Traditional Culture Encyclopedia - Weather inquiry - Exterior wall rock wool insulation construction contract
Exterior wall rock wool insulation construction contract
Exterior wall rock wool insulation construction contract template (5 general articles)
In a society where people increasingly believe in the law, contracts appear more and more in our lives. , it is also an important measure to reduce and prevent disputes. What kind of contracts have you seen? The following is the exterior wall rock wool insulation construction contract template (5 general articles) that I have carefully compiled. You are welcome to learn from it and refer to it. I hope it will be helpful to everyone.
Exterior wall rock wool insulation construction contract 1
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, and in compliance with the principles of equality, free will, mutual benefit and reciprocity, Party A and Party B signed the following contract through friendly negotiation
1. Project Overview
1. Project name: ____ City Blue Diamond Residence Phase I Project
2. Project location: North XX of Danyang East Road, west side of 207 National Highway XX
II , Project contract scope
Party B is responsible for
1. Brick sticking on the exterior wall of the 4th floor (including cleaning work of the exterior wall).
3. Quality Standards and Acceptance Requirements
1. Party B must strictly abide by relevant national and industry technical standards and specifications, and follow the on-site construction personnel’s follow-up inspections to achieve quality standards. It must be inspected and accepted by the company before being dismantled (including cleaning the tiles and repairing).
2. Construction period requirements: The construction period of this project is Party B’s. From the date of signing the contract, Party B must complete the project according to Party A’s construction progress plan. Party B shall be responsible for the losses and liabilities arising from delays in the construction period or non-extension of the construction period due to Party B's fault, and Party A shall have the right to impose penalties on Party B. The 4th floor will be glued on a large area on ____ month ____, and the 1st floor will be glued on a large area on ____ month ____.
IV. Price and payment method
1. Contracting unit price: 40 yuan per square meter, calculated based on the actual pasted expansion area.
2. Payment method: Workers can pay living expenses during the construction process. The external wall of this project
will be paid to the general manager after all brick pasting is completed and accepted by the project department, supervisor, and construction unit. 85% of the project payment will be paid to 95% ____ months after the project is completed and accepted, and the balance will be refunded without interest at the end of the warranty period.
5. Responsibilities of both parties:
1. Responsibility of Party A
1.1. Provide technical briefing to Party B and review the construction technical plan prepared by Party B.
1.2. Provide water, power, and accommodation for workers.
1.3. Coordinate Party B’s cooperation with other majors during construction.
1.4. Party A will unconditionally erect the areas where the exterior wall needs to be erected. After both parties confirm that there are no safety hazards, Party A will hand them over to Party B for safe construction. Including shelves for patio and roof flower stands.
2. Party B’s Responsibilities
2.1. Comply with Party A’s relevant management rules and regulations and obey the command, coordination and organizational management of Party A, the supervising engineer and the owner’s representative. The person in charge of Party B must attend regular project meetings organized by Party A and keep records. Party A will fine Party B 200 yuan for each absence if absent.
2.2. The person in charge of Party B (or designated person) must stay on site 24 hours a day (in special circumstances, he must ask for leave from the foreman in charge and the foreman in charge), otherwise Party A will punish Party B 100 yuan each time.
2.3. All machines, safety helmets, and safety belts used by Party B shall be brought by Party B. Party B is responsible for repairing, maintaining, and replacing spare parts to meet safety requirements.
2.4. Party B’s personnel shall not dismantle or change the scaffolding, various safety facilities, and safety warning signs at the construction site without authorization. If it is really necessary to dismantle or modify the construction, it must be approved by the person in charge of the construction site and the safety management personnel assigned by Party A, and necessary and reliable safety measures must be taken before dismantling. The party B shall be held responsible for the consequences caused by unauthorized demolition by Party B's personnel. Party B shall be responsible for any work-related injuries caused.
2.5. Party B is responsible for providing safety education to Party B’s personnel and abiding by relevant national safety construction management regulations. It is strictly prohibited to throw, play, fight, or drink during construction. Those who violate the regulations and fail to stop will be fined - 3,000 yuan. If a safety accident occurs under the above circumstances, Party B will be responsible. Party A is not responsible.
2.6. Party B’s personnel shall consciously abide by the rules and regulations of the construction site. Fighting, brawling and gambling are strictly prohibited. If found, a fine of more than 5,000 yuan will be imposed. Medical expenses caused by fighting shall be paid by the person in charge of Party B.
2.7. Party B must ensure quality and construction period and be responsible for site clearance after completion. For the agreed construction period of the contract, a construction period bonus is provided. A bonus of 500 yuan will be given if the project is delayed one day, and a penalty of 500 yuan will be given if the project is delayed one day. And bear the cost of quality rework.
2.8. Party B’s construction personnel shall strictly obey the management of Party A’s on-site management personnel and abide by Party A’s relevant rules and regulations for safe and civilized construction. If there is any violation, they shall be punished according to Party A’s corresponding regulations, with a fine amount of Deducted from Party B’s project payment.
2.9. It is strictly prohibited to use high-consumption appliances such as electric stoves, rice cookers, and heaters in the dormitory, and it is strictly prohibited to use gas stoves.
2.10. If the team accommodation staff disobeys the management and uses high-consumption electrical appliances without authorization, the project department will fine the team 500-1,000 yuan each time and impose a fine of 200-500 yuan on the team members.
2.11. If a team member violates the guard personnel management system, such as climbing doors, climbing over walls and other uncivilized behaviors, the project department will impose a penalty of 500 yuan on the team and 200 yuan on the parties involved in the team.
2.12. Team members must register for accommodation with their ID cards or other valid documents and obey the unified arrangements of the dormitory management personnel.
2.13. After moving in, the squad leader should conduct daily inspections at least once a week, urge the accommodation staff in the team to improve indoor and outdoor hygiene, and check the compliance of the accommodation staff in the team.
6. Safe and civilized construction
6.1 Before team members enter the construction site, they must first undergo the third-level safety education of the project department, and apply for employee salary cards and employment certificates before entering the construction site;
p>
6.2 When the team is working on-site, the team leader should do a good job in the daily management of the team, regularly strengthen inspections of each operation point, and actively carry out team safety activities, and complete the three activities before the shift (induction) Information disclosure, on-the-job inspection, on-the-job education) and after-shift inspection work;
6.3 If the team members do not wear safety helmets on site, the safety officer will be responsible, and each person will be fined 50 yuan each time, which will be paid by the team .
7. If there is a dispute between Party A and Party B during the performance of the contract, they should actively coordinate and resolve it. If the negotiation fails, you can file a lawsuit with the ____ Municipal People's Court.
8. This contract is made in duplicate and will take effect after being signed and sealed by Party A and Party B.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
< p> Exterior wall rock wool insulation construction contract 2 on _________year____month___________year____month________Party A:
Party B:
After negotiation between Party A and Party B, Party A contracts the ceramic tiles on the exterior wall of the project to Party B. The specific terms are as follows:
1. Construction period:
The total construction period is 65 days, that is, from the start of construction on _________year____month____ to the completion acceptance on _________year____month____. (The construction period cannot be postponed due to weather reasons)
2. Contracting price:
The contracting amount is 30 yuan per square meter, including foundation, tiling, joint wiping, cornering, Clean the wall before removing the outer frame. The total area is calculated according to actual conditions.
3. Payment method:
Pay living expenses on a regular basis, and pay in full upon completion acceptance.
IV. Responsibilities of Party A:
1. Responsible for the supply of main materials such as ceramic tiles, cement, and glue.
2. Responsible for connecting power and water sources.
3. Make payment for the project in accordance with the contract requirements.
5. Party B’s responsibilities:
1. Strictly implement construction specifications and safety operating procedures. Party B will be responsible for all safety accidents that occur during construction.
2. Construction must be carried out according to Party A’s requirements to ensure the quality of decoration.
3. If there are quality problems caused by construction during the decoration period and the warranty period, Party B will be responsible for rework and repair at the expense of Party B.
4. Party B is responsible for transporting ceramic tiles, cement and other materials upstairs.
5. The consumption reduction of ceramic tiles shall not exceed 2%.
6. Party B must complete the work on time as required by the contract. If Party B cannot complete the work on time, the rent (yuan days) of the steel pipe scaffolding will be borne by Party B, and Party A will deduct it from the project payment.
This contract is made in two copies, with each Party A and Party B holding one copy. It will take effect after signature.
Signature of Party A:
Signature of Party B:
Exterior wall rock wool insulation construction contract on _________year___month_____3
Party A;
Party B;
In accordance with the "Construction Law", "Contract Law" and relevant laws and regulations, after full consultation between Party A and Party B, in the spirit of mutual benefit, equality, Based on the principles of voluntariness, fairness and good faith, Party A now contracts the (project name) exterior wall insulation project to Party B for construction. In order to ensure the legitimate rights and interests of both parties, both parties negotiated and reached the following contract to sign this contract.
1. Project Overview:
1. Project Name:
2. Project Location:
3. Project Content:
p>
4. Contracting method:
2. Project contracting scope
All external wall insulation included in the construction blueprint.
III. Contract Period
1. The project starts from ____ month ____, _________ year and ends on ____ month ____, _________ year. The effective construction period of the project is ____ days.
2. Party B must reasonably arrange construction according to the construction schedule prepared by Party A. The rainy season and other objective reasons will affect the construction period. It can be resolved through negotiation between Party A and Party B.
3. Party B shall carry out construction according to Party A’s construction period requirements. If Party A delays the construction period due to reasons B, Party A has the right to take corresponding economic penalty measures against Party B. If Party B does not delay for one day, Party A will finally be charged RMB 100,000. fine.
IV. Quality requirements:
1. Party B shall comply with the "Uniform Standards for Quality Acceptance of Construction Projects" (GB50300), "Specifications for Quality Acceptance of Building Decoration and Decoration" (GB50210) and related National specifications and external insulation construction technology.
2. Party B must establish a complete quality management responsibility system. The quality of construction shall be subject to acceptance by the project department, supervision unit, and quality supervision station. If the quality requirements are not met due to Party B's reasons, Party B will be responsible for all costs of rework, re-construction, etc., as well as all quality consequences and economic losses.
3. The exterior wall must be smooth, solid, and free of quality defects such as powdering, peeling cracks, and hollows that affect the construction of exterior wall finishes. During the construction of exterior walls, the site must be cleared after completion.
4. Materials entering the site must provide corresponding performance test reports, product certificates and site acceptance records.
5. Party B must follow the construction process of external wall insulation during the construction process. Only after the project department and supervision unit have passed the inspection, can the construction proceed to the next step.
6. Party B must obey the instructions of the project department during the construction process and construct in strict accordance with the national construction specifications.
5. Project cost:
The amount of external wall insulation construction work is calculated based on the actual area, and the comprehensive unit price is ____ yuan.
6. Payment methods and settlement
1. The project will be determined according to the construction blueprint.
2. Based on the construction progress and project progress payment, each payment shall not exceed 85% of the completed project
3. After the project construction is completed and accepted, 5% of the quality warranty will be retained Party A shall pay the balance if there are no quality problems within half a year.
4. Four payments: Material workers come in to pay living expenses and start construction.
The first exterior wall, construction
The second exterior wall, coated with mesh cloth and anti-crack mortar, 95% of the total project price will be paid after the construction is completed
7. Party A’s responsibilities:
1. Pay project progress payment to Party B in accordance with this contract. Party A will be responsible for any impact on the project schedule due to insufficient payment.
8. Party B’s responsibilities:
1. Party B shall construct in accordance with the requirements of the project department and supervision unit and the corresponding national construction specifications and exterior wall construction techniques. Party B shall reasonably arrange construction according to Party A's construction progress, obey project management, and shall not delay the construction period for any reason. (If the construction period needs to be delayed due to objective reasons, it is necessary to communicate and negotiate with the project department and the supervisory unit)
2. Party B shall not subcontract the contracted project to a third party, otherwise the construction period will be delayed for one day and a fine of 500 yuan will be imposed. Party A has the right to terminate the contract.
3. Party B’s workers entering the construction site must be proficient in exterior wall insulation construction techniques. Construction operations are prohibited for non-professionals. The food and accommodation of Party B’s workers shall be arranged by Party B.
4. After the project is accepted, Party B shall make repairs on call during the warranty period. Otherwise, Party A has the right to entrust other personnel to carry out repairs. The cost will be deducted from Party B’s maintenance fee, and Party B shall be responsible for any resulting damages. as a result of.
5. During the construction process, Party B must establish a complete safety guarantee system and arrange for dedicated personnel to inspect the safety protection equipment of construction machinery and operators on a regular basis. Carry out correct construction in accordance with safety technical regulations. Illegal operations are prohibited, and Party B will be fully responsible for all safety accidents that occur at the construction site.
6. Party B shall carry out construction in strict accordance with the national safety operating procedures and civilized construction standards. Otherwise, Party A has the right to take punitive measures against Party B in accordance with the project management penalty management measures. After the completion of the project, Party B will clean up the construction waste at the construction site, keep the construction site clean, and ensure that the site is clean after the work is completed.
9. Other matters:
If there are any unsatisfied matters in this contract, Party A and Party B shall separately negotiate a supplementary agreement, and the supplementary agreement shall have the same legal effect as this contract. This agreement is made in two copies. Party A and Party B each hold one copy. It will take effect after being signed and sealed.
Party A:
Party B:
Date: _________year____month____Exterior wall rock wool insulation construction contract 4
Party A: ID number: Home address:
Party B: ID number: Home address:
In order to clarify the responsibilities and obligations of both parties, ensure safe construction, and improve the project In order to ensure the quality, Party A will contract the external wall insulation construction project to Party B in the form of a clean-up contract. Party B will be the person responsible for the contract and organize personnel and related tools and equipment to carry out the construction. The following agreement has been reached by consensus between both parties:
1. Project name: Exterior wall insulation project.
2. Scope of work: All exterior wall insulation projects within the scope of the project contract, including plastering on structural surfaces, application of interface agents, inorganic insulation, inlaid mesh cloth, anchors, and application of anti-cracking mortar , site cleaning, finished product protection and other work.
3. Construction period and warranty period:
1. This project will start on ____ month ____ of _________year to ____month___ of _________year Completed on _day.
2. In order to ensure completion on schedule, Party B promises to employ no less than 20 construction workers per building every day. If Party B's construction personnel cannot keep up with the progress (do not meet the project progress plan), Party A has the right to change the team and settle the bill based on 50% of the completed work.
3. If the construction period is delayed due to Party B’s construction organization and other reasons, for each day of delay, Party B will pay Party A a penalty of 1% of the total contract price, which will be deducted from the settlement payment.
4. If the construction period is delayed due to force majeure, compensation for the construction period will be given after Party A signs and approves.
5. The warranty period of this project is two years, calculated from the date of passing the acceptance inspection.
4. Cleanup contracting price: _____ yuan based on the actual construction area. At this price, Party A is only responsible for providing raw materials, and all other tools and accessories such as electric hammers, electric drills, cables, etc. required for the construction. Party B is responsible for both materials and labor. If you need to add molding lines to the wall, please calculate it separately.
5. Payment method:
1. After the contract is signed, there will be no progress payment for the first 2 months before Party B enters the site, and the workers’ living expenses will be advanced by Party B themselves;
2. Party A will pay 50% of the completed project volume at the end of the third month after entering the site;
3. Acceptance after all projects are completed, and 90% of the total price will be paid after passing the acceptance; < /p>
4. After the construction unit and the Wall Renovation Office of the Construction Committee pass the inspection and acceptance, both parties will measure the project quantities and settle the actual amount, and pay 95% of the total settlement price;
5. The remaining 5% will be two years No quality problems will be paid off after the warranty expires.
6. Agreement on quality:
1. Construction shall be carried out in strict accordance with the technical regulations for the application of exterior wall insulation in ____ provincial engineering construction (inorganic insulation requires anchors), and the quality shall reach Relevant acceptance standards are met.
2. During the construction process, if the construction quality does not meet the requirements, Party A has the right to change the construction team and settle the bill based on 50% of the completed project quantity. If rework or quality problems occur due to construction reasons, Party B shall bear full responsibility and bear the resulting economic losses.
3. The quality of the project is in accordance with the current national acceptance standards and is required to meet the one-time acceptance standards of the Municipal Construction Committee Wall Renovation Office. If the inspection fails at one time, Party B shall bear all costs required for repairs until the inspection is passed. and bear the resulting economic losses.
4. During the two-year warranty period, if quality problems occur due to Party B’s construction, Party B shall go to the site to perform repairs within 24 hours after receiving Party A’s maintenance notification. If Party B does not arrange maintenance personnel, Party A will arrange other personnel to perform maintenance on its own, and Party B will bear double the costs incurred. If problems occur due to other reasons, Party B shall also arrange personnel to perform repairs, and Party A shall pay the repair costs.
VII. Agreement on safety:
1. Party B shall provide safety insurance for all construction personnel, and the expenses required for construction safety insurance shall be borne by Party B.
2. During the construction period, Party B must carry out construction according to relevant safety operating specifications, and at the same time provide safety education to team members and take necessary safety measures (hard hats, safety belts and safety ropes). Party A will conduct inspections on safety measures from time to time. If any illegal operations are found and safety protection equipment is not worn as required, Party A will impose a financial penalty on Party B of 100 yuan per person per time. When the same person appears for the second time, he will be expelled from the construction site.
3. If a safety accident occurs, it has nothing to do with Party A. Party B will bear full responsibility and handle the aftermath.
8. Agreement on the delivery of materials:
1. After the materials provided by Party A are transported to the construction site, Party B shall bear the responsibility for safekeeping.
2. The materials used shall be in accordance with the amounts agreed in the table below (including losses), and both parties will make an accounting after completion. If materials are overused, the market price will be deducted from Party B's cleaning fee. The name of the materials for the insulation part: interface agent, inorganic insulation, mesh cloth, anchor nails, anti-crack mortar. The usage limit per square meter is 1g, 20g, 1.22, 5 sets, 3g.
9. Responsibilities of Party A and Party B:
(1) Responsibilities of Party A:
1. Transport all required materials to the construction site.
2. Coordinate the construction unit to provide water and electricity required for construction.
3. Make timely payment according to Article 5 of the contract.
(2) Party B:
1. After signing this contract, a labor contract agreement and a safety responsibility letter shall be signed with all operators involved in the construction in a timely manner and submitted to Party A for record.
2. Strictly abide by the rules and regulations of Party A and the construction site, safe operating procedures, civilized construction and comprehensive management regulations, obey the supervision and inspection of Party A and the construction party’s on-site management personnel, and accept rectification opinions, Complete rectifications within a time limit to ensure safety and construction quality.
3. Inspect the base layer to be constructed before starting construction. At any time, you may not shirk responsibility for construction quality problems on the grounds of grassroots quality problems.
4. All safety facilities, machinery and electrical appliances at the construction site should be inspected before use. If any hidden dangers are found, they should be dealt with in a timely manner and reported to Party A. No construction is allowed unless safety is guaranteed. Put an end to illegal command, illegal operations and sick operation of machinery. Party B and the perpetrator shall bear full responsibility for any safety accidents caused by violations of regulations or illegal operations.
5. Keep and use the materials provided by Party A properly, and compensate according to the price if lost.
6. The responsible person of Party B shall exercise the responsibilities and obligations towards the contracting party on behalf of Party A at the construction site.
7. Clean up the construction site after completion, sort out remaining materials and scraps in a timely manner, and keep the site neat, civilized, clean and hygienic.
8. Party B and its affiliated members are not allowed to bring non-site personnel into the construction site. If found, Party A will punish Party B in accordance with relevant regulations. If any accidental injury occurs, Party B will be held responsible.
9. Protect all existing finished structures such as windows and roof tiles of residents on site. If there is any damage, Party B is responsible for restoring it to its original state, and all costs will be borne by Party B.
10. For unfinished matters, both parties should resolve them through friendly negotiation. If the negotiation fails, they can apply to the ____ Municipal Arbitration Commission for arbitration or file a lawsuit with the ____ Municipal People's Court.
11. This contract is made in two copies, one copy each for Party A and Party B. It will take effect after being signed and sealed.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
< p>_________year____month_____________year____month______Exterior wall rock wool insulation construction contract 5Contractor (referred to as Party A):
p>Contractor (hereinafter referred to as Party B):
Party A and Party B have negotiated in the spirit of fairness, justice and reasonableness and in the spirit of mutual benefit. In accordance with the relevant provisions of the "Contract Law of the People's Republic of China", the "Construction and Installation Project Contract Regulations" and relevant laws and regulations, and combined with the specific conditions of this project, the two parties have reached this construction agreement for the purpose of mutual agreement during the cooperation period. Comply with the specific terms as follows:
1. Project Overview
Project Name: Exterior Wall Decoration of Buildings A and B of Gemdale Community Office Building
Project Address: Gemdale Community Nature of internal contracting: Contracting of labor and materials according to the requirements of Party A (construction drawings provided) Contents of the construction project: tiling on exterior walls, spraying or rolling real stone paint, installing aluminum alloy windows, etc.
2. Contract duration
p>1. _________year____month____day________year____month____day, the construction period is 30 days.
2. If construction cannot be carried out due to Party A’s reasons or force majeure factors, the construction period will be postponed.
IV. Basis for project settlement
If there is an increase or decrease in project items and project quantities, changes in project structure, project design, and material changes during the construction of this project, visa procedures should be handled in a timely manner. , submit project change notices, etc. as the basis for project settlement; at the same time, settlement will be based on the national calculation rules for construction installation and decoration projects and the completion drawings of the project
5. Material supply
Supplied by Party B according to design requirements. Provide samples first for sample acceptance and inspection.
3. Contract Price
This project adopts the form of a unit price contract. The unit price of the installation of aluminum alloy doors and windows is 380 yuan, the removal of stainless steel protective nets is 50 yuan, and the removal of plastic steel windows is 60 yuan. The total cost of the contract is about 20 yuan, which is finally settled based on financial evaluation based on material quality and actual construction area (attached: negotiation, initialing, as-built drawings, and bill of quantities).
IV. Project Settlement Method
1. There is no project advance payment for this project. Party B’s materials have been brought in to install the aluminum alloy frame and have been accepted by the supervision unit and Party A. Within the next week, 50% of the total project price will be paid. After the completion acceptance is passed, 45% of the total project cost will be paid in one lump sum within 7 days after the settlement review is completed, and the remaining 5% will be used as a warranty deposit. If there is no warranty within the ________-year warranty period, For quality problems, Party A shall pay the full amount within one week after the expiration of the warranty period of _________.
2. The unit price shall be fixed according to the project price, design changes, increase or decrease in project quantity shall be settled. It shall be subject to the signature and confirmation of the on-site engineer.
3. After the project is accepted and accepted, the contractor will prepare a construction settlement statement and send it to the contracting party for review. The review will be completed within 7 days from the date of receipt of the contractor's settlement statement.
6. Work of both parties
Party A’s work
1. Provide the starting conditions and coordination work required for the water and electricity required for construction.
2. Party B is responsible for assisting Party B in reporting inspection matters to the quality supervision department, and Party A shall bear the required expenses.
3. Responsible for supervising and inspecting the progress and quality of the project.
4. Provide relevant drawings and materials required for the construction of this project, and promptly notify Party B after Party A or the design institute changes the design.
5. Relevant losses caused by rework, work delays, and shutdowns caused by reasons other than Party A or Party B shall be borne.
6. Assist Party B to handle completion documents and organize relevant acceptance work. Party B’s work
1. Construction shall be carried out strictly in accordance with the construction plan confirmed by both parties, and materials or design plans shall not be changed at will.
2. Accept the supervision of Party A and the supervisor, carry out civilized construction, and do not damage any indoor or outdoor facilities, otherwise
7. Party B shall complete the agreed work on schedule according to the construction plan arranged by Party A content, and comply with various safe and civilized construction systems at the construction site and obey the instructions of Party A’s on-site person in charge.
2. Construction shall be carried out strictly in accordance with the aluminum alloy window design and construction drawings provided by Party A and the samples confirmed by the supervisor.
VII. Project quality requirements and acceptance standards
1. The production and installation of doors and windows should comply with the design and national acceptance standards.
2. After the aluminum alloy doors and windows enter the site, Party B can only proceed with installation and construction after passing the inspection.
3. After completion, Party B must provide engineering technical data. If the data does not meet the filing requirements due to Party B's reasons, Party B will supplement and improve it within the agreed period, and Party B will bear the resulting costs.
4. Party A, supervision, and quality supervision departments will randomly inspect products and processes that do not meet the requirements, and Party B will rework them unconditionally.
8. Liability for breach of contract
Responsibilities of the contractor:
1. If the construction does not comply with the provisions of the contract, it will be responsible for free repair or rework. If delivery is delayed as a result, overdue liquidated damages will be paid.
2. If the project cannot be delivered for use within the construction period stipulated in the contract, overdue liquidated damages shall be paid. If losses are caused, Party A must be compensated for the losses.
Responsibilities of the contractor:
1. If the project is suspended or postponed midway, or rework is caused by design changes or design errors, measures should be taken to compensate or reduce losses. At the same time, Party B shall bear the actual losses caused by this.
2. The project has not been inspected and accepted, and the contracting party has used it in advance. Therefore, the contracting party shall bear the responsibility for any quality problems that occur.
9. After-sales service and warranty
The warranty period is _________ years from the date of acceptance. If quality problems occur, Party B is responsible for repairs. Party B is not responsible for repairs due to non-quality reasons.
10. Supplementary Provisions
1. If a dispute arises between the two parties during the performance of the contract, it shall be under the jurisdiction of the court at the place where the contract is performed.
2. This agreement is made in duplicate, with Party A and Party B each holding one copy.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
< p>_________month____day_____year____month____day;- Previous article:Which city does Qiannan Buyi and Miao Autonomous Prefecture belong to?
- Next article:Does Hefei Wetland Park need tickets?
- Related articles
- What if the weather is dry?
- Matters needing attention when going to the seaside in thunderstorm weather
- I bought a boot. How does a short man dress with a pair of riding boots?
- Why does the weather forecast always come back?
- Compared with autumn, what's more weather in summer in Medog County?
- What software is good for downloading applications?
- A poem sorry for a friend
- What contribution did the beautiful Xiaoxing 'anling make to people in autumn?
- The main manuscript to prevent drowning activities
- Will the fog affect the high-speed rail