Traditional Culture Encyclopedia - Weather forecast - Engineering construction agreement

Engineering construction agreement

In today's society, there are more and more places to use agreements, and signing agreements has legal support. So how to write the relevant agreement? The following are four construction agreements that I have collected. Welcome everyone to refer to it, I hope I can help you.

Project Construction Agreement 1 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Quality Management of Construction Projects and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on house maintenance and concluded this contract.

I. Overview of the Project

1, project name:

2. Project location:

3, the scope of the project:

4. Contract duration: commencement date, completion date and completion date, including legal holidays, cross-construction and waiting time for coordinated construction. If the weather or other factors affect the construction, Party B may extend the construction period appropriately after Party A confirms and agrees.

Second, the engineering service form

Contract work, contract materials, contract term and contract quality.

Third, the settlement method

Party A, Party B and the supervisor will sign the parts and quantity to be repaired in the form of technical contact sheet, and the quantity shall be subject to the contents of the technical contact sheet signed by Party A, Party B and the supervisor to determine the total project cost.

Party A and Party B attach a technical contact list of quantities signed and sealed by settlement book, Party A, Party B and the supervisor as an annex to the contract.

Fourth, the total project price

It is tentatively set at RMB 1 ten thousand yuan (subject to the final settlement amount confirmed by both parties).

V. Supervision, Inspection and Acceptance of Project Quality

During the construction, Party B shall carry out the construction in strict accordance with the national and industrial standards, enterprise norms and this contract, and accept the inspection of Party A at any time to provide convenient conditions for inspection and inspection. Party B shall promptly rectify the problems raised by Party A. After the maintenance project is completed, both Party A and Party B and the owner of the house to be repaired shall jointly accept it. Acceptance shall be subject to the construction record signed by the three parties. At the time of completion acceptance, for Party A or the industry,

If the quality problem of the project is not repaired by the owner, Party B has the responsibility to continue the maintenance according to Party A's requirements and bear the responsibility for overdue.

Six, the project payment

After the project is completed and accepted, 97% of the total project amount will be paid, and the remaining 3% will be used as quality deposit. After the expiration of the warranty period, Party B shall pay in full without any quality problems.

Seven. guarantee

1. After Party B's maintenance project is completed, Party B shall undertake the warranty responsibility for all projects. The warranty period is years, counting from the date when the project is completed, accepted and delivered to Party A. ..

2. The project warranty payment is 10% of the project payment. Within ten days after the expiration of the warranty period, Party A will refund the remaining warranty payment without interest.

3. During the warranty period, if there is any quality problem in the maintenance project, Party B shall guarantee to send someone to inspect and repair it within 2 hours after receiving Party A's notice, and carry out the maintenance within a reasonable period determined by Party A. If Party B fails to send someone to repair it within the time limit or the problem still occurs after the second maintenance, Party A has the right to entrust others to repair it, and all expenses and losses arising therefrom shall be borne by Party B. ..

4. In the process of construction, Party B must operate in strict accordance with the requirements of construction technology. If the repaired project has mildew and leakage again, Party B shall complete the repair within two days after receiving the notice from Party A, and bear all consequences and economic compensation caused by the recurrence of mildew and leakage. Such as home decoration, compensation for loss of goods, etc.

5. During the warranty period, Party B shall pay a regular return visit to the construction project, make a record of the return visit, and solve the quality problems with hidden dangers in time. Party B now keeps the written mailing address and telephone number of the person in charge of warranty so as to inform Party B to carry out maintenance.

Eight. responsibility for breach of contract

65438+

2. If Party B stops work for more than two days (including two days) without Party A's permission, Party A has the right to terminate the contract, and Party B shall leave unconditionally within two days, and both parties shall settle accounts after Party B leaves.

3. If Party B violates any other obligations under this contract and is notified by Party A to make corrections within a time limit, Party A has the right to terminate this contract, and Party B shall bear all losses caused thereby.

4. If the materials and construction technology do not meet the technical specifications and environmental protection requirements due to Party B's intention or negligence, or the quality problems of the project do not meet the requirements of the contract, Party A or the owner has the right to claim compensation from Party B within two years from the date of knowing whether the project has passed the acceptance, delivered for use or exceeded the warranty period.

5. Without the written consent of Party A, Party B shall not transfer the rights and obligations under this contract to others, otherwise, Party A has the right to terminate this contract.

6. Before the engineering quality problems of the parts repaired by Party B are solved, Party A has the right to refuse to pay any money.

7. If the contract is terminated due to Party B's reasons, Party B shall bear the penalty of 65,438+00% of the provisional contract price. If the liquidated damages are insufficient to make up for the losses of Party A (including the compensation and liquidated damages paid by Party A to the third party), Party B shall also compensate the losses of Party A.. ..

Nine, safety construction

Party B shall take strict construction safety measures in accordance with relevant regulations, and bear the responsibility for accidents caused by its own ineffective safety measures and the expenses and consequences arising therefrom. Party B shall be responsible for the personal safety of its construction personnel. Party B shall purchase personal accident insurance and all insurance related to the project construction for the construction personnel. In case of safety accidents or other accidents during construction, Party B shall bear the responsibilities.

X. Construction responsibility

1. Party A shall provide Party B with water, electricity and other conveniences during the construction period, and be responsible for coordinating with residents and subordinate departments. Party B shall carry out the construction according to the requirements of construction technology.

2. During the construction period, Party B shall protect the square brick footpaths, flowers and trees in the residential area from damage. When maintaining tenants' houses, we must strictly abide by the property rules and regulations. If the tenant complains or Party B damages the goods, Party A has the right to deduct it from the project payment payable to Party B. ..

3. Party B shall be appointed as the site representative of this project, organize the construction according to the requirements of this contract, and complete the contents stipulated in this contract on time with good quality and quantity. And be responsible for communication and contact with Party A. Any promise, guarantee, letter, signature and confirmation made by the person in charge to Party A on this project shall be regarded as the behavior of Party B, and Party B shall bear the responsibility.

4. Party B shall carry out the construction in strict accordance with the construction specifications and quality standards confirmed by Party A, and make records of various quality inspections. Strictly implement construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations to ensure that the project meets the requirements of the contract and Party A..

5. Before the project is completed and accepted, Party B shall be responsible for protecting all the facilities, finished products and semi-finished products on site and bear the expenses.

6. During the maintenance period, Party B must concentrate the garbage in the place designated by Party A every day, keep the construction site clean and remove it within the time required by Party A, otherwise Party A has the right to entrust others to clean it up, and the expenses incurred shall be deducted from the project payment payable by Party A to Party B. ..

7. Accept the quality inspection, inspection and supervision of Party A's representative and its appointed personnel at any time during the construction process, provide convenient conditions for inspection, inspection and supervision, rework and modify according to the requirements of Party A's representative and its appointed personnel, and bear the cost of rework and modification caused by its own reasons.

8. All the examination and approval procedures required for maintenance and construction (referring to the projects that need to be submitted for approval according to relevant laws and regulations) shall be handled by Party B, and all the responsibilities shall be borne by Party B. ..

9. The maintenance works agreed in this contract must be completed by Party B. Without Party A's consent, Party B shall not subcontract or hand over the works to any other third party, otherwise, Party A has the right to terminate this contract.

10. Party B shall keep good communication with the maintenance owner during the maintenance to avoid disputes. If there is a dispute with the maintenance owner due to Party B, which causes losses to Party A, Party B shall bear the responsibility, and Party A shall have the right to deduct it from the project payment payable to Party B, and Party A shall have the right to recover the insufficient amount from Party B. ..

1 1. During the maintenance and construction, Party B shall take good care of the property and articles of Party A and the owner, and shall not damage the buildings and related facilities and equipment in the community. In the maintenance project, Party B shall compensate Party A or a third party for personal or property losses caused by Party B. Party A has the right to deduct from the project payment payable to Party B, and Party A, the owner or relevant obligee has the right to recover the insufficient part from Party B. ..

XI。 others

1. If this project involves the confirmation of project price, the relevant confirmation shall be confirmed by Party A's representative and Party A's budget department and stamped with Party A's official seal. Other people (except the legal representative) sign or lack any of the above confirmations, or fail to affix Party A's official seal (such as visa stamp), Party A will not recognize it.

2. If the confirmation of engineering quantity is involved, it must be countersigned by the representative of Party A and the project manager * * * and stamped with the special visa seal of Party A, both of which are indispensable.

3. The technical liaison sheet of quantities signed by settlement book, Party A, Party B and the supervisor determined by both parties is an annex to this contract, which has the same legal effect as this contract.

4. This contract is made in sextuplicate, with Party A holding four copies and Party B holding two copies. This contract shall come into effect as of the date of signature and seal by both parties.

5. Matters not covered in this contract or disputes arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled by the people's court where the maintenance project is located.

Party A: Party B:

(Seal) (Seal)

Legal representative:

(signature) (signature)

Handler: Handler:

(signature) (signature)

Part II of the Project Construction Agreement Party A: Project Department of Bid A of Hangzhou Sijianjin City Garden Phase II

Party B:

Through friendly negotiation between Party A and Party B, Party A decides to transfer the 29#, 3 1#, 32#, 34#, 36#, 38# and 39# projects.

Contract the project to Party B, and sign this agreement in order to ensure the smooth progress of the project.

As follows:

1. Party B shall be responsible for all sporadic work, such as chipping off uneven concrete nails on the indoor ceiling. During the water lifting test in the kitchen and bathroom, if there is leakage or water seepage that affects the quality of the coating project, Party B is obliged to take the initiative to repair it. During the construction of the air-conditioned tunnel, Party B is responsible for repairing the polluted wall. Details where the dimension deviation of the inner corner of the ceiling exceeds the specification requirements shall be handled.

Party A shall provide Party B with outdoor distribution box, vertical transportation derrick and other on-site construction conditions without increasing according to the existing configuration.

2. Black cement is used to repair the uneven joints of the ceiling. If the ceiling is scraped with black cement in a large area, each set will be fined 100 yuan.

3. Party B must establish a safety network according to the drawings, determine full-time safety management personnel, and Party A shall carry out relevant safety education.

4, aerial work must wear a seat belt, into the work area must wear a helmet, not illegal construction, brutal construction.

5. Party B's construction team leader is responsible for all management work in the construction, and Party A will supervise it. In case of safety accident, all responsibilities shall be borne by Party B..

6. On the premise of ensuring safety, Party B will ensure the quality and time to complete the construction period. If the delay is one day, the penalty will be 1 1,000 yuan, and so on.

7. This agreement shall be valid from the date of signing to the date of project acceptance.

8. If theft, fighting and gambling are found, once found, a fine of 3,000 yuan will be imposed. If the second discovery is cleared, this agreement will be invalid, and if the circumstances are serious, it will be handed over to the public security organ for handling.

9. This Agreement is made in duplicate, with each party holding one copy.

10, and the construction period is 20xx65438+February 20th.

1 1. Payment method: 800 yuan/person shall be paid for the living expenses of the workers every month, 80% of the total project price shall be paid when the workers leave the site, 90% of the total project price shall be paid within three months after the completion acceptance, and the balance shall be paid two years later (if the maintenance work is not timely or in place, Party A shall arrange maintenance personnel, and the expenses shall be deducted from Party B's warranty fund).

Party B shall submit the worker's time card and salary card (signed by the worker himself) on the 5th of each month, otherwise, after investigation by the Municipal Construction Management Office, all consequences shall be borne by Party B..

Remarks: During the construction period and after the completion of the project, the garbage should be cleaned in a timely and civilized manner. Do not spit fast and other barbaric construction.

Party A: Project Department of Bid A of Hangzhou Sijianjin City Garden Phase II.

Party B:

date month year

Article 3 of the project construction agreement was issued by _ _ _ _ _

Contractor: _ _ _ _ _ _ _

In order to further clarify the responsibilities, rights and obligations of Party A and Party B, on the basis of the Construction Project Contract of Shuanglongyuan Commercial and Residential Building Project in Puding County, Anshun City, according to the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), and in combination with the specific conditions of this project, Party A and Party B sign this supplementary agreement on a voluntary basis.

I. Overview of the Project

1, project name: _ _ _ _ _ _

2. Project address: _ _ _ _ _ _

3. Building area: _ _ _ _ _ _

4. Structure type: bottom frame structure, bottom brick-concrete structure 6+ 1.

5. Design unit: _ _ _ _ _ _

6. Supervision unit: _ _ _ _ _ _

Second, the project content and contract scope

1. The exterior wall brick was replaced by exterior wall paint.

The sliding door of the living room has been cancelled.

3. This project has seven floors and the structure is inclined.

4. Stairs should be polished into cement mortar surface.

5. The 40 × 40 dark gray grid of the external wall is cancelled.

6. The door with windows (MC-2324) between the kitchen and the balcony was cancelled, and the balcony was changed into a closed kitchen. The agreement was a supplementary agreement for the demonstration of engineering construction.

7. The rest shall be constructed according to the original drawing.

Three. Term of the contract (all the dates listed in this agreement are calendar days)

1. Commencement and completion dates

1. 1 Commencement date: _ _ _ _ _ _ _ _ _ _; Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four. mode of payment

This project is contracted according to the construction area, RMB/m2; In the process of construction, if the engineering quantity is increased according to the requirements of Party A, it shall be calculated according to the price negotiated by both parties; This project is the main second-floor advance payment. Party A shall pay Party B 30% of the total contract price after the installation of the second floor precast slab; Party A shall pay15% of the total contract price to Party B after the installation of the main five-story precast slab is completed; Party A shall pay Party B 20% of the total contract price after the seventh floor is completed; After the interior and exterior decoration is completed, Party A shall pay 20% of the total contract price to Party B, and the rest shall be paid within one month after the acceptance.

Verb (abbreviation of verb) The entry into force, termination and dispute settlement of a contract.

1. In addition to the normal quality assurance, this contract will be terminated after both parties have completed all the obligations stipulated in this contract.

2. This Supplementary Agreement is made in sextuplicate (including two originals), with each party holding one original and two copies.

3. This supplementary agreement is an immaterial supplement to the Construction Contract of Shuanglongyuan Commercial and Residential Building Project in Puding County, Anshun City. In case of inconsistency, this supplementary agreement shall prevail.

4. Any dispute arising from the performance of this Agreement shall be settled by both parties through negotiation. If no settlement can be reached through negotiation, it shall be submitted to Chengdu Arbitration Commission.

5. This supplementary agreement shall take effect within 5 days from the date of signature by both parties.

Party A: (Seal) Party B: (Seal)

Legal representative:

Tel: Tel:

Fax: Fax:

Bank of deposit: Bank of deposit:

Bank account number Bank account number:

Signature Representative: Signature Representative:

Year, month, sun, moon, sun.

Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction project of this construction project and conclude this agreement.

I. Overview of the Project

Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the scope of project contracting

Contract scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the term of the agreement.

Start date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Completion date of the Property: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total calendar days of agreed construction period: _ _ _ days

Four. Delay in construction period: If the construction period is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A.

1. Design change and engineering quantity increase;

2. Water, electricity and gas cut-off for more than _ _ _ _ _ hours within one week due to reasons not attributable to Party B;

3. Force majeure natural conditions;

Verb (abbreviation of verb) project completion: Party B must complete the project according to the completion date agreed in this agreement. If the project cannot be completed according to the completion date agreed in this agreement due to Party B's reasons, Party B shall be liable for breach of contract.

Engineering quality standard of intransitive verbs: _ _ _ _ _ _ County Quality Inspection Bureau shall prevail. (excluding material quality)

Seven. agreement price

Amount: RMB per square meter of construction area × square meter of total construction area.

Advance payment for the project: ¥ 10,000 yuan.

Payment on completion date: _ _ _% of the remaining total amount.

Settlement of project funds: check and accept that there are no construction quality problems within _ _ _ months after the completion of the project, and settle the arrears.

Eight. Documents constituting the agreement

1. protocol

2. Standards, specifications and related technical documents

3. Cartography

The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this agreement.

Nine. Party B promises to Party A to carry out the construction and completion according to the agreement, and undertake the project quality warranty responsibility within the quality warranty period.

X. Party B must submit a written application to Party A 10 in advance for building materials needed in the construction process, and Party A shall provide all the buildings in time without delay to ensure smooth flow during the construction. If Party B causes unnecessary waste in the construction process, it shall compensate according to the market price.

XI。 Party A has the right to supervise Party B's project. In the internal structure of pigsty, Party B shall carry out the construction according to Party A's requirements. During Party B's construction, Party A shall not transfer Party B's construction personnel at will.

12. This agreement is made in duplicate, with the same effect, and the employer and the contractor hold one copy respectively.

Thirteen. Entry into force of the agreement

The conclusion time of this Agreement is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

The conclusion place of this Agreement is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

This Agreement shall come into force after both parties reach an agreement on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Employer: (signature) _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor: (signature) _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _