Traditional Culture Encyclopedia - Hotel reservation - Simple contract for hotel catering decoration
Simple contract for hotel catering decoration
In a society where people pay more and more attention to law, the position of contract can not be ignored. Signing a contract can clarify the rights and obligations of both parties. So how to write the relevant contract? The following is a simple renovation contract model of hotel catering compiled by me for your reference only. Let's have a look.
Simple Hotel Catering Decoration Contract 1 Party A: (Hotel)
Party B: (Construction Party)
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of hotel decoration engineering construction, both parties (hereinafter referred to as Party A) have reached the following agreement on matters related to hotel decoration engineering on the basis of equality, voluntariness and consensus:
Article 1 General situation of the project
1. 1 Project location: _ _ _ _ _ _ _ _ _ _.
1.2 project contents and practices (see attached table 1: hotel decoration project construction project confirmation table for details). Schedule 2: List of Contents and Practices of Hotel Decoration Works).
1.3 project contracting mode: both parties agree to adopt the following contracting mode.
(1) contracting and materials.
1.4 The construction period of this project is _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1.5 contract price: the project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 3 Obligations of Party A
4. 1 Create conditions for Party B to enter the site for construction _ _ days before commencement. Including: demolition of indoor furniture and furnishings, or stacking and covering indoor furniture and furnishings that are not easy to move on the principle of not affecting construction;
4.2 Provide water and electricity supply during construction;
4.3 Responsible for coordinating the relationship between the construction team and the hotel departments;
4.4 During the construction period, Party B shall be responsible for the public security and fire control work on the construction site;
4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance. Article 4 Obligations of Party B
5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;
5.2 Strictly implement the management regulations of the construction site, without disturbing the people and polluting the environment;
5.3 Protect the furniture and furnishings in the original hotel and ensure the smooth flow of water pipes and pipes in the hotel;
5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed.
Article 5 Engineering changes
If it is necessary to change the project and construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see Annex Change Order for Hotel Decoration Project). Article 6 The construction period shall be postponed.
8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party B:
(1) engineering quantity change and design change;
(2) Force majeure;
(3) Other circumstances in which Party A agrees to postpone the construction period.
8.4 If the construction period is affected by Party B's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed. Article 9 Quality standards
Both parties agree that the construction quality standard of this project is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer.
Article 10 Project Acceptance and Warranty
10. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:
( 1)_________________________;
(2)_________________________;
10.2 After the completion of the project, Party B shall notify Party A for acceptance, and the Employer shall organize acceptance within two days after receiving the acceptance notice, fill in the project acceptance form, and go through the handover procedures after the project payment is settled.
10.3 The warranty period of this project is _ _ months from the date of acceptance and signature by both parties. After acceptance and signature, fill in the project warranty form.
Article 11 Method of payment for project funds
1 1. 1 Both parties agree to pay the project payment according to the following method:
(1) After the contract comes into effect, Party A shall directly pay the project funds to the contractor according to the following table: | First time | Commencement Date | Payment Yuan || Second acceptance by both parties | Payment Yuan |.
1 1.3 After all the project payment is settled, Party B shall issue a receipt for the project payment to Party A. ..
Article 12 Liability for breach of contract
12. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for the economic losses.
12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses. ...
12.5 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the construction period will not be postponed.
12.6 If the construction period is delayed due to Party B's reasons, Party B shall pay the liquidated damages of RMB yuan to the other party for each day of delay.
Article 13 Settlement of Contract Disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:
(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;
(two) to bring a lawsuit to the people's court according to law.
Some specific provisions of Article 14
14. 1 The garbage generated by the project construction shall be transported out of the construction site by Party B and transported to the designated place.
Article 15 Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 16 Supplementary Provisions
16. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.
16.2 after the signing of this contract, the project shall not be subcontracted.
16.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract.
Party A:
Party B:
date month year
Simple Hotel Catering Decoration Contract 2 Party A: (hereinafter referred to as Party A) _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
In order to complete this project, Party A originally contracted this project to Party B for about square meters, and both parties signed this agreement based on the principles of equality, mutual benefit, consensus through consultation, equality, voluntariness, fairness and good faith, and combined with the specific conditions of this project.
I. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project address
Three. Building area: about _ _ _ _ _ _ _ _ square meters.
Verb (abbreviation of verb) Contract method: contracting for work and materials.
Construction cost of intransitive verbs: RMB _ _ _ _ _ _ _ _ _ yuan/square meter including tax.
Seven. Term of the contract: the total number of days is _ _ _ _ _ _ _ _ _, counting from the date when Party A issues the notice of commencement. Delay due to force majeure.
Eight. Project nature: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Nine, the final accounts of both parties are based on the actual acceptance of both parties.
10. Party B is responsible for the pressure test work and expenses of the materials needed for the project, and Party A is responsible for coordinating the test data and handing them over to Party A for unified management.
XI。 Specific requirements in construction
1. quality requirements: the quality of this project shall be subject to the signature and seal of the state and the owner, the specific requirements of Party A, and the acceptance of the owner, supervision company and relevant functional departments.
2. Safety responsibility: During the construction process, Party B shall carry out the construction in strict accordance with relevant national standards and safety technologies, so as to achieve civilized construction, clean and tidy site and perfect and appropriate safety measures. During the construction, Party B shall be responsible for all safety accidents within its contracted scope.
3. Estimation and payment method: The estimation is based on the actual quantities collected by Party A and Party B on site. After the signing of this agreement, Party B shall pay Party A RMB _ _ _ _ _ _ _ _.
4. Time limit requirements: Due to the tight time limit and heavy tasks of this project, Party B must carry out the construction in strict accordance with the requirements of Party A's construction progress, and shall not stop work or delay the construction period under any excuse. If the above situation occurs, it will constitute a breach of contract, and Party B shall pay _ _ _% of the total project cost to Party A as liquidated damages, and Party A has the right to terminate the agreement, and all its losses shall be borne by Party B. ..
Twelve. When signing this agreement, Party B shall pay Party A a performance bond of RMB _ _ _ _ _ _ _ _.
Thirteen. Liability for breach of contract: If one party breaches the contract, the breaching party shall compensate the other party for all losses caused.
14. Matters not covered in this contract shall be settled by both parties through negotiation. This Agreement is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (signature/seal): _ _ _ _ _ _ _ _ _ _ Party B (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Simple Hotel Catering Decoration Contract 3 Entrusting Party (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project: _ _ _ _ _ _ _ _ _ _ _ _ _
Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the facade house. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.
Rule number one. Project overview
1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The construction area is _ _ _ _ _ _ _ _ square meters.
3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1), the removal of the intermediate partition wall shall not affect the original fire fighting and load-bearing columns and beams of the main structure.
2) Decorate the ceiling, dado, floor tile, wood floor and decorative lines of the whole hall without destroying the original ceiling.
3) Add _ _ _ _ rooms and decorate the hall.
4) Party B shall reasonably plan and decorate the kitchen according to Party A's requirements.
5) The billboard and bar on the facade shall be decorated according to Party A's wishes.
6) A vegetable washing pond, fish pond and sunshade shall be built behind the kitchen.
7) Improve all water and electricity facilities in the store.
4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Total days of the project: _ _ _ _ _ _
Article 2, the project price
The project price (amount in words) is _ _ _ _ _ _ _ _.
Article 3, Quality Requirements
Party B's construction must be carried out in strict accordance with Party A's requirements.
Article 4. terms of payment
After the project is completed and accepted by Party A, all the money shall be paid.
Article 5. responsibility for breach of contract
1. Party B must complete the project within the project period, otherwise Party A has the right to refuse to pay the project payment and hold Party B accountable.
2. If Party B's construction does not meet the quality requirements, Party A has the right to order Party B to take full responsibility.
Article 6. Modification of contract
After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation.
Article 7. Entry into force of contract
1. This contract shall be sealed by both parties and come into force after being signed.
2. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (signature/seal): _ _ _ _ _ _ _ _ _ _ Party B (signature/seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
;
- Related articles
- Composition by fifth grade primary school students
- Suzhou Pingjiang Road Food Guide
- I plan to go to Wuxi on National Day. Q: Which is closer to the Three Kingdoms Studios, the Millennium Hotel in Wuxi, the Jal Hotel or the Hilton?
- How about Zhonghai Jinyuan? OK or not? Is it worth buying?
- Super 8 Hotel near Xi 'an Bell Tower
- How to get from Shenzhen Baoan Airport to Shenzhen Qian 'an International Hotel?
- From the four core elements of homestay design, talk about how to make a homestay.
- Copy hotel room card with nfc mobile phone
- Computer configuration of e-sports hotel
- Announcement on Temporary Adjustment of Foshan Qiao 17 and Other Lines