Traditional Culture Encyclopedia - Photography major - Film and television production contract

Film and television production contract

In the era of continuous progress, there are more and more uses of contracts, and signing a contract can restrain the behavior of the parties that harm the interests of the other party. But do you know how to write it? The following are three films about film and television production contracts for reference only. Welcome to reading.

Film and television production contract number 1:

Customizer (hereinafter referred to as Party A):

Manufacturer (hereinafter referred to as Party B):

Based on the principle of mutual benefit, Party A and Party B have reached the following agreement through friendly negotiation:

1. Party A entrusts Party B to shoot and produce TV advertisements (special topics), and provides Party A with master tapes (kept dry by Party B) and dvd/vcd discs.

Two. Rights and obligations of Party A:

Party A shall pay Party B the production expenses totaling RMB Yuan only (in figures ¥ Yuan).

Party A shall provide Party B with relevant materials needed for production, and guarantee the authenticity and legality of the materials.

Party A shall organize, arrange and specify the specific shooting requirements of the shooting site, and cooperate with Party B to shoot the scene. If the shooting time and effect are affected due to poor organization and arrangement, Party A shall bear the responsibility.

During the film review, Party A has the right to ask Party B to make some modifications without deviating from the script.

Three. Rights and obligations of Party B:

Party B must shoot and produce the film in strict accordance with the script requirements of Party A, and the technical indicators of the film must meet the broadcasting requirements. In case of quality problems, Party B shall take full responsibility and take corresponding remedial measures.

If the film cannot be completed on schedule or the quality of the film is affected due to Party A's reasons, Party B has the right to refuse or demand compensation from Party A when Party A demands compensation from Party B. ..

During the production of Party B, Party A shall not change the script at will. If the workload of Party B increases or the film delivery time is delayed, Party B has the right to ask Party A to pay separately.

Party B shall not disclose the relevant information provided by Party A and keep Party A's business information absolutely confidential.

4. Payment and film review methods:

1. Payment method:

When both parties sign a formal contract, Party A shall pay Party B a down payment of RMB Yuan only (in figures ¥); Party A shall pay the final payment in full, that is, RMB Yuan only (¥ in figures) after the film is approved.

2. Film review method:

Within working days after the formal signing of the contract by both parties, Party B shall complete the production and submit it to Party A for review.

Verb (abbreviation for verb) Other terms:

This contract shall come into effect as of the date of signature by both parties.

This contract is made in duplicate, one for each party, with the same legal effect.

Matters not covered in this contract shall be settled by both parties through consultation in the spirit of friendly cooperation. If negotiation fails, it shall be settled through litigation, and the court where the contract is performed shall be the court under the jurisdiction of this contract.

Party A: Party B:

Signature (seal): Signature (seal):

Date: Date:

Article 2 of the film and television production contract Party A: (entrusting party) xxxxxx Co., Ltd. Party B: (shooting party) XXXXXX Media Co., Ltd. Project: shooting and production of publicity and training video discs.

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party B accepts the entrustment of Party A, and both parties enter into this contract through consultation and abide by it jointly.

1. Contents and requirements of the contract:

Party A entrusts Party B to shoot and make promotional and training video discs with a length of minutes.

2. Project shooting:

Overall project shooting time: 20 years from 20 years to 20 years. (From the date of receiving the advance payment)

Three. Project shooting fee:

1. The total cost of filming this project is RMB.

2. After the signing of this contract, Party A shall pay 50% of the total design fee to Party B, that is, RMB Yuan only, and Party A shall complete it according to the production requirements.

When the CD is delivered, the remaining 50% of the project production cost, that is, RMB Yuan only.

Four. Rights and obligations of both parties:

Rights of Party A:

1. Party A has the right to put forward suggestions and ideas for Party B's shooting, so that the works shot by Party B can better meet Party A's requirements; 2. Party A shall provide Party B with relevant materials needed for production, and guarantee the authenticity and legality of the materials;

3. The video script can only be filmed after being reviewed and signed by Party A, and Party B shall shoot it in strict accordance with the signed script; After the script is signed and confirmed, if it needs to be changed, the expenses arising from the change shall be borne by Party A. ..

4. During the film review, Party A has the right to ask Party B to edit and modify the film in the later stage without deviating from the script.

Obligations of Party A:

1. Party A has the obligation to pay relevant expenses according to this contract;

2. Party A has the obligation to provide Party B with relevant information or other relevant materials. ..

Rights of Party B:

1. Party B must shoot and produce in strict accordance with the script requirements of Party A, and the technical indicators of the film must meet the broadcast requirements.

2. If the film cannot be completed on schedule or the quality of the film is affected due to Party A's reasons, Party B has the right to refuse or demand compensation from Party A;

3. During the production of Party B, Party A shall not change the script at will. If Party B's workload increases or the film delivery time is delayed, Party B has the right to ask Party A to pay another fee;

4. Party B shall not disclose the relevant information provided by Party A and keep the business information of Party A absolutely confidential;

5. Party B has the right to require Party A to pay the corresponding amount according to this contract;

6. Party B enjoys the copyright of the shot works, has the right to display Party B's name at the beginning or end of the promotional film, and has the right to ask Party A not to use the shot works before paying the money.

Obligations of Party B:

Party B shall shoot and produce works according to the requirements of Party A; 2. Party B shall deliver the filming and production works on time according to the contract.

Verb (abbreviation for verb) intellectual property agreement:

1. Party B enjoys the copyright of the finished works. Party B can automatically transfer the copyright of the work to Party A after Party A has settled all the expenses of the commissioned filming;

2. Before Party A pays off all the entrusted shooting fees, the copyright of the works shot by Party B belongs to Party B, and Party A has no rights to the works;

3. If Party A uses or modifies the works shot by Party B without authorization before paying the balance, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC);

4. Party A has the ownership, use right and modification right of the work after all the expenses of the commissioned filming and production are settled.

Liability for breach of contract of intransitive verbs:

1. Party A terminates the contract before the completion of the first draft of the filming work, and has no right to demand the refund of the prepaid expenses; If Party A terminates the contract after the completion of the first draft of Party B's works, it shall pay all the shooting and production expenses;

2. If Party B terminates the contract prematurely without justifiable reasons, all the fees collected shall be returned to Party A;

3. After Party B completes the video image, Party A shall pay the balance as agreed in the contract, and pay a penalty of 10% of the total contract price for each day overdue. After signing the contract, if either party breaches the contract, it shall pay the other party a penalty of 100% of the total contract amount.

Seven. Controversy:

Any dispute arising from the performance of this contract between Party A and Party B shall be settled through friendly negotiation. If negotiation fails, either party may submit it for arbitration.

Eight. Entry into force of the contract:

The annex to this contract is an integral part of this contract. This contract is made in duplicate, with each party holding one copy, which shall come into effect as of the date of signature and seal by both parties and have the same legal effect.

Nine. Supplementary terms:

This contract does not include special aerial photography, underwater photography, rocker arm and other shooting projects. If requested by Party A, both parties will negotiate specific matters and expenses separately according to market conditions.

(Party A): (Party B):

Legal representative:

Tel: Tel:

Date of signing this contract: year month day.

Article 3 of the film and television production contractNo.:

Party A:

Name of Party B (Contractor):

Code of Party B (Contractor):

Party A's business undertaker:

Date of signing:

Party A (the entrusting party):

Party B (contractor):

According to the Contract Law of People's Republic of China (PRC) and relevant regulations, both parties, based on the principles of honesty, credibility, equality and mutual benefit, signed this contract at the place where Party A entrusted Party B to produce the video and television project (VCR) through friendly negotiation, and they will abide by it together.

I. Design and production of film projects (multiple films should be listed separately):

Video (video recorder) 1:

Movie Name: Movie Format:

Production specification: production length (seconds):

Project language: delivery form: □ network transmission □ data tape □ CD □ other.

Background music: The production requirements are as follows: attachment and script.

Second, the film production period:

1. The estimated production cycle is days. Party B shall start production on, and complete production on, and deliver it to Party A..

2. If Party A fails to deliver the relevant materials for film production to Party B or fails to pay the advance payment, the production period may be extended accordingly. If the production time is delayed due to irresistible factors such as weather, both parties shall settle it amicably.

III. Providing film production materials and film production requirements:

1. Party A shall deliver all materials and pictures required for film production to Party B within the day after the signing of this contract, and Party B shall sign or send an email for confirmation.

2. Party B shall, at the same time of signing this contract, deliver the text of this contract to Party A, which shall be signed and confirmed by both parties as an annex to this contract. The production script shall include Party A's advertising production requirements and creative requirements.

3. During the production process, Party A shall provide Party B with Party A's relevant products, enterprise professional texts, enterprise texts, pictures, addresses, telephone numbers and other materials required for production.

4. After the film is made and delivered to Party A, the copyright of the film belongs to Party A. Party A has the right to enjoy the publishing rights, distribution rights and ownership of the original tapes of all films.

5. Party B shall make the film in strict accordance with the production requirements of Party A, and ensure that the picture quality and technical quality of the film reach the standards agreed by both parties. After the film is completed, its technical indicators are not lower than the standards set by Party A's film production requirements.

6. Party B is responsible for presenting all script ideas, translations, refinements, lines (Chinese and English), shots and subtitles through movies.

7. Party B guarantees that the copyright of the produced content is legal (including: pictures, music, dubbing, actor portrait rights, etc.). ).

Four, production costs and payment methods:

1. The design and production cost of this project is RMB Yuan only, which shall be paid by Party A. ..

The project of 1. 1 needs to be paid in advance, and the down payment is% of the total amount, RMB _ _ _ _ _ _ _ (i.e. RMB _ _ _ _ _ _), which Party A will pay to Party B on the effective date of the contract, so that Party B can put into production and implementation as soon as possible.

The balance of 1.2 is% of the total amount, that is, RMB _ _ _ _ _ _ _ (that is, RMB _ _ _ _ _ _ _ _ _ _), which shall be implemented according to the production cost and payment method in Article 2 below.

2. Party B shall provide unmarked samples to Party A.. After Party A's written acceptance 15 working days, Party A shall pay Party B the production balance, totaling RMB Yuan only.

3. Party B shall provide Party A with a complete official invoice of this contract before payment. If payment is delayed due to Party B's failure to provide legal official invoices, Party A shall not be liable for breach of contract. Party B shall issue a written report on the failure to provide invoices and submit it to Party A for the record.

4. Payment method: Party A pays by transfer according to the requirements of the contract.

Verb (abbreviation of verb) acceptance criteria and methods:

1. The acceptance standard shall be an annex to this contract after being signed by both parties or confirmed by e-mail.

1. 1 Party A compares the film and television project documents designed by Party B according to the appendix of the contract and the standard of the promotional film content planning scheme provided by Party B, and the conclusion is satisfactory.

1.2 There are no spelling mistakes in the text, pictures, audio and video of the film and television project documents (subject to the materials provided by Party A).

2. If Party A needs to modify the creativity, change the production script or increase the film content, production length or other new production requirements during the production process, both parties shall negotiate separately to determine the production cycle and increase the production cost, and sign a written supplementary agreement.

3. Party B shall submit the completed film samples to Party A for review in the form of multimedia data within the agreed time. Party A's review

Within days. If it meets the requirements of Party A's film production, Party B shall provide Party A with a complete finished film of the project after being confirmed by Party A in writing or email.

4. If Party A has any objection to the finished product, it shall put forward modification opinions to Party B in written form or e-mail during the review period, and Party B shall complete the modification according to Party A's modification opinions.

Rights and obligations of intransitive verbs;

1. Rights and obligations of Party A:

1. 1 Party A shall provide relevant standard texts and graphic materials required for this film; Commercial props, company scenes and staff (related products and information in buccal tablets) specified in this film.

1.2 Party A shall confirm the script production plan in time during the execution of Party B, and make written confirmation or put forward written amendments within five working days; Confirm the meeting contents in time before production (PPM).

After Party B receives the contents confirmed by Party A1.3; In particular, after Party A and Party B confirm the contents by PPM or Party A confirms the modification opinions in writing, if Party A needs to add new contents or modify the advertisement again, the expenses incurred shall be calculated according to the actually increased modification expenses; Meanwhile, Party A and Party B will coordinate the time and method of re-delivery.

2. Rights and obligations of Party B:

2. 1 Party B must be responsible for the whole implementation process, film quality and creative performance. Strictly follow the script requirements of Party A..

The technical indicators of creative design shooting and production must meet the broadcasting requirements. In case of quality problems, Party B shall bear the responsibility for breach of contract and take corresponding remedial measures.

2.2 Party B shall ensure that the film content provided by it does not violate any laws and regulations or infringe the legitimate rights and interests of any third party (including but not limited to intellectual property rights), otherwise all consequences shall be borne by Party B. ..

2.3 Party B must make it according to Party A's requirements. If Party B needs to change his mind, he must get Party A's consent. ..

2.4 During the project, Party B will make free modifications to the film production according to the unprincipled modification opinions put forward by Party A. ..

2.5 According to the requirements stipulated in this contract, Party A shall use it to browse the film and television documents of this contract film and television production project in time.

2.6 Complete the development of film and television production projects within the time limit stipulated in this contract, and promptly notify Party A for acceptance.

2.7 During the acceptance period, at the request of Party A, the unqualified parts shall be corrected in time.

2.8 Confidentiality obligations:

2.8. 1. Party B shall strictly keep this contract and any confidential information (including but not limited to any data, product technical data and other valuable information) and business secrets of Party A known during the performance, and shall not disclose the above information and secrets to any third party after the expiration of this agreement. Even if it is provided to personnel related to the performance of this contract, it shall be kept confidential and limited to the scope necessary for the performance of this contract.

2.8.2 Within 15 days after the termination of the contract by both parties, Party B has the responsibility and obligation to return the originals and copies of all the certificates, product manuals, drawings and other product materials entrusted by Party A related to the production of film and television products. If it is not returned after the deadline, it will be deemed that Party B has leaked it privately, and Party A reserves the right to further investigate the legal responsibility of the supplier.

2.8.3. Party B has the responsibility to keep this contract confidential, and shall not disclose all or part of the text or contents of this contract to a third party (including organs, enterprises, groups, collectives and individuals) without the formal written authorization of Party A, otherwise Party A will pursue the supplier's responsibility for disclosure through legal means.

2.8.4. This clause shall be valid for five years after the termination, dissolution, invalidity or confirmation of invalidity of this contract, and shall be legally binding on both parties.

Seven. Liability for breach of contract:

1. Both parties shall perform the contract in strict accordance with the stipulations of this contract. If one party breaches the contract, it shall be liable to the other party for breach of contract and compensate the other party for the losses caused by its breach of contract.

2. If Party A delays payment, during the overdue period, Party A shall pay Party B a penalty of 0.5% of the unpaid production fee every day.

3. If Party B fails to complete the production or renovation on time, Party B shall pay 2% of the total contract price to Party A as liquidated damages for each day overdue until the production project is completed. The liquidated damages can be deducted from the unpaid amount.

4. If Party B violates the obligations stipulated in this contract, Party B shall pay Party A a penalty of 20% of the total contract amount.

5. If Party B fails to complete the production or modification within 65,438+00 working days, Party A has the right to terminate this contract, and Party B shall send it to Party A.

Within 5 working days from the date of termination notice, Party A shall unconditionally return the received funds in full, and pay the liquidated damages for delay to Party A according to the calculation method agreed in the third paragraph of this article, and the liquidated damages for delay shall be calculated until the date when Party A issues the termination notice. ..

Eight. Force majeure:

During the performance period stipulated in the contract, if the contract cannot be performed due to force majeure (disaster, war, etc.). ), the party unable to perform can be exempted from the liability for breach of contract after obtaining the legal proof of force majeure (disaster, war, etc.). ), but the other party shall be informed of the force majeure (disaster, war, etc.). Within ten working days after the occurrence of force majeure (disaster, war, etc.). ) happens.

Nine. Settlement of contract disputes:

Any dispute between Party A and Party B during the performance of this contract shall be settled through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court where Party A is located.

X. Other agreements:

1. This contract shall come into effect as of the date of signature and seal by both parties. After the contract is fulfilled, it will automatically become invalid. If the representatives of both parties are responsible for signing the contract

And be responsible for the performance, supervision and communication of this contract. The legal representative and person-in-charge of Party B shall be jointly and severally liable for the performance of this contract.

2. The interpretation and execution of this contract shall be governed by the laws of People's Republic of China (PRC) (PRC).

3. Without the written consent of Party A, Party B shall not transfer any rights and obligations under this contract to a third party.

4. Matters not covered shall be implemented in accordance with the Supplier Cooperation Contract, Product Quality Assurance Agreement, Supplier Specification and other documents signed by both parties.

5. Any additions, additions and modifications to the terms of the contract shall be made in writing and signed by the authorized representatives of both parties.

XI。 Annex to the contract:

Film production script, project schedule control table

(There is no contract text below)

Party A:

Address: Party B: Address:

Chuan Zhen:

Telephone message:

Agent:

Bank of deposit:

Account number:

Tax number:

Authorized representative (signature):

Date of signing:

Fax: telegram: manager: bank: account number: tax number: legal representative (guarantor): authorized representative (guarantor): date of signature: