Traditional Culture Encyclopedia - Weather inquiry - Individual house building project construction contract
Individual house building project construction contract
In today’s evolving world, the frequency of use of contracts is on the rise. Contracts are a very important factor in enterprise development. What kind of contracts have you seen? The following is a collection of personal house building project construction contract templates (selected 5) that I have collected. You are welcome to share them. Personal House Building Project Construction Contract 1
Private residential construction general person in charge: ____________
Party B: ____________
Private residential building construction party person in charge: ____________ < /p>
According to the Construction Law, the "Economic Contract Law" and relevant laws and regulations, Party A and Party B, under the principles of equality, voluntariness, fairness, reasonableness, and mutual benefit, reach an agreement on the private residential building project through mutual negotiation, in order to standardize the construction The civil acts of both parties in private residential projects are specifically stipulated in this contract, and both parties must strictly implement and abide by them.
1. Overview of the construction project
The private residential building project is a civil residential building. This project is designed to be a two-story building with a brick-concrete structure. The building area is subject to actual measurement. The construction fee is __ yuan per square meter.
II. Architectural design requirements
1. This project is a brick-concrete structure residential building with a depth of 7 meters and a total length of 13.5 meters. It is a bungalow building with a construction area of ??___㎡.
2. The building area shall be subject to actual measurement. Payment shall be made to Party B based on the actual measured area to ensure that the area cannot be reduced or increased at will. If modifications are needed, they must be modified after consultation and agreement by both parties, otherwise Party B shall bear full responsibility.
3. Party A is responsible for feeding the steel bars and materials
1. The steel bars are grade three steel bars, and the square pillars: No. 16-18-20 (trees) are constructed according to the formal design.
2. Aohuan cement grade 32.5, floor height, the first floor is 3.9 meters, and the second floor is 3.8 meters.
3. The thickness of the board is 13-14 cm, and the thickness of the cylinder is 30 cm.
4. The window cover has two small window covers and one large window cover. The small window cover and the large window cover are designed and constructed according to Party A's design. There are slopes on three sides of the roof, and the height is ___ meters. .
5. Party B ensures that the house is of qualified construction quality and reasonably designed, and that building materials are not allowed to be used or discarded indiscriminately.
3. Structural design description:
1. This project adopts strip foundation with a depth of 1 meter and a 40 cm geocircle beam. It is constructed according to three foundations with a width of , must be constructed strictly in accordance with specifications.
2. The foundation ring beam and top ring beam steel bars shall be based on the standard steel bar materials provided by Party A, including the installation of vase railings on the slope of the second floor, including the painting of all walls and columns, and exterior wall cement. Whitewash.
IV. Contracting construction methods
1. Before the construction of this project, Party A must ensure that electricity, water and access are available, and the building area is flat, and cannot affect the construction and surrounding neighbors' buildings due to land boundaries. Disputes over property and other matters shall be resolved by Party A.
2. The construction method of this project is contract construction, and the area price is subject to one-time negotiation according to the first contract. The project must be constructed in strict accordance with the graphic design and construction agreed by Party A and Party B (refer to the sketch stipulated by Party A and Party B). Party B is not allowed to change the graphic design at will. It is not allowed to increase or reduce the area without Party A's consent, and it has to responsibly mess with the construction methods.
3. If design problems are discovered during the construction process and changes are really needed, both parties must reach consensus and re-sign the change contract before it can take effect. Otherwise, Party A will not recognize it, and the materials and construction costs will be borne by Party B. Take full responsibility.
4. Party B must ensure production safety during construction. For safe construction, adequate safety guarantee mechanisms and measures must be in place. If a safety accident occurs due to Party B not paying attention to safety during construction, Party B shall bear full responsibility, and Party A shall not bear any responsibility.
5. Party B must accept Party A’s supervision during construction and accept and adopt contractual suggestions.
6. Party B will bring its own machinery, templates, ejector rods, and food.
5. 1. The project payer “pays __ yuan for the start of construction and three payments for completion of civil works. In addition to the deposit, the deposit is 6,000 yuan.
2. Withholding the deposit for quality issues 1 The total amount of RMB 10,000 shall be paid within 1 year from the date of completion of the civil engineering project. The quality deposit must be paid by Party A when it is due, and all funds shall not be withheld.
3. Party B: Ensure that there will be no quality problems with the house. , For example: if the wall is cracked, the floor is leaking, etc. If there is any problem, Party B will bear all the responsibilities and withhold all the money during the trial period.
4. Party A: There is a slight wall on the building wall. Body cracks and other minor phenomena that do not affect the construction quality are normal phenomena. Party A must pay all the money when it is due and shall not withhold it.
5. The scheduled construction period of this project is as of the date of commencement. 120 days.
6. Other Project Matters
During the construction process of this project, both parties must strictly abide by the contract and shall not terminate the contract at will. In the event of force majeure natural disasters or government departments The contract can be terminated by the person who moves the house, and the construction progress list is based on the percentage of the construction process.
For any unfinished matters during the construction period, both parties can negotiate and resolve them at any time and sign a supplementary project contract.
VII. Dispute Resolution
This agreement will become legally effective after being signed and sealed by both parties.
After the signing of this agreement, all disputes between the two parties regarding this agreement will be resolved through negotiation between the two parties. Any party that fails to reach an agreement may file a lawsuit with the judicial office or people's court of the jurisdiction.
For parts that are not involved in disputes, both parties will continue to perform in accordance with this agreement. If this contract needs to be modified, it must be agreed upon by both parties. This contract is made in two copies, with Party A and Party B each holding one copy.
This contract will come into effect upon signature by both parties A and B. After it becomes effective, both parties A and B must abide by it.
Party A (signature and seal): ___
Party B (signature and seal): ___
___year___month___day individual Building Project Construction Contract 2
Contract issuing party: ___ (hereinafter referred to as Party A)
Contractor: ___ (hereinafter referred to as Party B)
In accordance with the "People's Republic of China "Economic Contract Law of the People's Republic of China", "Urban Planning Law of the People's Republic of China" and relevant regulations. This contract was signed after negotiation between both parties, and *** agrees to abide by it.
1. The construction area of ??the project is ___㎡.
2. Before the start of the project, Party A must make three connections and one level at the construction site and provide a complete set of construction drawings.
3. According to the national construction period quota and usage needs, the total construction period of the project is agreed to be ___ days (calendar ___ days), starting from ___ month ___ day of ___ year to __ It was completed on ___ month ___ year. If there are special circumstances during the construction process, the construction period will be postponed after negotiation between Party A and Party B.
4. Party B must undergo the on-site inspection and acceptance by the leading group before construction.
5. Party B must strictly follow the drawings for construction. Party A will conduct a design briefing or joint review before starting construction. If Party B discovers design errors and unreasonable areas during construction, it should notify Party A in advance, and Party A will contact the designer. A change notice will be issued later.
6. All building materials provided by Party A must be of qualified quality, otherwise Party B has the right to refuse to use them. The main building materials must also have quality certificates, and all materials must be delivered to the construction site. The materials purchased by Party B on their own must also meet the quality standards stipulated in this article. If a quality accident occurs during the construction of Party B, the building walls of the house (the roof must not leak or leak, the wall must be flat, and the wall must have an angle). , Party A should be reported in a timely manner and proactively take remedial measures. The design and leadership groups can also be invited to jointly study and deal with the problem.
7. From the date of completion of the project, Party B will carry out warranty for the project according to regulations.
8. Project payment details:
1. The total salary of the contractor is RMB. If you do the basic work, you will pay ___ yuan, if you do the bottom level, you will pay RMB 0.0, and if you do the second level, you will pay RMB. ___ yuan, the third floor is ready to be paid, ___ yuan is paid after the top floor is completed, ___ yuan is paid in cash after the painting is qualified, and the remaining ___ yuan is used as a guarantee deposit.
2. If a quality accident occurs during the construction process, Party B will be responsible for it.
9. Party B is solely responsible for production safety during the construction process. Party A does not bear any financial or legal responsibility for safety casualties. However, Party A must provide Party B with construction insurance, and Party B is responsible for its own construction insurance. All liability for accidents.
10. This contract is in duplicate, with Party A and Party B and the leadership group each holding one copy.
11. Once this contract is signed and takes effect by both parties, both parties must abide by it and neither party shall violate it. If a contract dispute occurs, the two parties should resolve it through negotiation. If the negotiation fails, they can apply for arbitration to the contract arbitration agency or file a lawsuit in the People's Court.
12. For matters not covered above, Party A and Party B can resolve them through negotiation or sign supplementary terms.
Party A (house builder) (signature and seal) ___
Party B (village and town craftsmen) (signature and seal) ___
___ year ___ month ___Day Personal Housing Project Construction Contract 3
Party A: ID number:
Party B: ID number:
Party A is in _ town One three-and-a-half-story house will be built in the new rural area of ??_ Village, with a floor area of ??about __m__m. The construction will be contracted by Party B. After negotiation and agreement between both parties, the following contract is signed:
1. Contracting method:
The contract shall be contracted by contracting work but not materials. Party A provides the materials needed for building the house, mainly including: red bricks, yellow sand, gravel, lime, cement, steel, etc., and connects water and electricity to the construction site (Party B is responsible for the lines behind the distribution box). Party B provides all labor services, formwork, supports, scaffolding, nails, wires and auxiliary materials and construction tools during the construction process.
2. Contract scope:
Party B shall undertake the construction in accordance with the construction drawings provided by Party A and the requirements put forward by Party A.
Mainly includes walls, beams, columns, stairs, floors, formwork, steel bars, cast-in-place concrete and floors, concrete cushions for front steps; interior decoration painting, exterior wall cement mortar painting, exterior wall tiles, and roof glazed tiles , at the same time, carry out anti-seepage treatment, cooperate with water and electricity construction, door and window construction to carry out repair work, and cooperate with Party A in the storage of materials.
3. Contract price:
According to the requirements of the construction drawings, Party B’s contract scope, construction content and Party B’s responsibilities, the total construction cost will be lump sum. The lump sum price is ___ yuan, including safety. Civilized construction measures fees and purchase of rural housing insurance premiums. (During the construction period, Party A will provide lunch and tea to Party B’s construction workers)
IV. Payment method:
Party B will enter the site and start construction x days after Party A pays __ yuan to complete the first layer of bricks Pay __ yuan when the floor is laid and pounded, __ yuan when the second floor is completed, __ yuan when the third floor is completed, __ yuan when the roof is completed, the project is fully completed, and payment will be made to __ after acceptance. Yuan, the remaining balance of __ Yuan will be used as warranty deposit after
5. Responsibilities of both parties:
Party A is responsible for the supply of water and electricity and the timely arrival of raw materials. Party B must ensure the quality of the project, carry out safe and civilized construction and purchase rural housing construction insurance, carry out construction according to the construction drawings and Party A's requirements, save materials, and keep the materials well so that they cannot be lost.
6. Quality requirements:
Party B shall organize the construction in accordance with the national housing quality standards and the construction drawing requirements provided by Party A. If the project quality is unqualified and fails to meet Party A’s requirements Party B is responsible for the rework, and Party B is responsible for the rework fees.
7. Construction safety:
Civilized construction, if Party B's construction workers are injured at work, or other accidents cause injuries to others due to construction, Party B will be responsible for everything, and Party A will not bear any responsibility or expense. . Civilized construction, pay attention to professional ethics, and pay attention to cleanliness and hygiene.
8. Construction period requirements:
The total construction period of the project is x months. Starting from the start of Party B’s entry into the site on _, Party B must complete it before the end of ___. All projects within the scope of the contract must not be delayed until _month_day at the latest. If it exceeds _month_day, Party A will impose a financial penalty on Party B. The materials required by Party B should be submitted to Party A x days in advance for rapid preparation.
9. Other matters not covered shall be resolved through negotiation between Party A and Party B.
This contract is made in two copies, with each Party A and Party B holding one copy, and it will take effect from the date of signature.
Party A’s signature (seal):
Contact number:
Party B’s signature (seal):
Contact number:
Date: xx, xx, month xx, individual house building project construction contract 4
Party A (house owner):
ID number:
< p> Address:Telephone:
Party B (construction unit):
Legal representative:
Address:
Telephone:
Party C (subsidy fund issuing unit):
In view of the serious damage to Party A’s house caused by super typhoon "Ramason", according to the "Wenchang Rural Agriculture According to the provisions of the "Reconstruction Work Plan for Household Houses Damaged by Super Typhoon No. 9", Party C, as the unit designated by the Wenchang Municipal Government to issue housing reconstruction subsidy funds, decided to grant Party A a post-disaster housing reconstruction subsidy. Now Party A has decided to rebuild the house in 3 buildings, including: main house in 2 buildings; side house in 2 buildings, with a construction area of ??3 square meters, and Party B will contract the construction. In order to ensure that the subsidy funds are paid in place and the houses are rebuilt in a timely and high-quality manner, Party A, Party B and Party C have signed this contract by consensus in accordance with the principles of voluntariness, friendship and good faith, in order to mutually abide by:
1 , Contracting method
Adopt the method of contracting (contracting work and materials/contracting work but not materials).
(1) Contracting is carried out by contracting work and materials, that is, Party B includes labor, materials, material loss, transportation, installation, quality, construction period, safety, risks, and It is a form of contract that passes the acceptance by relevant government departments, covers construction equipment, covers construction water and electricity bills, covers taxes, etc. to complete all expenses required to complete the project.
(2) The contract shall be contracted by contracting work but not materials, that is, Party A shall make preparations for three connections (water, electricity, and roads) before starting construction. After the start of construction, it is necessary to ensure that building materials are delivered to the construction site in time. Party A is responsible for water and electricity bills. Party A is responsible for deep foundation, excavation and backfilling, or it is coordinated by Party A and Party B. Party B must construct according to the drawings or Party A's requirements, and may not make any changes without permission. All tools, templates, shelves and other equipment required in the manual work will be handled by Party B. Party B must standardize the construction and standard construction, and must not cut corners.
2. Construction projects and construction standards
1. Party B shall undertake the construction in accordance with the drawings provided by Party A.
2. Party B guarantees that the house constructed meets relevant national and local quality standards and can pass the acceptance inspection by relevant government departments.
3. According to the requirements of government documents, the house built by Party B for Party A contains at least 6 square meters of reinforced concrete structure house with disaster prevention requirements, and the construction cost has been included in the total project price.
3. Contracting price
1. The project cost is RMB yuan per square meter, and the total project cost is RMB yuan (¥ yuan).
2. The above contracting unit price and total price are lump sum prices. In addition, Party A and Party C do not need to pay any other fees to Party B.
IV. Payment method
1. After the contract takes effect, Party B’s construction personnel and equipment must enter the site within days, and Party A will prepay 30% of the total project price, or RMB, to Party B.
2. After completing the capping of the main body (including at least 6 square meters of reinforced concrete structure houses with disaster prevention requirements), Party A shall pay 40% of the total project price, or RMB, to Party B.
3. After the project is completed (including the construction of a flat-roofed house of at least 6 square meters with typhoon prevention functions above the level) and has been accepted by Party A, Party C and relevant government departments, the total price of the project shall be paid. 20% is given to Party B in RMB. If there are no quality problems within one month after passing the inspection, Party A will pay Party B 5% of the total project price. After the one-year warranty expires and there are no quality problems, Party A must pay the remaining 5% of the total project price to Party B without interest.
4. After appraisal and public announcement at the three levels of town, village and villager group, Party A’s house (main house/side house) (room/head) located in the town village committee village is (collapsed/level D/ Lift the tiles). In accordance with the subsidy standards approved by the government, Party C shall issue a total of RMB yuan of housing reconstruction subsidy funds to Party A. In order to ensure that the subsidy funds can be fully and effectively used for Party A's housing reconstruction, Party C adopts the following allocation methods: p>
(1) If the roof of the house is lifted, Party C will allocate the subsidy fund to Party A in one go after the contract comes into effect.
(2) In the case of house collapse and Class D dilapidated buildings, Party C will allocate 30% of the subsidy funds to Party A after the contract takes effect, and the remaining funds will be disbursed by Party C in installments according to the city’s dilapidated building renovation funds.
5. Party A must pay Party B the project payment on time in accordance with the provisions of this agreement. When Party A fails to pay the project payment in full and on time, Party B shall not require Party C to bear joint liability or any other economic and legal liability.
5. Responsibility Agreement
1. Party A is responsible for the supply of water and electricity.
2. Party A and Party C have the right to supervise the construction work of Party B’s personnel. Party B must ensure the quality and progress of the project and construct the project according to the design drawings.
3. Party B is fully responsible for the soundness, safety and project quality of all on-site operations and construction methods.
4. If Party B fails to perform its obligations under the contract, resulting in quality accidents, construction delays, damage to life and property, and economic losses, it must bear full responsibility and compensate Party A for the economic losses suffered thereby.
5. During the construction process, any work stoppage, rework, loss of materials and equipment caused by Party B’s responsibility shall be borne by Party B, and the construction period will not be postponed.
6. Party B shall be responsible for handling any personal injury or other damage suffered by workers and other staff employed by Party B and bear legal liability such as compensation for damages.
7. Before the project is completed and accepted and delivered to Party A for use, Party B must protect the project, otherwise all economic losses caused shall be borne by Party B.
8. After the completion of the project, Party B shall clean up the site, sweep the construction site clean, and be responsible for clearing the site after the work is completed, and shall be responsible for transporting the garbage to the location designated by Party A.
9. If Party B defaults on the wages of its workers, Party A has the right to temporarily withhold the arrears from the project payment payable to Party B until Party B pays the workers in full. until. If Party B has not paid within ten days after this happens, Party B hereby promises and agrees that Party A will pay the outstanding amount directly to the workers, and the amount paid on behalf of the workers will be deducted from the project settlement amount.
6. Quality Requirements
Party B shall organize the construction in accordance with the national house quality standards and requirements. If the quality is unqualified, Party B shall be responsible for rework and the rework costs shall be borne by Party B. If Party B refuses to rework or Party B fails to rework more than 10 days after Party A proposes rework, Party A has the right to transfer this part of the project to other construction units for construction, and Party A will deduct the cost from Party B's project payment. The time for rework will be included in the construction period. If it is overdue, the overdue breach of contract liability clause will apply.
7. Safety Responsibility
1. Party B ensures labor protection measures, construction protection measures are in place, and safe construction. If Party B's construction personnel suffer work-related injuries due to their own reasons or Party B's inadequate safety protection measures, or any personal or property losses caused to others due to construction, all responsibilities shall be borne by Party B. Party B guarantees that Party A and Party C will not bear any responsibility or expense as a result. .
2. Party B ensures civilized construction, pays attention to professional ethics, pays attention to cleanliness and hygiene, protects the construction site and surrounding environment, and does not interfere with the normal production and life of nearby residents.
8. Construction period requirements
1. The total construction period of this project is days (calendar days), calculated from the date when Party B officially enters the site for construction. The specific start date shall be notified in writing by Party A shall prevail.
2. In case of heavy rain, typhoon and other severe weather, if normal construction cannot be carried out, the construction period can be postponed with the written consent of Party A.
Party B shall not unreasonably delay the completion time of Party A's house construction.
3. Party B guarantees that the project will be completed within the above-mentioned construction period and shall be accepted by Party A and relevant government departments.
9. Acceptance
1. After the project is completed, Party B shall notify Party A for acceptance. Party A shall notify the relevant government departments for acceptance within a few days after passing the inspection. After passing the inspection, Party A shall fill in the project acceptance form. .
2. After acceptance by Party A and relevant government departments, if the project content has not been completed or the quality is unqualified, Party B will rework it before acceptance, and Party B will bear the resulting expenses. Any delays in the construction period caused by this will be dealt with in accordance with the overdue breach of contract liability clause.
10. House warranty
1. Warranty shall be provided in accordance with the relevant provisions of the "Construction Project Quality Management Regulations". Party B shall be responsible for the maintenance costs caused by Party B's quality problems, and shall bear the relevant compensation and liability arising therefrom. If any project quality problems occur during the warranty period, Party B shall send personnel to provide free maintenance services within 48 hours after receiving notice from Party A.
2. During the free warranty period, Party B shall have a dedicated person responsible for the warranty work of the project. Party B's warranty personnel must ensure smooth communication and ensure that Party A can contact Party B at any time. If Party B changes the warranty personnel or contact number, Party A shall be notified promptly. If Party B delays or shirks due to poor communication or inability to contact, and more than 7 days have passed since the written notice, Party B will be deemed to have refused to assume warranty responsibility, and Party A has the right to resolve the matter on its own, and Party B will bear all costs and an additional 10% labor fee. .
Party B’s contact number: Party B’s contact person:
3. After the free warranty period ends, Party B receives a maintenance notice from Party A and shall actively carry out maintenance for Party A.
11. Force majeure
When force majeure such as earthquake, wind, rain, fire, etc. occurs, both parties must take measures to minimize losses as much as possible. Both parties should verify the losses within a reasonable time after the disaster occurs. Party A shall compensate for losses caused by force majeure.
12. Liability for breach of contract
1. Party A must use the financial subsidy funds for reconstruction/repair of the house and shall not misappropriate them for other purposes. Otherwise, Party C has the right to recover the lost property. Make payment.
2. If Party A pays Party B’s project payment overdue, Party A shall pay Party B a penalty of 3‰ of the unpaid amount due for each overdue day.
3. If Party B fails to complete the project on time with good quality and quantity, Party A shall pay Party A a liquidated damages of 3‰ of the total project price for each day overdue; if Party B is overdue for more than 15 days, Party A has the right to terminate this contract. At the same time, Party B shall pay Party A a liquidated damages of 30% of the total project price.
4. If Party B violates other provisions of this contract, Party A has the right to make rectifications within a time limit. If Party B fails to make rectifications within the limited time limit or the rectifications are ineffective, Party A has the right to terminate the contract. At the same time, Party B shall report to Party A Party B shall pay 30% of the total project price as liquidated damages. If the liquidated damages are insufficient to compensate for Party A’s losses, Party B shall continue to compensate.
5. Party C has fulfilled all its obligations under this contract by allocating house reconstruction subsidy funds to Party A in full and in a timely manner as agreed. The rights, responsibilities and disputes between Party A and Party B have nothing to do with Party C. Neither Party A nor Party B shall claim any other rights against Party C or require Party C to bear any liability for breach of contract or compensation.
13. Others
1. If any dispute arises during the performance of this contract and all agreements related to this contract, Party A, Party B and Party C shall resolve it through friendly negotiation; if the negotiation fails, the three parties shall You can file a lawsuit with the People's Court where the housing construction project is located.
2. Other matters not covered shall be resolved through consultation among the three parties and shall be strictly implemented in accordance with national and local standards.
3. This contract is made in triplicate, with Party A, Party B and Party C each holding one copy, and it shall take effect from the date of signing.
Party A (signature): Party B (seal): Party C (seal):
Representative (signature): Representative (signature):
Signing date: Year, month and day
Signing place: Individual house building project construction contract 5
Party A (contractor):
Party B (contractor):
Party A contracts its own house (story addition construction project) located in XXX to Party B. After negotiation between the two parties, the following agreement was reached:
1. Contracting method:
Contracting shall be carried out by contracting work and materials. Party A provides the land and drawings for building the house, and Party B is responsible for the following: red bricks, river sand, gravel, lime, cement, steel, water pipes, sewer pipes, nails, wire, water and electricity, etc. Party B provides labor services, construction technology, formwork, support trees, scaffolding materials, yard nails, production and living utensils, etc.
2. Construction projects:
Party B shall undertake the construction in accordance with the design drawings or the requirements put forward by Party A. The construction of the main project of Party A's house, including walls, beams, columns, stairs, floors, formwork installation, removal of formwork, reinforcement, cast-in-place concrete and ground, concrete cushion for front steps; decoration of indoor rough painting, rear wall Flour cement mortar is required to make the interior and exterior walls smooth with cement mortar, and the floor is clean and smooth; three wires and two pipes are laid out, namely, electric wires, TV cables, network cables, sewer pipes for toilet toilets and downpipes on the roof; the top layer is added The slurry is polished and anti-seepage treatment is done at the same time.
3. Contracting price:
____ yuan per square meter, calculated in RMB (uppercase: two hundred seventy thousand and two thousand round).
IV. Payment method:
From the date this contract is signed and takes effect, Party A shall pay Party B a lump sum of _ yuan within the same day for material preparation and construction fees. Before the project is completed and accepted, Party A may reserve a balance of _10_% of the total project cost, which will be fully paid after the project is completed and accepted.
V. Quality requirements:
1. Party B shall construct according to the engineering design drawings and Party A’s requirements. Without Party A’s consent, Party B shall not change the construction requirements without authorization.
2. After Party B completes the foundation and the reinforcement of beams, columns and slabs on each floor, Party A will organize relevant personnel to conduct quality supervision and acceptance. Only when the standards are met can the next step of construction be carried out. If rework is caused by Party B, Party B will be responsible for rework materials and other costs.
3. During the construction process, Party B shall not cut corners or use inferior materials.
4. The pouring of beams, columns and floors must be completed at one time.
5. After the project is completed, Party A will organize relevant personnel to conduct inspection and acceptance according to the construction technical requirements. If there are construction quality problems, Party B will renovate them until they meet Party A’s quality requirements, and compensate Party A for all losses caused by construction quality problems. The cost of re-repairing (including the cost of repair work and materials) shall be borne entirely by Party B.
6. The construction quality problems mentioned in the above article include the following aspects:
(1) The lines are blocked;
(2) The main wall and the level The ground is not vertical, the walls are uneven and cracked;
(3) The main column is not vertical to the horizontal ground, broken, and the reinforcement is exposed;
(4) The cross beams and ring beams are broken and exposed Reinforcements and obvious distortion;
(5) The ceiling or floor is cracked, collapsed, exposed, and not perpendicular to the horizontal plane;
(6) Beams, columns, and slabs are hollow; < /p>
(7) The mortar on the walls and roof fell off;
(8) The roof leaked and was soaked in water.
6. Pay attention to safety:
Civilized construction, if Party B's construction workers are injured at work, or other accidents cause injuries to others due to construction, Party B will be responsible for everything, and Party A will not bear any responsibility or expense. . Civilized construction, pay attention to professional ethics, and pay attention to cleanliness and hygiene.
VII. Construction period requirements:
The construction period of the main project is ____
The main project must be completed before ____ month ____, and the completion time cannot exceed ____ Days later, Party B cannot delay the completion of Party A's house construction due to various reasons (except for special circumstances), and appeals to hold Party B responsible for breach of contract.
8. Quality warranty period:
Party B must adhere to the policy of "a century-old plan, quality first" when organizing construction, and require all projects to meet qualified standards; roof waterproofing projects , the leakage prevention of bathrooms, rooms and exterior walls is for 1 year.
9. Calculation of project costs:
1. The project contracting method is labor and material contracting, and the calculation is based on the actual construction area.
2. The water and electricity bills during the construction process shall be borne by Party A.
3. The construction workers shall bear their own food and lodging expenses. The rest shall be settled to Party B.
(Note: The above payments shall be made after the project is accepted and accepted, and no loans will be made during the construction period)
5. The project deposit shall be paid to Party B after the expiration of the project warranty period.
10. After the completion of the project, Party B is responsible for removing and cleaning up all construction waste around the construction site and indoors.
11. Liability for breach of contract: Any violation of the above terms is a breach of contract, and the breaching party must compensate the non-breaching party for liquidated damages, which is 30% of the total cost, plus losses.
This contract is made in triplicate, with Party A and Party B each holding one copy, and the guarantor shall keep a copy. This contract shall come into effect on the date it is signed by Party A and Party B. Other matters not covered shall be resolved through negotiation between Party A and Party B.
Party A (signature): Party B (signature):
ID number: ID number:
Year, month, day, year, month, day
Guarantor (signature):
Year, month and day
- Previous article:What skin care products should I use at the age of 30?
- Next article:Weather in Shexian County, Huangshan City, Anhui Province
- Related articles
- Composition of "Red Balloon"
- Hainan weather
- Is the Flame Mountain in Xinjiang cold in winter?
- Is Xiangxi hot or not?
- Is it hot in Qingdao?
- Summary of the work of kindergarten middle class in March
- What’s the matter with palpitations, shortness of breath, and general weakness?
- When can Huangshan see the sea of clouds?
- How to see through each other's psychology?
- How to apply for weather forecast?