Furniture ordering contract

My friends, the so-called liability for warranty of defects is the legal liability of the seller for the rights on the subject matter or the defects of the object. I am here to share some furniture ordering contracts with you, hoping to help you.

Article 1 of the furniture ordering contract Buyer: (hereinafter referred to as Party A) Seller: (hereinafter referred to as Party B)

In accordance with the requirements of the Procurement Law of People's Republic of China (PRC), the Civil Code of People's Republic of China (PRC) and the bidding documents, and in order to clarify the rights and obligations of both parties, this contract is hereby concluded through negotiation on the principle of equality, mutual benefit, honesty and credibility.

I. Contents of product orders

* * * Total RMB cost of the above products.

Second, the contract amount

1 The total contract amount is RMB in words: 2 The total contract amount includes transportation, installation fees and tax-included points.

The goods must be installed, debugged and accepted.

The price is fixed.

Three. Delivery time, place and installation method:

Previously, goods were transported to all locations above the town and installed.

Party B is responsible for delivery to the address designated by Party A and installation.

If the installation location exceeds this range, the installation fee will be increased as appropriate.

Fourth, packaging.

The packaging is intact and the goods are not damaged.

Verb (abbreviation of verb) payment terms

1. After the delivery and installation are completed, Party A shall pay Party B 100% of the total contract price. 2. Party B must issue a valid regional invoice when receiving the payment.

The warranty period and after-sales service requirements of intransitive verbs

The quality guarantee period of furniture is not less than one year, and it will be calculated after the project acceptance.

Party B shall be responsible for solving the quality problems that occur during the quality guarantee period free of charge (except for failures caused by improper use of Party A or other human factors).

During the warranty period, Party B shall provide free on-site service.

After the warranty period, Party B shall provide Party A with a lifetime warranty period. During the warranty period, Party B shall provide technical consultation and maintenance free of charge. If the faulty parts need to be replaced, only the preferential parts fee will be charged.

7. This contract is made in triplicate, two for Party A and one for Party B, which shall come into effect after being signed by both parties and have the same legal effect.

Party A (seal): Party B (seal):

Legal representative or authorized agent (signature):

Legal representative or authorized agent (signature):

Address: Address:

Tel: Tel:

Fax: Fax:

Date: Year Month Day Date: Year Month Day

In order to safeguard the legitimate rights and interests of both parties to the contract, according to the Civil Code of People's Republic of China (PRC) and relevant regulations, Party A and Party B have reached the following terms on the purchase and sale of ordered furniture through consultation.

1. Name, quantity and amount of furniture

1. Details of the ordered goods:

Please refer to the quotation for product name, model, specification, color, quantity and unit price.

The total amount of goods ordered is::. Not including tax.

Second, the mode of payment.

After signing this contract 1%:

The balance of 2% shall be paid by Party A after Party B completes the production, and Party B receives the payment and delivers the goods.

3. The balance is RMB, which shall be paid by Party A within half a year after acceptance.

Third, the delivery date.

1. After receiving the advance payment paid by Party A and signing relevant technical requirements such as drawings, color plates and cloth boards,

2. Party B's commitment to the above delivery date is based on Party A's timely payment of advance payment and Party A's confirmation of relevant technical requirements such as drawings, color plates and cloth boards. If the above delay occurs, the delivery date will be delayed.

Four. Delivery method, place and acceptance:

1. Party B is responsible for delivering to:

2. The acceptance criteria for Party B's door-to-door installation shall be based on the drawings and written descriptions approved by both parties.

3, process acceptance requirements:

After the wooden foundation is completed, Party A and Party B shall not paint until they are qualified.

Paint color samples need to be checked by both parties.

The gloss of the paint needs to be checked by both parties.

Verb (abbreviation of verb) quality assurance

1. Party B provides a one-year warranty for the goods sold. During the warranty period, if the product cannot be used normally due to quality problems, Party B shall be responsible for the maintenance, and the expenses shall be borne by Party B. ..

2. Maintenance after the warranty period shall be charged as appropriate.

3. During the warranty period, if the product is damaged for reasons other than product quality, Party B shall charge maintenance fees as appropriate.

Liability for breach of contract of intransitive verbs

1. If Party A's payment is overdue for more than seven days, Party B has the right to collect liquidated damages at the rate of two thousandths of daily payables.

2. If Party B delays the delivery for more than seven days, except for force majeure, Party A has the right to collect liquidated damages at the rate of two thousandths of the undelivered amount every day.

Seven. contract

Purchase orders, bills of lading, acceptance sheets, quotation sheets, design drawings and other relevant documents related to this contract are all contracts.

Eight. Changes to this contract shall be reached in writing through negotiation between both parties.

Nine. This contract shall be governed by the laws of People's Republic of China (PRC). In case of any dispute, both parties shall actively negotiate and solve it. If negotiation fails, it may be submitted to the arbitration commission where the plaintiff is located for arbitration.

X this contract is made in duplicate, with each party holding one copy, and shall come into force after being sealed by both parties.

Party A:

Party B:

Date, year and month

Article 3 of the Furniture Order Contract Party A:

Address:

Contact person:

Telephone:

Fax:

Party B:

Address:

Contact person:

Telephone:

Fax:

In accordance with the relevant laws and regulations of People's Republic of China (PRC), the Contract Law of People's Republic of China (PRC) and the principle of equality and mutual benefit, Party A and Party B have reached the following agreement through friendly negotiation for mutual compliance.

1. Party A will hand over the curtains of the conference room window on the second floor of the office to Party B for fabrication and installation.

2. Style: PVC vertical louvers are used for the external windows to ensure that the style, color and material are consistent with those installed in the previous batch. The aisle adopts 2.5cm light blue aluminum alloy venetian blinds.

Third, the price: 70 yuan/square; 78.78 square meters; Total preferential price: 5500 yuan. The above price includes tax, installation fee and all other fees.

Four. Settlement method: both parties shall settle the account within 7 working days from the date of acceptance of the goods after installation (acceptance within 3 working days after installation). Party B shall provide legal and valid invoices 3 working days before payment by Party A. If Party B delays providing invoices, the payment period of Party A will be postponed.

5. Delivery date: Party B shall install all curtains before May 25th, 20__. If the construction period needs to be extended due to Party A's reasons, the installation shall be completed within 10 days from the date when Party A re-notifies the installation.

6. Quality requirements: Party B shall supply the curtain in the color selected by Party A .. The inside and outside, the surface and the curtain are the same color, without fading or noise; Curtains have good elasticity and moderate softness; Curtain width is consistent with window width and wall height; The curtains are smooth, the curtains are stretched evenly, and the exhibition is natural and beautiful. Other quality requirements shall be subject to the national industry quality standards and Party A's actual use requirements.

Seven. Scope of service: Party A shall cooperate with Party B to make preparations before installation. The warranty period of the product is one year (except intentional damage, normal use damage shall be guaranteed), and the warranty period shall be counted from the date when the installation is completed and accepted by Party A. During the warranty period, if there is any quality problem, Party B shall complete the repair or replace the new product free of charge within the time specified by Party A. The warranty period after repair and replacement shall be recalculated.

Seven. Liability for breach of contract:

1. If Party B delays delivery (including installation, maintenance and re-delivery), Party B shall pay a penalty of 5% of the total price/day. If the overdue period exceeds 5 days, Party A has the right to terminate the contract, and Party B shall pay a penalty of 65,438 yuan+0,000 yuan.

2. If Party A delays payment, it shall pay a late fee of 5% of the total price/day.

3. If the curtains (including installation) have quality problems or cannot meet the actual needs of Party A, Party B shall re-deliver them within 3 days from the date of receiving Party A's notice. If the quality problem occurs again when the goods arrive again, Party B will be regarded as a serious breach of contract. Party A has the right to terminate the Contract, and Party B shall pay the liquidated damages of 20 yuan.

Eight. Acceptance criteria, methods and time limit for raising objections: acceptance within three days after installation, and Party B shall notify Party A of acceptance. If there is any objection, it should be raised within 7 days.

Nine. Ways to resolve contract disputes: If there are any objections, both parties shall settle them through consultation on the principle of friendship and mutual benefit; If no agreement can be reached, both parties have the right to bring a lawsuit to the people's court for settlement.

X. For matters not covered in this contract, a supplementary agreement can be signed after both parties reach an agreement through consultation, and the supplementary agreement has the same legal effect as this contract after signing.

XI。 This contract is made in duplicate, one for Party A and Party B respectively. It will come into effect on the same day after being signed and sealed by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 4 of the furniture ordering contract Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

Party A and Party B have reached the following agreement on ordering office furniture from Party B through friendly negotiation:

1. Name, specification, quantity, price, etc. Office furniture (with price details), layout and style (with drawings) required by Party A..

Two. Total contract amount (in words) (in figures) ￥:.

Three. Date of signature: year month day.

Four. Delivery date: the delivery date is days. In other words, the goods arrive on a certain day of the year.

Verb (abbreviation for verb) Supply location:.

Mode of transportation of intransitive verbs: (in figures) ￥:. After the goods are installed and accepted by Party A, 70% (RMB) (in words) of the balance shall be paid. If Party A breaches the contract unilaterally, the advance payment will not be refunded, and the money involved in this contract will be denominated in RMB.

Eight. Liability for breach of contract: Party A shall pay the payment according to the time stipulated in the contract between the two parties, and Party B shall guarantee the timely delivery. Party A shall not delay the acceptance time without reason. If Party A fails to accept the goods within seven days after installation, it shall be deemed as qualified. If the unilateral breach of contract is delayed, the other party shall compensate the losses on a daily basis: if the delay is within 7 days, the compensation shall be 2% of the total amount per day. If the payment is delayed for 7 days to 10 days, 3% of the total payment will be compensated for each day of delay. If the payment is delayed for more than 10 days, the compensation shall be 5% of the total payment for each day of delay. Until the payment and liquidated damages are all settled.

Nine. Other responsibilities: Party B guarantees to abide by the contract and supply furniture according to the specifications, quantity and time required by the contract. At the same time, Party A shall pay the payment according to the agreement of both parties and the contract. Party A shall not delay payment without reason. When Party B delivers the goods, Party A shall not put forward requirements inconsistent with the contents of the signed contract. If Party A requests to change the style and specification, both parties shall settle it through consultation on the premise of protecting the interests of both parties.

X. After-sales service: Party B provides Party A with one-year warranty period and lifetime free maintenance service.

XI。 Other matters: After the contract is signed, both parties shall abide by it, and unilateral breach of contract shall be handled according to the relevant provisions of People's Republic of China (PRC) Contract Law. Matters not covered in this contract shall be settled by both parties through consultation. This contract is made in duplicate, one for each party. This contract shall come into effect immediately after it is signed (signed or stamped with the official seal of the unit).

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 5 of the furniture ordering contract Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

Through friendly negotiation, Party A and Party B have reached the following agreement on ordering furniture from Party B:

1. See the annex for the furniture style name, specification, quantity, price and pictures required by Party A; See the drawings provided by Party A for the furniture installation layout.

Two. Total contract amount (in words) (in figures) ￥:.

Three. Date of signature: 20 _ _ _.

Four. Delivery date: the delivery date is days. In other words, the goods arrive on a certain day of the year.

Verb (abbreviation for verb) Supply location:

Transportation and packing method of intransitive verbs: Party B is responsible for transportation to Party A's supply place; Party B is responsible for site installation.

Seven. Payment terms:

After signing the contract, Party A shall pay the advance payment of 10%, with the amount (in words): (in figures) ￥; After the goods are installed and accepted by Party A, 85% of the payment shall be paid, with the amount (in words): (in figures) ￥:; The remaining 5% is the quality guarantee. If there is no quality problem, it will be paid to Party B one year later. If Party A breaches the contract unilaterally, the advance payment will not be refunded.

Eight. Liability for breach of contract: Party A shall pay the payment according to the time stipulated in the contract between the two parties, and Party B shall guarantee the delivery on time, and Party A shall not delay the acceptance time without reason. If Party A fails to accept the goods within seven days after installation, it shall be deemed as qualified; If it is damaged or inconsistent with the contract, Party B promises to complete the replacement within one week, otherwise it will be deemed as unqualified and bear the liability for breach of contract. If the unilateral breach of contract is delayed, the other party shall compensate the losses on a daily basis: if the delay is within 7 days, the compensation shall be 2% of the total amount per day. If the payment is delayed for 7 days to 10 days, it shall be compensated by 3% of the total payment every day; if the payment is delayed for more than 10 days, it shall be compensated by 5% of the total payment every day. The liquidated damages shall be based on this contract.

The agreed total payment amount is limited.

Nine. Other responsibilities: Party B promises to abide by the contract, supply furniture according to the specifications, quantity and time required by the contract, and Party A pays the payment according to both parties and the contract. Party A shall not delay payment without reason; When Party B delivers the goods, Party A shall not put forward requirements inconsistent with the contents of the signed contract. If Party A requests to change the style and specification, both parties shall settle it through consultation on the premise of protecting the interests of both parties.

X. After-sales service: Party B shall provide Party A with one-year warranty period and lifelong maintenance service, and the expenses shall be borne by the producer. XI。 Other matters: After the contract is signed, both parties shall abide by it. If negotiation fails, a lawsuit can be brought to the people's court where Party A's project is located.

12. This contract is made in duplicate, with each party holding one copy. This contract shall come into effect immediately after it is signed (signed or stamped with the official seal of the unit).

Party A: Party B:

Representative of Party A: Representative of Party B:

date month year

Article 6 of the furniture ordering contract Name of Party A: Contact person:

party B

Name:

Party A orders furniture from Party B, and this purchase contract is determined through friendly negotiation between both parties.

I. Purchasing goods

See the attachment for the list of goods.

Second, the transaction price

The unit price of the goods can be found in the attached list of goods. Total price of goods:1130,000 delivery fee: 60,000 contract price:1190,000.

Three. terms of payment

1. Advance payment: 40% will be paid after the contract is signed.

2. Final payment: Party B shall deliver the goods in batches, and pay off all the payment within three working days after Party A's acceptance.

Fourth, the delivery time.

The delivery time of the last batch shall be no later than April 28th, 20__

Verb (abbreviation of verb) Delivery place: Party A designates (Guangzhou, Guangdong Province) VI. The rights and interests of both parties.

1, Party A's rights and interests

(1) Party A has the right to determine the place of delivery (Guangzhou only).

(2) Party A has the right to request the quality of the goods.

(3) Party A has the obligation to determine who will sign for the goods and notify Party B in advance. (4) Party A is obliged to pay the advance payment and settle the balance of the delivered goods within three working days after the delivery of the goods.

2. Party B's rights and interests

(1) Party B has the obligation to guarantee the quality of the goods.

(2) Party B is obliged to deliver the goods to the place designated by Party A (Guangzhou only). (3) Party B has the right to ask Party A to pay the advance payment and the balance after delivery. Seven. Party B's account number:

1. Company name: Guangzhou Hongda Furniture City 2. Bank of deposit: 3. Account number: 8. Special instructions.

1. There may be some slight errors between the goods delivered by Party B to Party A and the proposal submitted to Party A, including but not limited to the dimensions and curves. Party A acknowledges this error, but the error cannot exceed 5%. More than 5% will be regarded as unqualified products.

2. Under the dry air in the north, it is inevitable that the solid wood furniture will be slightly cracked or deformed after being used for a long time. Party B promises to provide a one-year warranty period for Party A's furniture.

Nine. breach clause

1, if the product quality is defective and cannot be remedied after being reminded by Party A, Party B shall be deemed to have breached the contract. ..

2. Party B's failure to deliver the goods according to the delivery time stipulated in the contract shall be regarded as Party B's breach of contract. For each day of delay, Party A has the right to deduct 1‰ of the final payment as liquidated damages.

3. The delay in delivery caused by Party A's failure to provide cloth according to the time stipulated in the contract is not a breach of contract by Party B. ..

4. The delay in delivery caused by Party A's failure to arrange the contracted personnel and delivery place as agreed in the contract shall not be regarded as Party B's breach of contract.

5. If Party A fails to pay the final payment within three working days after the delivery of the goods, it will be deemed as a breach of contract by Party A, and Party B has the right to demand Party A to pay the liquidated damages, that is, 1‰ of the final payment for each day of delay.

X. force majeure clause

Force majeure refers to unforeseeable events, such as earthquake, typhoon, flood, fire and war. , which directly affects the performance of this contract or cannot be performed according to the agreed conditions. The party in case of force majeure shall immediately notify the other party and provide the other party with the details of force majeure and relevant supporting documents within fifteen days. In case of force majeure, Party A and Party B shall negotiate to find a reasonable solution and make every effort to mitigate the consequences of force majeure. If the force majeure event lasts for 30 days, Party A and Party B shall solve the problem of whether to continue to perform or terminate this contract through friendly negotiation.

XI。 Entry into force and termination of contract

The effective date of this contract is the date when the advance payment arrives after the signature of the authorized representatives of both parties to this contract. This contract shall be terminated after Party B delivers the goods and Party A pays the final payment. Twelve. settlement of dispute

The validity and performance of this contract and its amendments and all matters related to the validity of this contract and its amendments shall be governed by the laws of People's Republic of China (PRC), and any dispute shall be governed only by the laws of People's Republic of China (PRC). Any dispute arising from the interpretation or performance of this contract between Party A and Party B shall be settled first through friendly negotiation, which shall be settled within 30 days. If negotiation fails, either party may submit the dispute to the local arbitration commission for arbitration according to its arbitration rules. The arbitration decision is binding on both parties. During the dispute arbitration, Party A and Party B shall continue to perform their obligations and exercise their rights stipulated in this contract except for the disputed matters.

Thirteen. Contract confirmation

This contract is made in duplicate, one for each party, and shall come into effect as of the date when the authorized representatives of both parties sign it.

Party a and party b: MM DD YY:

Article 7 of the furniture ordering contract Party A (the buyer):

Address:

Contact telephone number:

Party B (supplier):

Address:

Contact telephone number:

After careful negotiation, Party A and Party B have reached the following agreement on ordering a batch of furniture from Party B, and hereby conclude this order contract.

I. Goods ordered:

Style:

Quantity:

Materials:

Amount (yuan):

2. Quality requirements: the samples confirmed by both parties shall prevail.

Three. Payment for goods: the total amount is RMB _ _ _ _ _ _ _ _.

Four. Inspection, acceptance and delivery

1. The acceptance of finished products is based on the products, drawings and materials confirmed by both parties.

2. Inspection of semi-finished products, acceptance of finished products and delivery of products shall be carried out at Party B's place.

3. Party B will start the installation on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. After the delivery date expires, if Party A fails to deliver the goods on time for more than _ _ _ days, Party B may keep the goods for Party A. The storage fee shall be charged at/day of the total contract price.

Verb (abbreviation for verb) transport, carry and install.

1, and Party B shall be responsible for the expenses. Party B is responsible for the installation.

2. Party A shall clean up the installation site in advance (the site shall be flat) so that Party B can install it in time after the goods arrive. Party A's failure to clean up the installation site within _ _ _ days after the arrival of the goods will be deemed as all qualified.

3. The installation and acceptance procedures signed by users of furniture products (such as hotels and hotel office buildings) have legal effect on Party A. ..

Liability for breach of contract of intransitive verbs

If the payment agreed in this contract is overdue, Party A shall pay liquidated damages to Party B at the rate of _ _ _ _ _ _.

For the timely delivery of 1, Party A will charge Party B a penalty of% of the corresponding product price every day.

2. Before Party A pays the payment, liquidated damages or other corresponding funds, Party B has the right to detain or take back the products of corresponding value ordered by Party A. If Party B fails to pay within _ _ _ days after receiving the payment, Party B may dispose of the products by itself, and Party A shall bear the responsibilities.

Seven. alteration of contract

1. After the signing of this contract, neither party shall change the contract without authorization, and the change of the contract shall be valid only after confirmation by both parties.

2. Party A shall bear the loss of Party B's materials or labor costs caused by Party A's modification of the contract.

3. Product changes or other explanations must be stamped with the official seal or signed by the handler in written form, which have the same legal effect.

Eight, quality warranty

1. Party B will maintain the delivered products for one month. During the warranty period, if the product has general quality problems, Party B shall be responsible for the maintenance; If there are major quality problems, Party B can replace them.

2. The warranty of the product is limited to the quality problems during normal use. Damage caused by abnormal use, maintenance, maintenance, transportation and other human factors, or damage caused by force majeure, are not covered by the warranty. However, if Party A pays the cost of materials and labor, Party B can repair it in time.

Nine. supplementary terms

1. There are _ _ _ _ _ _ _ _ _ clauses in this contract.

2. Matters not covered in this contract can be supplemented by both parties separately, and the supplementary agreement has the same legal effect as this contract.

3. Any dispute arising from this contract can be settled by both parties through friendly negotiation. If negotiation fails, they can bring a lawsuit to the court.

Party A:

Date of signing:

Party B:

Date of signing: