovation deposit of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Within one year from the date of signing the contract, Party B shall not concurrently engage in other brands or products that conflict with Party A, otherwise, Party B's decoration deposit will be deducted.
After a year of cooperation between Party A and Party B, Party B can maintain Party A's product image well and there is no breach of contract. Party A will refund Party B the decoration deposit in full (the refund will be cashed on the floor).
This contract is signed in the form of _ _ _ _ _ _ _ _ _ _
The modification of this contract shall be settled by both parties through consultation.
This contract shall come into effect as of the date when both parties affix their seals, and shall be terminated on _ _ _ _ _ _.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
Person in charge: _ _ _ _ _ Person in charge: _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Paving Construction Contract 4 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ _ _ _ _
Based on the principle of equality and mutual benefit, Party A and Party B, through friendly negotiation, have reached the following unanimous agreement terms on Party A's _ _ _ _ _ store/exhibition hall construction project (hereinafter referred to as "the project"):
First, the term of the contract
Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The construction period of this project starts from the effective date of the signature and seal of this contract and ends at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Second, the total project contract cost, payment schedule and methods
2. 1 The total budgeted cost of this project is RMB Yuan only. In the process of decoration implementation, if there is any increase or decrease in the project, the final settlement shall be based on the actual amount.
2.2 Within _ _ _ _ _ days after the signing of this contract, Party A shall pay _ _ _% of the total budgeted cost of this project to Party B, that is, RMB _ _ _ _ _ (that is, RMB _ _ _ _ _). ..
2.3 After Party B completes the production of the booth and arrives at the construction site, Party A shall pay Party B _ _ _% of the total budget cost of this project, that is, RMB Yuan only (that is, RMB Yuan only) after passing the acceptance.
2.4 Within _ _ _ _ _ days after Party A completes the project acceptance, Party B shall be paid _ _ _% of the total budgeted cost of this project, namely RMB _ _ _ _ _ (namely RMB _ _ _ _ _).
2.5 Party B shall issue receipts to Party A in installments according to the actual amount of money collected in the previous period. After Party A has paid all the money, Party B shall issue a full invoice to Party A. ..
Bank of deposit: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Account number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Company name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Three. Party A's responsibilities
3. 1 Party A shall provide corporate image manuals or corporate publicity texts, pictures and other contents. In order to facilitate production, materials must be provided within one week from the effective date of this contract. If there is any ambiguity between the pictures and texts, Party A shall arrange corresponding personnel to answer for Party B in time.
3.2 Party A shall review the design and construction drawings (Annex 2 to this contract) issued by Party B and sign them for approval. After the design and construction drawings are confirmed, Party B shall provide Party A with samples of main materials for verification, and carry out the construction according to the design and construction drawings signed and confirmed by Party A. ..
3.3 Party A shall arrange special representatives to take charge of this project, attend meetings at any time and coordinate related work. Party A shall provide relevant materials, and Party B shall handle construction permits and other related matters.
3.4 If Party A temporarily requests to change the original design scheme, change the construction content or increase the project, it shall raise a written objection to Party B five days before the project construction, and the specific matters shall be settled by both parties through consultation, and the increase or decrease of the engineering quantity shall be subject to the written consent of both parties, otherwise, Party B has the right not to change Party A's requirements for on-site changes during the on-site construction.
3.5 Party A shall pay the corresponding project progress payment according to the contract, and Party A shall be responsible for the consequences caused by the delayed payment of project funds.
3.6 Party A is responsible for the water and electricity management fees and construction procedures of the exhibition hall site project.
Four. Party B's responsibilities
4. 1 Party B is responsible for the design and construction of the exhibition hall. According to the booth design renderings confirmed by Party A, Party B will issue detailed design and construction drawings (Annex 2) to Party A for verification and confirmation, which will be an annex to this contract.
4.2 Party B shall designate the person in charge of the project, organize relevant meetings and coordinate relevant work at any time.
4.3 During the construction period, Party B shall strictly abide by the rules and regulations formulated by Party A at the site and the operation specifications stipulated by the industry, especially to ensure safe operation. If Party A's property is damaged or Party B's personnel are killed or injured due to illegal operation, Party B shall bear all responsibilities.
4.4 Party B shall be responsible for the storage of materials and equipment at the construction site, fire prevention and cleaning at the site, and cleaning up the construction site.
4.5 After the project is delivered for use, Party B shall be responsible for the maintenance within the warranty period.
4.6 All materials designed and used by Party B meet the requirements of relevant national environmental protection standards and specifications, and materials with excessive toxic and harmful substances shall not be used.
Verb (abbreviation of verb) mode of production
5. 1 Party B is responsible for the design scheme, construction and packaging in Shenzhen factory in the form of exclusive store assembly.
5.2 Party B shall be responsible for delivering the manufactured exhibition tools to the designated place with good quality and quantity.
5.3 Party B shall be responsible for sending special personnel to complete the on-site installation and acceptance.
Acceptance of intransitive verbs
6. 1 Party A takes the requirements of design renderings confirmed by both parties, various data requirements agreed by both parties, quotation of this project (see Annex 1 for details), construction renderings (see Annex 2 for details) and design changes as the basis for project acceptance.
6.2 After the renovation project is completed, the project quality and environmental protection requirements shall meet the relevant national standards.
6.3 In case of engineering quality problems caused by Party A, the cost of rework shall be borne by Party A, and the construction period shall be postponed.
6.4 For quality accidents caused by Party B, the expenses and responsibilities for rework shall be borne by Party B, and the construction period shall remain unchanged.
6.5 After all the projects are completed, Party B shall notify Party A in writing for completion acceptance, and Party A shall organize acceptance within _ _ _ _ days after receiving the completion acceptance notice. After the acceptance, both parties shall go through the handover procedures, sign the warranty, and hand over the relevant construction and transformation drawings. If Party A uses it without acceptance, it shall be deemed as qualified.
Seven. responsibility for breach of contract
7. 1 If the construction cannot be carried out according to the construction schedule agreed in the contract due to Party B's reasons, the liquidated damages shall be calculated at _ _ _ _ _ _ of the contract price for each day of delay.
7.2 If Party A fails to pay the project payment according to Articles 2.2 and 2.3 of this contract, the liquidated damages shall be calculated at _ _ _ _ _ _ _ of the total contract price for each day overdue, and Party B has the right to suspend the construction. If Party A delays the payment of the first progress payment for _ _ _ _ days, Party B has the right to terminate the contract unilaterally.
Eight. Project warranty
8. 1 The warranty period is _ _ _ _ _ years, counting from the date when the project is completed and accepted.
8.2 In case of quality problems caused by Party B, Party B shall repair them unconditionally.
8.3 Damage or abnormal use caused by Party A's improper use is not covered by the warranty.
8.4 Party A shall be responsible for the quality warranty of the installation sub-projects purchased and arranged by itself.
Nine. any other business
9. 1 According to the needs of the project, both parties can hold a meeting at any time.
9.2 If Party A requests to add or change a larger project from the date when the contract of this project comes into effect with the signatures and seals of both parties, the following principles must be observed:
9.2. 1 After negotiation by both parties, Party A shall issue a "Design Change Notice" in written form.
9.2.2 After Party B submits the revised design and construction drawing, Party A shall sign and seal it for approval.
9.2.3 Additional expenses arising from adding or changing larger projects shall be negotiated by both parties and implemented according to the supplementary agreement.
9.3 This project has not been accepted and confirmed by both parties, but Party A uses the samples in advance without authorization, and Party A shall be responsible for the quality and quantity problems arising therefrom.
9.4 Any dispute arising from this contract shall be settled by both parties through friendly negotiation. If negotiation fails, the case shall be submitted to Shenzhen Arbitration Commission for arbitration.
9.5 The project quotation sheet, design and construction drawings and exhibition hall design renderings, as annexes to this contract, have the same legal effect as this contract.
9.6 If either party breaches the contract due to its own reasons, it shall bear all losses caused to the other party.
9.7 Matters not covered in this contract shall be settled by both parties through friendly negotiation, and the supplementary agreement has the same legal effect as this contract.
9.8 This Contract is concluded on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
9.9 Additional items shall be charged separately.
Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Representative: _ _ _ _ _ _ _ _ _ _ _ Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date: _ _ _ _ _ _ Date: _ _ _ _ _ _ _
5. Party A's (Employer's) pavement construction contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (contractor): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A entrusts Party B to decorate Party A's store located in _ _ _ _ _ _ _ _.
I. Decoration location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Decoration content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Three. Decoration area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four. Decoration period: from _ _ _ _ _ _ _ _
Verb (abbreviation of verb) decoration price: The total price of storefront decoration is RMB _ _ _ _ _ _. The total price includes design fees, material fees, labor costs, construction customs clearance fees, handling fees, taxes and other expenses.
Payment by intransitive verbs: After the agreement is signed, Party A shall pay _ _ _ _ _ _ _ _ _% of the total price of Party B; Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Seven, decoration regulations
1. Party A has the right to review the store decoration plan proposed by Party B, and Party B can only carry out the decoration after obtaining the written consent of Party A. ..
2. Party B's decoration plan must specify the location, scope, content and other detailed information.
3. All expenses such as water, electricity and garbage removal during the renovation period shall be borne by Party B. ..
4. If Party B causes damage to the store and other people's facilities and equipment during the renovation, Party B shall take full responsibility and bear all maintenance costs.
5. All decoration and renovation works of Party B must be completed within the time limit specified by Party A, otherwise, the liquidated damages will be _ _ _ _ _ _ _ _ _ _ _.
6. If Party B needs to rebuild the store (including installing fixtures in the site), it shall obtain the written consent of Party A in advance. Without written consent, Party B shall be responsible for restoring the original state and compensate for the losses caused to the Commodity House.
7. If Party B needs to transform the store's power system or increase lighting facilities, it must report to the corresponding management office for review, and after a written reply, it will carry out the construction in strict accordance with the _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. In case of unauthorized construction, Party B will be fined 1 1,000 yuan; If there are any unauthorized changes, Party B shall restore the original state and bear all expenses and losses caused thereby.
8. Party B's renovation of the store shall not adversely affect the safety of the main structure of the building, the use safety of pipelines such as fire fighting, circuits and air conditioning, and the overall beauty, and shall not affect the operation of Party A or a third party. Otherwise, Party B shall immediately correct it and compensate the losses caused to Party A and the third party.
9. The garbage and waste generated by Party B's decoration must be cleaned up in time, so as not to affect the overall beauty of the store, otherwise a fine of 200-500 yuan will be imposed.
10. Party B shall not drill holes in the walls and floors of the store, or directly install decorations or metal pendants on the walls. In case of violation, a fine of 200-500 yuan will be imposed.
1 1. The materials used in Party B's decoration project must meet the national requirements for fire prevention and environmental protection.
Eight, decoration acceptance
1. After the renovation of the store is completed, Party A makes a preliminary acceptance of the materials, construction quality and overall image used in the renovation of the store, and all losses caused by non-compliance with the contract requirements or fraud shall be borne by Party B..
2. The store will be put into use after Party A has passed the preliminary acceptance. If there is any problem within three months after the initial acceptance, Party B will repair it unconditionally, and the expenses shall be borne by Party B. If Party A suffers losses due to Party B's reasons, Party B shall bear all the responsibilities.
Nine. others
1. During the renovation, Party A shall actively cooperate with Party B and provide water and electricity for renovation. Due to the influence of water and electricity problems on the construction date, Party B will not bear any losses.
2. Party B shall be responsible for the safety of personnel during the renovation, and assume all responsibilities.
3. This agreement shall come into effect as of the date of signature and seal by both parties. This document is made in duplicate, one for each party, with the same legal effect.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
- Previous article:What should drivers pay attention to when the weather is hot in summer?
- Next article:Why is Sichuan so humid?
- Related articles
- Help New Zealand South Island weather conditions in early June 10.
- What to wear to travel to Yunnan in January?
- Sentences describing the rapid change of clouds
- Composition for the first grade of primary school 100 words: washing toys.
- How to get from Beijing to Yanji?
- Detailed introduction of one-day tour in Shidu, Beijing
- Franklin's life and all his inventions.
- What a dry weather!
- Senior copywriter about Tomb-Sweeping Day.
- What medicine should I take if I am out of breath in old age?