All-inclusive house renovation contract

Renovation contract model of all-inclusive residence (8 general rules)

In a society where people pay more and more attention to the law, contracts appear more and more times, and signing contracts is also one of the best ways to avoid disputes. There are different types of contracts, and of course, they also have different purposes. The following is a sample of all-inclusive housing in renovation contract (generally 8 articles), which I have carefully compiled. I hope it will help you.

Renovation contract 1 All Private Rooms Employer (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

According to the Economic Contract Law of the People's Republic of China and other relevant laws and regulations, Party A and Party B have reached the following agreement on the renovation project on the basis of equality, voluntariness and consensus:

1. Project location:No. X, X Community, X Town, X County.

2. Project contracting method: contracting for work and materials.

3. The duration of the project is X days.

4. The commencement date is 20XX x month x day, and the completion date is 20XX month x day.

5. Both parties agree that the price of this project is RMB (in words) XXXXX Yuan only. The down payment is X yuan only, and the balance will be paid in one lump sum after acceptance.

6. After the project is completed, Party B shall notify Party A for acceptance. Party A shall organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance form. After the project payment is settled, the handover formalities shall be handled.

7. This project is guaranteed for X years from the date of acceptance and signature by both parties.

8. If one party fails to perform the contract or violates national laws, regulations and relevant policies, and is fined or causes losses to the other party, the responsible party shall bear the responsibility and compensate the losses caused to the other party.

9. If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding losses.

10. This contract is made in X copies, with each party holding X copies. This contract shall come into effect after being signed (sealed) by both parties.

Party A (signature/seal):

Party B (signature/seal):

The employer renovation contract II (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Economic Contract Law of the People's Republic of China and other relevant laws and regulations, Party A and Party B have reached the following agreement on the renovation project on the basis of equality, voluntariness and consensus:

1. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

2. Project contracting mode: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. The construction period is _ _ _ _ days.

Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Both parties agree that the price of this project is RMB (in words) _ _ _ _ _ _ _. The down payment is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. After the project is completed, Party B shall notify Party A for acceptance. Party A shall organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance form. After the project payment is settled, the handover formalities shall be handled.

6. This project is guaranteed for one year from the date of acceptance and signature by both parties. After acceptance and signature by both parties, fill in the project warranty.

7. After the acceptance of the project, Party B proposes the project settlement to Party A, and sends relevant materials to Party A. If Party A has no objection within the day after receiving the materials, it will be deemed as agreement, and both parties will fill in the project description and sign it.

8. If either party fails to perform the contract or violates national laws and regulations and relevant policies of this Municipality, and is fined or causes losses to the other party, the responsible party shall bear the responsibility and compensate the losses caused to the other party.

9. If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding losses.

10. This contract shall come into effect after being signed (sealed) by both parties.

1 1. If Party A and Party B sign this contract directly, this contract shall be made in duplicate, with each party holding one copy.

Party A (seal): _ _ _ _ _ _ _ _ _ _ _ Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Entrusting party (Party A) of all-inclusive house renovation contract III: ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Contractor (Party B): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Rule number one. Project overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ Room specifications

(1) _ _ _ _ _ _, that is _ _ _ _ _ _ square meters.

(2)_ _ _ _ _ _ _ Hall, which is _ _ _ _ _ _ _ square meters.

(3)___ kitchen, with one meter _ _ _ _ _ _ square meters.

(4)___ bathroom, which is _ _ _ _ _ _ _ square meters.

(5)___ balcony, which is _ _ _ _ _ _ square meters.

(6) _ _ _ _ _ _ corridor, which is _ _ _ _ _ _ _ square meters.

(7) Other (specify location), which is _ _ _ _ _ _ _ _ _ _ square meters.

Total: the construction area is _ _ _ _ _ _ _ square meters.

3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Entrusting method: _ _ _ _ _ _ _ _ _ _ _ _ _ (contracting and materials, turnkey project).

5. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2, the project price

The project price (amount in words) is _ _ _ _ _ _ _ _.

Article 3, Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. Where materials and equipment are purchased by Party A, Party A shall be responsible for product quality and Party B shall be responsible for construction quality. ..

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4. Material supply

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5. terms of payment

1. After the contract is signed, Party A shall pay 100% of the engineering material cost and _ _ _ _% of the engineering cost. When the construction period is over half (_ _ _ _ _ _ _ _ _ _ _), Party A will pay _ _ _% of the second project cost. The remaining _ _ _% shall be settled by Party A after the project is completed and accepted. (Note: Construction costs include labor costs).

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

Article 6, the construction period

1. If the completion is delayed due to Party B's reasons, Party A will be fined _ _ _% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid _ _ _% of the labor cost of the decoration project price as the lost time fee for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. In the process of construction, if work is stopped due to engineering quality problems and disagreement between the two parties, it will not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

Article 7. any other business

1. Party A's responsibilities

1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

2. Party B's responsibilities

1) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the contract requirements, and complete the construction task on time with good quality and quantity.

2) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

Article 8. responsibility for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 9. Dispute mediation

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 10 Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 11 Entry into force of contract

1. This contract shall come into effect after being sealed by both parties.

This Contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature/seal): _ _ _ _ _ _ _ _ _ _ Party B (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Entrusting party (Party A) of all-inclusive house renovation contract IV: _ _ _ _ _ _ _ _ _ _.

Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for both parties to abide by.

I. Project Location:

________________________________________。

Second, the formal structure:

________________________________________。

Third, the project:

1, four rooms (two bedrooms and two living rooms) shall be paved with _ _ _ _ _ _ _ _ tiles and corner lines, which shall be smooth; The kitchen and bathroom walls are _ _ _ _ _ _ _ _ porcelain to the top, leaving room for ceiling, grinding corners and floor tiles _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. If no details are involved, Party A shall propose a plan and discuss it.

Fourth, the way of contracting:

Party A must, according to Party B's requirements, ensure the materials needed during the renovation period (Party B shall notify Party A in advance) and the lunch supply during the construction period, and Party B shall be responsible for the construction.

Five, quality standards:

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties. Within _ _ _ _ months after the project is completed and accepted, Party B shall be responsible for rework and maintenance for quality problems caused by Party B's construction.

Six, the project cost:

Materials shall be provided by Party A, and Party A shall pay Party B the renovation labor fee of RMB.

Seven. Payment terms:

In order to ensure the quality of the project, the deposit of _ _ _ _ _ _ _ yuan was temporarily withheld. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. Entry into force of the contract:

This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A (seal): _ _ _ _ _ _ _ _ _ _ _

Party B (seal): _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

All-inclusive house renovation contract 5 Party A:

Party B:

This agreement is reached by both parties through consultation, and both parties shall abide by it.

I. Project:

1, three rooms (two rooms and one living room, hereinafter referred to as three rooms) shall be marked with corner lines, including heating and pipes (the living room shall be symmetrical), and plaster lines shall be marked around the roof to cover the doors and windows of the three rooms; The living room and bedroom are covered with laminated wood floors; Remove the original paint from all rooms, putty from the living room and bedroom, and paint with Nippon paint twice.

2. Put a crossbar at the doors and windows of the balcony, and make a shelf on it according to Party A's requirements (drawings); On the east side of the balcony, a multi-purpose cabinet (shoes below and bookcases above) and a hanging cabinet on the west side are used to cover the balcony, lay tiles and hang pvc boards.

3, bathroom, bathroom, kitchen tiles to the top, pvc board hanging on the roof; The kitchen floor was tiled and a stove was built.

4. The power supply circuit of the room should be properly adjusted according to the requirements of Party A, and there is a multi-purpose cabinet behind the living room door (shoes are placed below and clothes are hung on it).

5. If no details are involved, Party A shall put forward a plan and discuss it.

Second, the way of contracting:

Party A must ensure the materials needed during the renovation according to Party B's requirements (Party B shall notify Party A in advance), and Party B shall be responsible for the construction.

Third, the quality standard:

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties.

Fourth, the construction period:

From XX, XX, XX to XX, XX, XX, XX, if it cannot be completed on schedule, 50 yuan will be fined every day.

Five, the project cost:

The materials are provided by Party A, and Party A only pays Party B the renovation labor cost of RMB XXXX.

Terms of payment for intransitive verbs:

After the completion of the project, if Party A meets the above-mentioned construction projects and design requirements after acceptance, the decoration labor cost shall be paid in one lump sum within three days.

Seven, other issues:

The specific requirements of the renovation project shall be put forward by Party A and implemented by Party B. Matters not covered in this agreement shall be settled by both parties through consultation. This agreement shall come into effect as of the date of signature by both parties.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect.

Party A:

Party B:

date month year

All-inclusive House renovation contract 6 Party A (Owner):

Party B (contractor):

According to the General Principles of the Civil Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of residential decoration engineering construction, and following the principles of equality, voluntariness, fairness, honesty and credit, the two parties reached the following agreement on matters related to residential decoration engineering through friendly negotiation:

I. Overview of the Project

1. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Signing method: Both parties agree to adopt the following _ _ _ _ _ _ _ _.

(1) contracting and materials;

(2) contracting and contracting some materials;

(3) The contractor does not package materials.

3. The total contract price is the budget price (in words): _ _ _ _ _ _ _ _ _ _ (in figures) _ _ _ _ _ _ _ _ _.

4. After the acceptance of the project, Party B shall submit the settlement book of the project to Party A, and send relevant materials to Party A. If Party A has no objection within five days, it shall be deemed as agreement, and the balance of the project shall be settled at the same time of signing the contract.

Second, the responsibilities and obligations of both parties

Party A:

1, coordinate relevant departments to do a good job in on-site security, fire fighting, garbage disposal, etc. , and bear the corresponding expenses;

2. The materials and equipment provided by Party A shall be qualified products that meet the requirements of design and national standards, and shall be supplied to the site in time according to the construction schedule, and Party B shall be notified in advance. Both parties shall accept the quantity and appearance of the supplied materials and handle the handover procedures.

3. Due to the difference in quality specifications of materials and equipment provided by Party A, Party B proposed to Party A that Party A still claimed that the use would affect the quality of the project, and Party A would bear the cost of rework.

Party B:

1. Provide the construction plan and progress according to the construction situation, which shall be approved by Party A;

2. Strictly implement safety construction operation specifications, fire prevention regulations, construction specifications and quality standards during construction, and complete the project with good quality on schedule;

3, responsible for the protection of on-site facilities and engineering products, to prevent accidents such as pipeline blockage, water leakage, power failure, damage to goods, etc. caused by construction, if any, should be responsible for repairing as soon as possible;

4, civilized construction, she certificate, ensure the cleanliness of the construction site, try to reduce noise, do not disturb the people and pollute the environment, after the completion of the project is responsible for cleaning up the construction site.

5. If the project quality is not in conformity with the contract, Party A has the right to ask for free repair or rework, and Party B shall be responsible for the losses caused thereby.

Third, the engineering change

1. During the construction of the project, when Party A proposes to modify or add or subtract the project, it must contact Party B in advance and sign a written change agreement before the project can start.

Fourth, the supply of materials and equipment

1. The materials supplied by Party A shall not be used for other purposes without the consent of Party A. If Party B misappropriates them, it shall compensate Party A at twice the price of the misappropriated materials.

2. The materials and equipment provided by Party B must conform to the varieties, specifications, models, varieties, grades, quality, measurement standards and quantities in the list of materials provided, and can only be used after being approved by Party A. ..

3. If the materials and equipment provided by Party B do not meet the quality requirements of national standards or have different specifications, it is prohibited to use them; If it has been used, then XX and losses shall be borne by Party B. ..

Verb (abbreviation of verb) the solution of contract dispute

1. After the contract comes into effect, during the performance of the contract, if either party terminates the contract without reaching an agreement and handling the contract termination procedures, it shall pay 5% of the total contract price to the other party as liquidated damages. If one party terminates the contract without authorization, it shall pay compensation. If one party is unable to perform the contract for some reason, it shall handle the contract termination formalities in another way in time, and the responsible party shall compensate the other party for the corresponding economic losses.

2. If one party fails to perform the contract or violates the national laws, regulations and relevant policies, the responsible party shall bear the responsibility and compensate the other party for direct economic losses.

3. Disputes arising from the performance of this contract shall be settled through negotiation by both parties or mediated by relevant departments. If mediation fails, it may be submitted to Meizhou Arbitration Commission for arbitration.

Other agreed items of intransitive verbs

1. Party A may entrust Party B with the responsibility of garbage cleaning and material handling caused by the construction, and the expenses shall be borne by Party A. ..

2. During the construction period, Party A will give the key 1 to Party B as a guarantee. After the project is completed and accepted, Party A will be responsible for providing new locks, which will be installed by Party B on site and delivered to Party A for use.

Seven. supplementary terms

1. If both parties agree otherwise, a supplementary contract can be signed.

2. This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated after the performance of the contract.

3. This contract has the same legal effect as the supplementary contract.

4. After the signing of this contract, the project shall not be subcontracted illegally.

5. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature): _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _

Telephone or mobile phone: _ _ _ _ _ Telephone or mobile phone: _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

All-inclusive House renovation contract VII (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _

Based on full consultation between Party A and Party B, compliance with relevant national laws and regulations, and combined with the specific conditions of this project, this contract is hereby signed and abided by both parties.

I. Overview of the Project

1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Project content: _ _ _ _ _ _ _ _ _ _ _ _.

3. Scope of this project: auxiliary materials, construction period, quality, safety and civilized construction.

4. The project duration is _ _ _ _ _ days (calendar days), starting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the project quality and acceptance criteria

According to the drawings, design requirements and construction acceptance specifications, procedures and quality inspection standards issued by the state.

Three. Contract price and payment method

1. The estimated total cost of this project is (in words) _ _ _ _ _ _ _. See the project budget table for details. If there are additional items, both parties will negotiate separately.

2. Payment method:

(1) When the construction site starts, Party A shall pay the project payment to Party B: _ _ _ _ _ _.

(2) After the bricklayer's work is completed, Party A shall pay Party B RMB.

(3) After the completion acceptance, Party A shall pay the project payment to Party B: _ _ _ _ _ _.

Four. Party A's responsibilities

1. Provide a complete construction site, coordinate the relationship between various departments and neighbors, and ensure the smooth progress of the project.

2. Provide Party B with water supply and power supply during the construction period.

3. Be responsible for reviewing the drawings and signing them for approval as the basis for construction. Otherwise, Party B has the right not to carry out the construction and the construction period will be postponed. If the project is changed or added, both parties shall negotiate to adjust the construction drawings, project cost and construction period, otherwise Party B has the right not to modify or change or add.

4. Be responsible for the acceptance of concealed works before concealment.

5. Organize the acceptance work in time after the completion of the project.

6. Pay the project progress payment to Party B in time according to the provisions of Article 3 of this contract.

Verb (abbreviation of verb) Party B's responsibility

1, in strict accordance with the drawings approved by Party A. ..

2. Fine construction operations shall be carried out in strict accordance with the relevant specifications of engineering design to ensure the quality and safety of the project.

3. Actively cooperate with Party A to do a good job in environmental health and safety, and abide by the relevant management system of the community.

4. Be responsible for the whole project budget, determine the quality of materials needed for the project, and purchase materials in strict accordance with the quality standards listed in the project design plan.

5. Be responsible for timely cooperating with Party A to complete the project completion acceptance.

6, the construction site as scheduled, completed on schedule.

Liability for breach of contract of intransitive verbs

1. If the construction period is delayed or stopped halfway due to Party A's reasons, it must be signed and agreed by Party A or its authorized person, and the construction period will be postponed. If Party A fails to pay the project progress payment as agreed in the contract, it shall pay 0. 1% of the payable amount for each day overdue.

2. If the completion is delayed due to Party B, a penalty of 0.65438+ 0% of the payment amount shall be paid for each day overdue.

3. If the contract cannot be continued due to one party's reasons, it shall notify the other party to handle the contract termination agreement, and the responsible party shall compensate the other party for the resulting economic losses.

Seven. Warranty regulations

The warranty period of the project shall be implemented according to the relevant provisions of the state. In case of quality problems during the warranty period, Party B shall be responsible for free maintenance. If the quality problems caused by Party A's improper use or intentional damage are not covered by the warranty, Party B can assist in the maintenance, and the expenses shall be borne by Party A. The warranty period of this project is _ _ _ _ years.

Eight. safe

1. During the period from project construction to project delivery, Party A's personnel (except site representatives and supervisors) shall not enter the construction site without the permission of Party B's on-site project management personnel, otherwise Party A shall be responsible for personal safety or other safety accidents. If personnel other than Party A enter the construction site without authorization, causing personal safety or other safety accidents, Party B shall be responsible.

2. In the process of construction, Party B shall be responsible for the loss of personnel safety or construction in progress due to its illegal construction and violation of operating procedures.

Nine. any other business

1. Other matters not covered shall be settled by both parties through negotiation.

2. In case of any disagreement during the performance of this contract, both parties shall, in principle, settle it through friendly negotiation; If negotiation fails, the case may be submitted to the local economic arbitration commission for arbitration.

3. This contract is made in duplicate, one for each party. It will take effect as of the date of signature and seal by both parties. After the project is completed and settled, Party A pays off the project payment, and Party B delivers the project to Party A for use, and this contract is terminated.

Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

All-inclusive House renovation contract 8 Customer (Party A):

Organizer (Party B):

I. Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Form and structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the project:

Four. Contracting method: Party B contracts materials.

Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same building type. Both parties agree that the Code for Quality Acceptance of Building Decoration Engineering (GB502 10-20xx) is the minimum standard for quality evaluation; The indoor environmental standards are 10 mandatory national standard for the limit of harmful substances in building decoration materials and the indoor environmental pollution control standard for civil construction projects.

Intransitive verb contract sum: (in words) _ _ _ _ _ _ _ _. After the completion of the project, check the settlement according to the facts. The contract payment is a one-time payment.

Seven. Payment method: after the contract is agreed, Party A shall pay 35% of the project price in advance _ _ _ _ _ _ _ _; Pay 40% of the project cost _ _ _ _ _ yuan after the concealed works such as water and electricity are qualified; Pay 20% _ _ _ _ _ yuan after the acceptance of the bricklayer's carpentry intermediate project, and pay the balance of 5% _ _ _ _ _ _ yuan within 5 days after the project completion acceptance.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A:

Party B:

;