Individual housing renovation contract format 5.

Renovation contract format of individual house 1

Employer (Party A):

Contractor (Party B):

In accordance with the Contract Law

Individual housing renovation contract format 5.

Renovation contract format of individual house 1

Employer (Party A):

Contractor (Party B):

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction project of this construction project and signed this contract, which shall be kept in good faith.

Article 1 General situation of the project

1, project name:

2. Project location:

3. Engineering quantity: subject to the contract budget table. If the engineering quantity changes, the actual engineering quantity shall prevail.

4. The contracting method shall be implemented according to the following terms.

(1) contract works and materials (2) excluding contract works and materials (3) contract works; Partial package (4) package; Some contractors

The second construction section

1, starting date: YY.

2. Completion date: MM DD YY.

3. Total working time of the project: days (excluding the time for extending the construction period).

Article 3 Project Price

The total cost of this project is (in words) (RMB).

Rmb: yuan

Note: This price is the basis of project settlement and is calculated according to the actual workload.

Article 4 Project Quality

The quality of this project shall be implemented according to the following terms.

(1) National standards (2) Local standards (3) General industry standards (4) Party A's special standards.

Article 5 Drawings

1. The following terms and conditions are adopted by both parties through consultation.

(1) Party A entrusts Party B to design the construction drawing, and the design fee is RMB (in words), which is not included in the total project price;

(2) Party A shall provide the construction drawings by itself

2, the blue prints.the design and design disclosure time:

3. Construction drawings in duplicate, each party holds one copy. Where Party A provides drawings, it shall submit them to Party B the day before commencement.

Article 6 Contract Composition Documents

The documents constituting this contract include:

1. Agreement in this contract

2, standards, specifications and related technical documents

3. Cartography

4, project quotation or budget

5. The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.

Article 7 Engineering Changes

1, engineering design change

If the Employer needs to change the original engineering design during the construction, it shall send a change notice to the Contractor in writing three days in advance. When the change exceeds the original design standard or the approved construction scale, the employer shall report it to the planning management department and other relevant departments for re-approval, and the original design unit shall provide corresponding change drawings and explanations. The change notice and related requirements issued by the contractor shall be changed as follows:

(1) Change the elevation, baseline, position and size of relevant parts of the project;

(2) increase or decrease the quantities agreed in the contract;

(3) Change the construction time and order of related projects;

(4) Other extra work required for engineering change.

The increase or decrease of the contract price and the loss of the contractor caused by the change shall be borne by the Employer, and the delayed construction period shall be postponed accordingly.

During the construction period, the contractor shall not change the original engineering design without justifiable reasons. The expenses incurred by the contractor in changing the design without authorization and the direct losses caused to the Employer shall be borne by the contractor, and the delayed construction period shall not be postponed.

The rationalization proposal put forward by the contractor in the construction involves the change of design drawings or construction organization design and the replacement of materials and equipment, which must be approved by the employer. If it is changed or replaced without the consent of the Employer, the Contractor shall bear the resulting expenses and compensate the Employer for the related losses, and the delayed construction period will not be postponed. The Employer agrees to adopt the rationalization proposal of the Contractor, and the expenses and benefits arising therefrom shall be shared by the Employer and the Contractor respectively.

2. Other changes

During the performance of the contract, the Employer's request to change the engineering quality standard and other substantive changes shall be settled by both parties through consultation.

3. Determine the change price

The contractor shall submit the project price change report within 3 days after the confirmation of the project change, and adjust the contract price after confirmation by the employer. Change the contract price as follows:

(1) If there is a price suitable for changing the project in the contract, the contract price shall be changed according to the existing price in the contract;

(2) If there is only a change in the price of similar projects in the contract, the contract price can be changed with reference to similar prices;

(3) If there is no price applicable to or similar to the changed project in the contract, the contractor shall propose a suitable change price, which shall be implemented after being confirmed by the Employer.

The first party

party B

Renovation contract Form II of Individual House

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, the two parties reached the following understanding on the renovation project of the sales department of the project in Area C of Yilongwan, Changzhi City through consultation:

I. Overview of the Project:

1, project name:-Decoration project of photography shop

2. Project location:

3. Project contracting scope:-Contents and door head included in the construction drawing of the photographic facade house.

4. Work content: Party A shall provide the construction drawings, and after they are reviewed and confirmed by both parties, Party B shall complete all the contents required by the construction drawings in accordance with the requirements of the relevant national construction specifications for architectural decoration projects.

5. Contracting method: contracting for work and materials.

6. Duration: All projects will be completed within 50 days after both parties sign the contract. Due to force majeure factors such as power failure, water cut-off, gas cut-off and design changes not caused by Party B, the construction period will be postponed accordingly, resulting in work stoppage for more than 8 hours (calculated cumulatively within one week).

7. Contract price: According to the construction drawings and material samples confirmed by Party A, the total project price is about RMB (in words), and the main materials within this price range are listed in the inquiry sheet.

On this basis, the final main material quantity is settled in real value. This price includes all expenses such as transportation, management and profit.

8. Engineering quality standards: qualified standards required by the state and local governments.

Second, the payment method:

Pay 40% of the contract price three days before commencement; 85% of the contract price shall be paid after the completion of woodworking works (including ceiling, partition, door head, etc.). ); After all the project completion experiences are accepted, both parties shall settle accounts and pay 100% of the settlement price after settlement.

Third, the quality and acceptance:

1. Project quality: If Party B's project quality fails to meet the acceptance standards of various sub-projects, it must unconditionally rework until it meets the qualified requirements, and bear the responsibility for delay.

2. Concealed works and intermediate acceptance: the intermediate acceptance agreed by both parties shall be implemented according to construction standards and specifications.

3, each component, division of the project must be qualified, to enter the next working procedure.

4, project acceptance standards and specifications, according to the current national and local latest codes or standards.

5. All mobilization materials can only be used after Party A's acceptance. Unqualified samples and any unqualified materials shall not be used, and the unqualified materials must be transported away from the site unconditionally, and all consequences and expenses arising therefrom shall be borne by Party B..

Four, safe and civilized construction:

Carry out the construction in strict accordance with the requirements of the national safety and civilization regulations, abide by the current safety regulations, ensure the construction safety, and strengthen the management of on-site safety and civilization construction. In order to prevent the occurrence of safety accidents, Party B shall take full responsibility for all kinds of potential safety hazards and safety accidents.

Verb (abbreviation of verb) liability for breach of contract:

1. Except for force majeure, the construction period agreed by both parties shall not be postponed. In case of force majeure, the construction period shall be postponed separately by both parties. Force majeure refers to war, plague, flood, earthquake, destructive snowstorm, water and power failure for more than 8 hours per week. The construction period can only be extended after being signed and confirmed by Party A..

2. Because the construction site can't meet the requirements, the construction period can be postponed accordingly after being signed and confirmed by Party A. ..

3. If the construction period is delayed due to Party A's untimely payment, the construction period can be postponed accordingly.

4. Party B shall bear the penalty of RMB 65,438+0,000 for each day of delay in the total construction period, and five thousandths of the total price every day after one month.

The entry into force of intransitive verb contract;

1. The performance bond shall come into effect after the above agreement is signed and sealed by both parties.

2. Matters not covered in this contract can be supplemented by another agreement, which has the same legal effect as this contract.

3. This Agreement is made in duplicate, with each party holding one copy.

Attachment: 1, list of main materials and quotation sheet.

Party A: (Seal)

Party B: (Seal)

Individual House renovation contract Format 3

Party A (the entrusting party):

Signature time:

Party B (construction party):

Signing place:

In order to standardize the construction of residential decoration and protect the legitimate rights and interests of both parties, according to the Contract Law of People's Republic of China (PRC), the Law on the Protection of Consumers' Rights and Interests of People's Republic of China (PRC), the Administrative Measures for Interior Decoration and Decoration of Residential BuildingsNo. 1 10 of the Ministry of Construction and other relevant laws and regulations, and in combination with the specific conditions of this project, the two parties reached the following agreement.

I. Overview of the Project

1. Conditions of both parties:

The house renovated by Party A is legally inhabited. Party B is a unit approved and registered by the administrative department for industry and commerce of this Municipality, and has obtained the qualification certificate of residential decoration issued by the real estate management department.

2. Decoration construction site: BuildingNo./Room KLOC-0/02. (unit), district road (community).

3. Huxing structure: living room structure, with a construction area of square meters.

4, decoration construction content:

5. Contracting method: (engineering and material contracting, cleaning and partial contracting).

6. This project is sponsored by.

7. Duration: The duration of the project is days, from the date of commencement to the date of completion.

Second, the project price and settlement method

1. Total price: (in words) yuan (including design fee, management fee (%) and tax (%)). If both parties agree to change the construction content, the project price of the changed part shall be calculated separately.

2. Within two days after signing the contract, Party A shall pay 60% of the total price in RMB. Party A shall pay 35% of the total price, that is, RMB yuan, from the time limit for a project to the time when all carpenters call it a day and painters enter the site. Within two days after the project completion acceptance, Party A shall pay 5% of the total price, RMB.

III. Construction Preparation and Obligations of Both Parties

(I) Work of Party A

1. Before starting construction, Party A shall register with the property management unit or property right unit for the record; If it is really necessary to change the structure and nature of the house, a unit with corresponding qualifications shall be invited to issue an appraisal and reinforcement plan, and after approval by the real estate management department, a residential decoration permit shall be obtained.

2. Party A shall make on-site disclosure to Party B two days before commencement. Empty houses, remove obstacles that affect construction, and take protective measures for furniture and furnishings stranded in houses that can only be partially vacated. Provide Party B with water and electricity needed for construction, and explain the matters needing attention in use.

3, do a good job in the construction of temporary use of public parts and affect the neighborhood relations and other behaviors of coordination.

4. Party B shall be appointed as the representative of Party A, responsible for the performance of the contract, supervision, acceptance, alteration and registration procedures of the project quality and progress.

(II) Work of Party B

1. Conduct on-site disclosure of construction drawings or instructions to Party A, draw up plans and progress plans, and submit them to Party A for approval.

2. Appoint as the representative of Party B to be responsible for the performance of the contract. Organize the construction according to the requirements, ensure the quality and quantity, complete the construction tasks on schedule, and solve all matters that Party B is responsible for.

3. Without the consent of Party A and the approval of the local real estate management department, the structure and use nature of the house shall not be changed at will.

4. Sign a residential interior decoration management service agreement with the local property management unit.

5, strictly implement the relevant provisions of the construction site management, shall not be a nuisance and pollute the environment.

Fourth, the supply of materials

1. Materials supplied by Party A: The materials and equipment purchased and supplied by Party A in this project shall be qualified products that meet the design requirements and must meet the national standards, and the product name, specification, model, manufacturer's name and address shall be marked in Chinese. , shall not use the building decoration materials and equipment explicitly eliminated by the state. Supply to the site on time, and Party B shall go through the acceptance formalities. If the materials and equipment provided by Party A have quality problems or specifications differences or cannot provide relevant certificates, Party B shall submit them to Party A in writing in time. If Party A still expresses its intention to use it, it can continue to use it with written consent, and Party A shall be responsible for the engineering losses caused thereby.

2. Materials provided by Party B: The materials provided by Party B must meet the national standards, with quality and environmental inspection certificates, product name, specification, model, manufacturer's name and address, etc. Marked in Chinese. Building decoration materials and equipment explicitly eliminated by the state shall not be used for residential decoration stipulated in this contract, and shall be approved by Party A, and shall not be used for other purposes without Party A's consent. If the materials provided by Party B are fake and shoddy goods, Party A shall be compensated twice the price of the materials provided.

If the materials and equipment provided by Party B do not meet the requirements of quality and environmental protection or have different specifications, they shall not be used. If it has been used, Party B shall be responsible for the losses caused to the project.

Verb (abbreviation of verb) safe production

The construction drawings or instructions provided by Party A and the construction site shall meet the fire prevention requirements. The requirements for accident prevention mainly include that the electrical, communication lines, gas pipelines, tap water and other pipelines are unblocked and qualified. During the construction period, Party B shall take necessary safety protection and fire control measures to ensure the safety of operators and nearby residents, and prevent the pipelines of nearby residents from being blocked. Accidents such as water leakage, power failure and damage to articles occur. All kinds of solids, flammable liquids and other wastes formed in the process of shipment and repair shall be piled up and removed according to the designated place, method and time. In case of the above situation, it is the responsibility of Party A, and Party A shall be responsible for compensation; Where Party B is responsible, Party B shall be responsible for repair and compensation.

Party B shall strengthen the safe production and civilized construction during the construction period. Party B shall be responsible for all work-related injuries and deaths.

Six, construction content and time limit for a project change

During the construction process, Party A shall contact Party B in advance when proposing design modification opinions and adding or subtracting engineering projects. The construction of this project can only be started after signing the Project Change Form (see Annex 4 for details), and the resulting cost increase or decrease or time limit change shall be negotiated by both parties. If Party A agrees with the workers to change the construction content privately, all consequences shall be borne by Party A, and if losses are caused to Party B, Party A shall compensate.

Seven, project quality and completion acceptance method

1. The quality evaluation and acceptance criteria of this project are construction drawings, practice notes, design changes and industrial specifications for construction quality of residential decoration projects.

& gt2. After the decoration project is completed, the project quality and environmental protection requirements shall meet the relevant national standards.

3. If the project quality problems are caused by Party A's reasons, the rework cost shall be borne by Party A, and the construction period shall be postponed.

4. In case of quality accident due to Party B, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

5. Party B shall promptly notify Party A to handle the acceptance procedures for concealed works and intermediate works. If Party A fails to attend the acceptance as scheduled, Party B shall organize personnel to conduct the acceptance, and Party A shall acknowledge it in writing.

6. After the completion of the project, Party B shall promptly notify Party A for acceptance, and Party A shall conduct acceptance within seven days after receiving the acceptance notice.

Eight. responsibility for breach of contract

1. After this contract comes into effect, Party A and Party B shall perform all the terms stipulated in the contract (including contract annexes, budget and drawings confirmed by both parties), and shall not change or terminate it without authorization, otherwise, the breaching party shall pay the other party a penalty of 10% of the total project budget and bear other economic losses caused thereby.

2. Party A shall compensate Party B for the delay in commencement or stoppage due to Party A's reasons. The losses caused by the economic slowdown. Party A shall pay Party B1‰ of the project price for each day of shutdown; If Party A fails to make payment as agreed in the contract, Party A shall pay a penalty of 65,438 ‰ of the project price for each day overdue.

3. If the completion is delayed due to Party B, Party B shall pay 1‰ of the project price to Party A for each day overdue.

4. Without the consent of Party B, Party A arbitrarily changes the structure and use nature of the house, and Party A shall be responsible for the losses or accidents (including fines) caused thereby.

Nine, the project warranty

1. The warranty period of the "double package" project of the contractor and materials is two years from the date of completion acceptance. The warranty period is calculated from the date when the residential interior decoration project is completed and accepted.

2. In case of quality problems due to Party B, Party B will unconditionally carry out maintenance.

3. The damage caused by Party A's improper or abnormal use is not covered by the warranty.

4. This guarantee shall come into effect after being signed and sealed by both parties.

X. Dispute settlement

Disputes arising from residential interior decoration projects can be resolved through consultation or mediation. Unwilling to negotiate or mediate, or if negotiation or mediation fails, the parties may deal with it in the following ways.

(1) submitted to Taizhou Arbitration Commission for arbitration;

(2) bring a lawsuit to the people's court according to law;

XI。 Other agreed matters.

12. This contract is made in duplicate, with the same legal effect. The annex to the contract is an integral part of this contract.

Party A: Party B:

Name (signature): unit name (seal)

Individual House renovation contract Format 4

Party A: (hereinafter referred to as Party A) Party B: (hereinafter referred to as Party B)

In order to provide a good learning and office environment for all teachers, the school office was renovated by the school Committee meeting. Based on the principle of equality and openness, Party A and Party B have reached the following school office decoration contract through consultation, the details of which are as follows:

1. This project is contracted to Party B in the form of contract work and materials. Party A is responsible for providing water and electricity needed for the project, and Party B is responsible for all other required materials.

Second, the engineering requirements

1, the office floor is required to be tiled, the tile specification is 60cm-60cm, the wall tile specification is 25cm-33cm, and the waist line is attached to the top of the wall tile.

2. Where brick is needed, there shall be no holes. If there are loopholes, Party B is required to rework, and all losses caused by rework shall be borne by Party B. ..

Three, the floor tile area is 6 square meters, and the unit price is 59 yuan per square meter; The area of wall brick (including waist line) is 32 square meters, and the unit price is 36 yuan per square meter. Total of two items 1506 yuan. Party B shall pay Party B in one lump sum after the completion and acceptance by Party A..

This project started on March 2, 2000 and was completed on March 20, 2000.

5. This contract is made in duplicate, with each party holding one copy. It will take effect as of the date of signature.

Signature of Party A: Be the legal representative of Gu Primary School.

Signature of Party B:

March 20, 65438 +0,

Individual House renovation contract Format 5

Demander (Party A): _ _ _ _ _ _

Supplier (Party B): _ _ _ _ _ _

In accordance with the provisions of the Contract Law of People's Republic of China (PRC), the Contract is hereby concluded through negotiation:

Article 1 The total value of Party A's order from Party B is RMB.

Article 2 Acceptance method: provide sealed samples before supply and receive sealed samples on site.

Article 5 Payment and expense settlement method: 50% of the payment shall be paid after the contract is signed, and all the payment shall be paid within 7 days after the goods arrive at the site for acceptance.

Article 6 Terms of delivery

Delivery place: _ _ _ _ _ _.

Delivery date: _ _ _ _ _ _ _.

Transportation cost: _ _ _ _ _ _ _.

Article 7 Economic Responsibility

(1) Economic responsibilities that Party B shall bear.

1. If the style, color, variety, specification and quality of the product do not conform to the provisions of this contract, if Party A agrees to use it, the price will be determined according to the quality. If it cannot be used, Party B shall be responsible for the warranty and return. If the delivery time is delayed due to the above reasons, Party B shall pay Party A liquidated damages for overdue delivery at the rate of three ten thousandths of the total overdue payment.

2. When Party B fails to deliver the goods according to the quantity stipulated in this contract, if necessary, Party A shall pay the insufficient part according to the quantity. If Party A doesn't need it, it can return it. The losses caused by the return of goods shall be borne by Party B. If Party A needs it, Party B shall pay Party A a fine of 5% of the total value of the undelivered part.

3. If the product packaging does not meet the requirements of this contract, Party B shall be responsible for repairing or repackaging, and bear the cost of repairing or repackaging. If Party A requests not to repair or repackage, Party B shall pay Party A a penalty of 2% of the package value that is inconsistent with the contract.

4. If the delivery time of the products is not in conformity with the contract, Party B shall pay Party A a fine of three ten thousandths of the total value of the delayed delivery for each day.

(II) Economic responsibilities of Party A ..

1. If Party A changes the design, variety, specification, quality or packaging specifications of the products in the middle, it shall pay a penalty of 1% of the total value (or packaging value) of the changed part.

2. If Party A returns goods midway, it shall negotiate with Party B in advance. If Party B agrees to return the goods, Party A shall pay Party B a fine of 65,438+0% of the total value of the returned goods. If Party B does not agree to return the goods, Party A will still receive the goods according to the contract.

3. If Party A fails to deliver the technical data, raw materials or packaging materials to Party B within the specified time and requirements, Party A shall pay a fine of three ten thousandths of the total value of the delayed products to Party B for each day of delay, except that Party B may postpone the delivery. If Party A fails to provide the above-mentioned materials, it will be deemed as a return halfway.

4. If Party A fails to take delivery of the goods according to the specified date, it shall pay a fine of three ten thousandths of the total payment to Party B for each day overdue.

5. If Party A fails to pay Party B on the specified date, Party A shall pay Party B a penalty of three ten thousandths of the total delayed payment for each day of delay.

6. If Party A refuses to accept the products delivered or shipped by Party B, Party A shall bear the losses, transportation expenses and fines caused thereby.

Article 8 If the product price needs to be adjusted, it must be negotiated by both parties and reported to the price department for approval before it can be changed. Before the approval of the competent price department, it should still be executed at the original contract price. If the delivery is affected by the price problem, Party B shall pay Party A a penalty of three ten thousandths of the total value of the delayed delivery every day.

Article 9 If Party A and Party B or any party wants to dissolve this contract in whole or in part, they must give sufficient reasons, negotiate with both parties and report to the higher authorities for the record. The party who proposes to terminate the contract shall pay the other party 10% of the total amount of the contract termination.

Article 10 In case of major changes in raw materials, production equipment, production technology or market, if Party B needs to change the product variety, color, specification, quality and packaging, it shall negotiate with Party A three days in advance.

Article 11 All terms and conditions stipulated in this contract shall not be changed or modified by any party without authorization. If one party independently changes or modifies this contract, the other party has the right to refuse to produce or receive the goods, and demand the party that independently changes or modifies this contract to compensate all losses.

Article 12 If either party is unable to perform this contract due to force majeure, it shall promptly notify the other party of the reasons why it is unable to perform or needs to postpone or partially perform this contract. After obtaining the certificate from the competent authority of the other party, this contract may not be performed or postponed or partially performed, and the liability for breach of contract may be exempted.

Article 13 In case of disputes or disputes during the execution of this contract, Party A and Party B shall settle them through consultation. If negotiation fails, either party may apply to the contract management authority stipulated by the state for mediation and arbitration. If one party refuses to accept the arbitration, it may bring a lawsuit to the people's court within 15 days after receiving the arbitration.

Article 14 This contract shall come into effect as of the date of signature by both parties, and shall become invalid after Party B submits all orders to Party A for acceptance and settles the payment according to the provisions of this contract.

Article 15 During the execution of this contract, if there are any matters not covered, Party A and Party B may formulate additional supplementary terms through consultation as annexes to this contract. All supplementary clauses have the same legal effect as this contract.

Article 16 This contract is made in quadruplicate, with two originals and two copies held by Party A and Party B respectively, and one copy submitted to the competent authorities of both parties.

Party A: _ _ _ _ _ _ _ (signature and seal)

Party B: _ _ _ _ _ _ _ (signature)

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Five items related to renovation contract format of individual residence:

★ Private renovation contract format template.

★ 5 pieces of simple room renovation contract model in 2022.

★ renovation contract 202 1 template for 5 houses.

★ 202 1 year individual house renovation contract template

★ Five model contracts for all-inclusive house decoration.

★ 5 simple houses renovation contract

★ renovation contract model of individual residence

★ 3 copies of renovation contract model of individual housing contract and materials.

★ renovation contract Model of Simple Personal Housing

★ Five Practical Clauses of renovation contract Agreement on 2022 Housing.