3 demonstration construction general contracting contract

Construction project contracting shall conclude a written contract according to law, clarifying the rights and obligations of both parties. How to write a simple project construction contract? The following is a simple construction project contract I compiled. Please refer to.

General contracting of template construction 1

Employer (Party A): _ _ _ _ _ _ _

Contractor (Party B):

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party A and Party B sign this contract on the principle of equal consultation, honesty and trustworthiness, and abide by it jointly.

I. Overview of the Project

1, project name: circulating water zero workshop reconstruction project

2. Project location: _ _ _ _ _ _ _ _

3. Project content: The design and transformation of construction drawing mainly includes the transformation of arc screen pool, air flotation pool, four-stage biological filter, anti-skid floor of workshop, drainage ditch and equipment room.

Second, the construction period requirements

The project duration is 40 calendar days. Due to the influence of design changes, bad weather or other irresistible factors, the construction period can be extended accordingly through consultation between both parties. If the construction period is delayed for one day without reason, 5‰ of the total project amount will be deducted.

Third, the way of contracting.

This project is contracted by the contractor, and all engineering raw materials and construction auxiliary materials are provided by the construction unit.

This project shall not be subcontracted.

Four. Contract price

The contract cost of this project is RMB 5,654.38+500,000 Yuan only (five hundred and fifteen thousand Yuan only). If there is any design change or increase or decrease in engineering quantity, the actual engineering quantity shall be adjusted with reference to the contractor's quotation.

Verb (abbreviation of verb) engineering quality and acceptance

1, engineering quality standard: qualified

2, the construction unit to ensure the construction according to the design drawings, the construction unit to ensure the quality of raw materials.

3. After the completion of concealed works and individual projects, the construction unit shall immediately submit the acceptance notice, and the construction unit shall conduct the project quality acceptance.

The main responsibilities of both sides of intransitive verbs

(1) Party A

1. Provide detailed construction drawings in time.

2, timely supply of raw materials and ensure the quality.

3. Send site representatives to supervise and inspect the materials, quality and progress of the project, and coordinate various matters at the site.

4. Pay the project payment according to the contract, and bear all the consequences caused by the default of the project payment.

(II) Party B

1. Set up water and electricity lines in the construction battery limit.

2, in strict accordance with the design drawings for construction, to ensure the quality and progress of the project.

3. Actively cooperate with Party A to coordinate and solve various problems on site.

4, civilized construction, tools and materials neatly, ensure the rational use of materials. If you waste raw materials, you must pay compensation according to the price.

5, in strict accordance with the safety production operation procedures. If an industrial accident occurs due to illegal operation, Party A shall be responsible, and Party A shall not bear any responsibility.

6. According to the construction requirements of construction projects, provide construction logs, issue official national tax invoices, and cooperate with Party A's acceptance work. Specific matters shall be negotiated by both parties according to the actual situation.

Seven, project payment

Complete all the contract contents and pay 95% of the contract price. The other 5% will be used as quality deposit, which will be paid without interest after one year from the date of completion.

Eight. responsibility for breach of contract

Any dispute between the two parties shall be settled through consultation. If negotiation fails, a lawsuit can be brought to Laizhou People's Court.

Nine. supplementary terms

This contract is made in duplicate and shall come into effect after being signed and sealed by the representatives of both parties.

Party A: _ _ _ _ _ _ _ Party B:

Legal representative:

Address: Sanshandao Street, Laizhou Address:

Tel: Tel:

Demonstration construction general contracting II

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

I. Overview of the Project

1, project location:

2. Project name:

3. Building area: calculated according to actual area. The total construction area is not less than

2. All projects of the project: contracting, contracting materials, depreciation and new construction, water and electricity installation: sewage pipes, muck and garbage removal, indoor 888, bathroom, kitchen, fire room wall tiles, switches, sockets, faucets, etc.

3. Project cost: RMB per square meter. The total price is 10 thousand.

Four. Construction date: month, except weather (such as rainy day). In case of overdue construction, Party B shall compensate Party A for its losses and impose a fine of 100 yuan for one day overdue. By analogy, it will be deducted from the total project cost. The construction period starts from.

5. Payment method: payment shall be made on schedule, that is,% of the total price shall be paid after the demolition of the old house,% after the foundation pouring,% after the laying of the roof slab on the second floor and% after the main body is completed. After passing the inspection, the total amount will be kept as quality deposit, and the rest will be settled. It's time for Party A to return the quality deposit in one lump sum.

6. Construction requirements: Party B must pay attention to the technical quality and safety according to the design drawings, and shall not cut corners or cheat Party A, otherwise Party A has the right to stop the construction and investigate the responsibilities.

1. Party B shall issue the construction drawing, water and electricity diagram, nearby construction requirements, construction process flow chart, etc. Construction shall be carried out according to the drawings after confirmation by Party A. ..

2. The floor thickness must be10-12cm. After laying floor tiles and wall tiles, the joints shall not be uneven, and the surface texture shall not be smooth, uneven, uneven, etc. After the shop is stuck, the ground shall not be uneven and stagnant.

3. After scraping 888, the wall surface shall be free of unevenness, scratches, scratches and unevenness. 888 needs to be shaved three times.

4. Foundation and cast-in-place reinforced concrete require "Pingtang" brand 42.5 cement. 32.5 cement of other brands can be used for bricklaying, and copper core wires are used for indoor concealed wires, and the conductor sections of main wires and kitchen stoves are not less than 4cm2. The section of the socket wire in each room shall not be less than 2.5cm2, and all wires must be sheathed.

The first floor of the house is 3.2 meters high, and the second and third floors are 3.0 meters high. Roofs, balconies, kitchens and bathrooms must be waterproof, and they shall be responsible for the corresponding compensation.

6. Party B shall be responsible for any damage to the neighbor's house in the construction project.

7. If Party B intentionally conceals some projects that must be implemented in the process of architectural decoration design, and then requests to increase them in the process of construction, Party A has the right not to increase any fees.

8. The ground should be waterproof and moistureproof.

9. Each room shall not be less than four 7-hole sockets (except air conditioners, televisions and network cables), two lamps, and two lamp wires shall be reserved. The four rooms on the first floor of the house are cast-in-situ, the turrets on the fourth and a half floors are also cast-in-situ, and the rest are prefabricated panels.

10, the construction of each material needs the acceptance of Party A before construction.

1 1. In the process of project demolition and construction, the quality, safety and hygiene of the site shall be guaranteed. The above processes must meet the requirements of urban management and street communities. The fence around the project is required to be two stories high. Do not meet the requirements, can not be started. The construction process shall not disturb the people, and the construction shall be stopped after ten o'clock in the evening.

7. Building materials: steel, cement, sand ash, wires, water pipes, sewage pipes, door and window frames, prefabricated panels, switches, sockets, faucets and other materials must be qualified products certified by the state.

1 grade and I steel should be produced by Xianggang.

2. The secondary steel bar adopts the double diamond brand steel bar produced by Lianyuan Iron and Steel Company.

3. Doors (rolling gates, security doors, solid wood doors).

4. The reinforcement of column beam is 14φ.

5. Party B is responsible for pasting all floor tiles and sweeping bricks on the first floor. The area of 65,438+000 square meters on the second and fourth floors is RMB per square meter (including pasting sweeping bricks and cement plastered stairs). )

6. Grade 42.5 cement produced by cement flat pond.

7. Electrical material: copper wire The West Lake Jinbei copper wire produced by Hengyang.

Socket switch: produced by national genuine manufacturers.

8. Windows: Xiangrui brand plastic-steel windows are adopted.

9. Sewer pipes are produced by domestic genuine manufacturers (diameter 200mm).

10. If the excavation depth of the foundation foot exceeds 1 m, both parties shall settle it through negotiation.

Eight. Scope of safety responsibility: from the date when Party B starts construction to the date when Party A passes the acceptance, Party A will not bear all man-made and non-man-made safety accidents and illegal penalties within this date, including the demolition of old houses and the construction of new houses, so Party A requires it.

Party B shall establish the idea of safety production first and quality first, and carry out civilized construction from beginning to end.

9. Security: During the construction period, Party B shall be responsible for the security during the day and night until the project is completed and accepted by Party A. ..

X. responsibilities of party a: make good preparations before construction, and coordinate with neighbors and surrounding units. Supervise the construction, supervise the progress, check the quality of materials and projects, and handle problems in time when found. If Party A needs to change the construction scheme, it shall negotiate with Party B in time. If the value exceeds RMB, Party A shall compensate Party B appropriately. If it does not exceed RMB, no compensation will be paid.

XI。 supplementary terms

1. This contract is made in duplicate, with each party holding one copy.

2. This contract shall come into effect as of the date of signature and seal by both parties, and shall be terminated after the project is completed and accepted and the project payment is settled.

3. After the signing of this contract, if Party A and Party B need to propose amendments, they will supplement them after consultation.

Party A (signature): Party B (signature):

Year, month, sun, moon, sun.

Demonstration construction general contracting 3

Project name: _ _ _ _ _ _ _

Project number: _ _ _ _ _ _

Employer: _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _

Signature time: _ _ _ _ _ _ _

Signing place: _ _ _ _ _ _

In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Engineering Contracts and relevant regulations, and in order to clarify the rights, obligations and economic responsibilities of both parties in the construction process, this contract is signed by both parties through consultation.

First project

I. Project Name: _ _ _ _ _ _

Two. Project location: _ _ _ _ _ _ _

III. Project Approval Unit _ _ _ _

Approval number _ _ _ _ _ (refers to the document number of the authority that has the right to approve the project)

Project supervisor: _ _ _ _ _ _ _

Four. Scope and content of the contract: (see the project schedule for details); Project construction area _ _ _ _ (square meters); Others: _ _ _ _ _ _

5. Project cost: _ _ _ _ _ _ (ten thousand yuan), of which civil engineering: _ _ _ _ _ _ (ten thousand yuan), installation: _ _ _ _ _ _ _ _ (ten thousand yuan).

Article 2 Construction preparation

I. Owner:

1 before. ____ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Before _ _ _ _ _ _, be responsible for connecting the general water source, power supply and transformer (including water meter and switchboard) at the construction site to meet the needs of construction water and electricity. Do a good job of site leveling and obstacle removal within the red line.

3. Submit the building permit within _ _ _ days after the signing of this contract.

4. Within _ _ _ days after the signing of the contract (subject to the final signed drawings), provide _ _ _ copies of complete construction and installation drawings and _ _ _ _ copies of construction technical data (including geological and leveling point coordinate control points).

5. Organize contractors, design units and relevant departments to participate in the joint review of construction drawing disclosure, and make joint review minutes signed by the three parties, and make them in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the contractor:

1. Responsible for the laying, management, use and maintenance of temporary roads, temporary facilities and water and electricity pipelines in the construction area;

2. Organize construction management personnel, materials and construction machinery to enter the site;

3. Prepare the construction organization design or construction scheme, construction budget, general construction schedule, mobilization plan (including monthly plan) of materials, equipment, finished products and semi-finished products, and water and electricity utilization plan, and send them to the owner.

Article 3 Project duration

A, according to the national time limit for a project quota and use needs, the two sides agreed that the total project duration is _ _ _ days (calendar days), starting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the contractor shall issue a notice of commencement to the owner _ _ _ days before commencement.

Three. In case of any of the following circumstances, the construction period shall be postponed accordingly after the visa of the on-site representative of the Employer:

1. According to the construction preparation regulations, the construction site, water and electricity roads cannot be provided, and obstacles cannot be removed, which affects the construction on the site;

2. The materials, equipment, finished products or semi-finished products supplied by the Employer cannot meet the construction needs due to defects found during delivery or need to be repaired, matched, replaced or replaced, which will affect the progress;

3. Major design changes that are not within the scope of the lump sum coefficient, and the engineering geological data provided are not allowed, resulting in changes in the design scheme or affecting the progress due to the inability to construct;

4. In the process of construction, power failure for more than 8 hours or continuous interruption for more than 3 days (more than 4 hours at a time) will affect the normal construction;

5. The supervision visa is not timely due to the contractor, which affects the construction of next working procedure;

6. Failing to allocate the advance payment, project progress payment or the price difference of purchased materials as stipulated in the contract, which affects the construction;

7. Force majeure factors delay the construction period.

Article 4 Project Quality

1. According to the research requirements of both parties, the quality of this project has reached _ _ _ _.

Second, the contractor must carry out the construction in strict accordance with the construction drawings, documents and construction project specifications, procedures and standards issued by the state, and accept the supervision of the representative sent by the employer.

Three, the contractor must abide by the following provisions in the construction process:

1. The main raw materials, equipment, components and semi-finished products provided by the contractor must provide quality certificates according to relevant regulations, or can be used in the project only after passing the inspection;

2. The main raw materials, equipment, components and semi-finished products provided by the Employer must also have quality certificates before they can be used in the project. The change or substitution of materials must be approved by the original design unit, and a formal written notice and a visa from the employer's representative can be used in the project;

3. The concealed works must be inspected and accepted by the owner's representative before the next working procedure can be carried out;

4. The contractor shall evaluate the project quality of disciplines, divisions and units according to the quality inspection and evaluation standards, and send the unit project quality evaluation results to the Employer and the quality supervision station in time. After the completion of the unit engineering structure, the intermediate acceptance of the structure shall be carried out in conjunction with the construction unit and the quality supervision station;

5. The contractor shall promptly report the quality accidents in construction to the employer's representative and the local construction engineering quality supervision station. General quality accident treatment results should be sent to the employer and the quality supervision station for the record; The treatment scheme of major quality accidents shall be studied by design units, quality supervision stations, contracting units and other units, and implemented after being signed by design and construction units;

6. After the completion of the project, the contractor shall guarantee the project in accordance with the regulations, and the warranty time shall be calculated from the date of completion acceptance.

Article 5 Supply, acceptance and price difference treatment of building materials and equipment

1. Physical objects or indicators of the following materials and equipment provided by the Employer (see Table 2 for details);

2. In addition to the materials and equipment supplied by the Employer, other materials and equipment shall be purchased by the Contractor;

Three, the materials and equipment supplied by the employer and purchased by the contractor must be accompanied by a product certificate before they can be used in the project. If either party thinks that the information provided by the other party needs to be reinspected, it shall be allowed to do so. Only after the re-inspection meets the quality requirements can it be used in the project, and the re-inspection fee shall be borne by the party requesting the re-inspection; Do not meet the quality requirements, should be handled in accordance with the relevant provisions, the reinspection fee shall be borne by the material equipment supplier.

Four. Treatment method for price difference of materials and equipment in this project: _ _ _ _ _ _ _

Article 6 Payment and settlement of project price

The payment and settlement of the project price shall be carried out in accordance with the Measures for Settlement of Capital Construction Project Price formulated by the People's Construction Bank of China.

1. Within _ _ _ _ days after the signing of this contract, the Employer shall pay _ _ _% of the total contract price (or the investment amount of the current year) for the preparation of materials, totaling RMB _ _ _ _. The cost of temporary facilities is RMB _ _ _% of the total contract price of civil works, and _ _ _% of the labor cost is RMB for installation works; The price difference of materials and equipment is RMB 10,000.00 Yuan, which shall be paid in installments, and the time and amount of each payment shall be.

Second, the employer must pay the progress payment according to the verified progress within _ _ days after receiving the monthly progress report from the contractor. When the progress payment reaches _ _% of the total contract price, the reserve fund will be deducted gradually according to the specified proportion.

Three, the project price payment reaches 95% of the total contract price, no longer pay according to the schedule, after the completion acceptance, after the expiration of the warranty period, even with interest (financial allocation does not bear interest) one-time payment to the contractor.

4. If the Employer defaults on the progress payment or the final payment, it shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ to the Contractor.

5. If the employer defaults on the difference between the project payment and the purchased materials, which really affects the progress of the project and causes the contractor to stop working or slow down, it shall be borne by the employer.

Settlement method of intransitive verb contract fee: _ _ _ _ _

Seven, the contractor within _ _ days after the completion acceptance of a single project, the completion settlement documents will be sent to the employer and the handling bank for review, and the employer will complete the review within _ _ _ days after receiving the settlement documents. If no written objection is raised at the expiration of the period, the undertaking bank may request the handling bank to allocate funds after examination and approval.

Article 7 Construction and Design Changes

1. The design drawings, specifications and relevant technical data delivered by the Employer shall serve as an effective basis for construction. Before construction, the owner shall organize design disclosure and tripartite joint review, and form joint review minutes as supplementary basis for construction. The employer and the employer shall not modify it without authorization.

2. If design errors or serious irrationalities are found during the construction, the contractor shall promptly notify the Employer in writing, and the Employer shall study and determine the modification opinions or change the design documents in time together with the design and other relevant units, and the contractor shall carry out the construction according to the modified or changed design documents. In case of cost increase (including rework loss, shutdown, slowdown, relocation of personnel and mechanical equipment, actual loss of overstocked materials and spare parts), the Employer shall be responsible for and adjust the contract cost.

3. On the premise of ensuring the engineering quality and not lowering the design standard, the contractor puts forward reasonable suggestions to modify the design and process, which will be implemented with the consent of the employer, the design unit or the relevant technical department, and the saved value will be distributed according to the provisions of the state.

4. If the Employer needs to change the design, the original design unit must issue a formal notice of change and modify the drawings before the Contractor can implement it. Major modification or cost increase must be negotiated separately, and the contractor can only implement it after obtaining the investment implementation certificate and complete technical data and design drawings.

Article 8 Project acceptance

1. The completion acceptance shall be based on the Interim Provisions on Completion Acceptance of Capital Construction Projects, Code for Construction and Acceptance, Standard for Quality Inspection and Evaluation of Construction and Installation Projects promulgated by the state, and the completion acceptance regulations formulated by relevant departments in the State Council, as well as construction drawings and specifications and construction technical documents.

Second, underground engineering and structural engineering must have hidden acceptance visa, pressure test, water test, impermeability and other records in engineering construction. After the quality of the completed project has passed the inspection by the local quality supervision department, the employer shall go through the visa acceptance formalities in time.

Three, after the completion of the project acceptance, the employer can use.

Within the specified warranty period, all quality accidents and quality defects caused by construction shall be guaranteed by the contractor free of charge. The warranty conditions, scope and duration shall be implemented in accordance with the Construction Project Warranty Measures (Trial) issued by the Ministry of Urban and Rural Construction and Environmental Protection (84) No.79 Notice.

Article 9 Liability for breach of contract

Contractor's responsibilities:

A, the project quality does not conform to the provisions of the contract, responsible for free repair or rework. If the delivery is delayed due to repair or rework, the overdue penalty shall be paid.

Two, the project can not be delivered within the time limit stipulated in the contract, according to the provisions of Article 9 of the contract on the reward and punishment of the time limit for a project in advance or delay to pay late fees.

Employer's responsibilities:

1. If the contractor fails to perform its responsibilities as stipulated in the contract, it shall compensate the contractor for the actual losses caused by the delay in the completion date.

Two, due to design changes and design errors caused by the project stop, delay or rework, measures should be taken to make up for or reduce losses. At the same time, compensate the contractor for the actual losses caused by shutdown, slowdown, rework, transshipment, relocation of personnel and mechanical equipment, and backlog of materials and components.

Three, the project without acceptance, the employer in advance or unauthorized use, the resulting quality or other problems shall be borne by the employer.

Four, the contractor fails to accept after receiving the acceptance notice, pay overdue liquidated damages in accordance with the provisions.

5. If the project funds are not allocated as stipulated in the contract, the contractor shall be compensated for three ten thousandths of the overdue payment amount every day according to the bank's regulations on overdue payment methods.

Article 10 Dispute settlement methods

Any dispute arising from the execution of this contract shall be settled by both parties through consultation. If negotiation fails, both parties agree to arbitrate by the _ _ _ _ _ _ Arbitration Commission (if both parties have not agreed on an arbitration institution in this contract and have not reached a written arbitration agreement afterwards, they may bring a lawsuit to the people's court).

Article 11 Supplementary Provisions

I. This Contract was signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ According to the regulations, the contract for authentication (notarization) must be handled and sent to the industrial and commercial and notary departments where the building is located for authentication (notarization).

2. This contract shall come into effect after being signed by representatives of both parties and stamped with official seals or special seals for the contract. If it is necessary to apply for certification (notarization), it will take effect from the date of completion of certification (notarization); The project completion acceptance meets the requirements and will be terminated after the project payment is settled.

III. After the signing of this contract, if both parties need to propose amendments, a supplementary agreement can be signed as a supplementary contract to this contract after consultation.

Employer (seal):

Representative (signature):

Address:

Telephone message:

Date, year and month

Contractor (seal)

Representative (signature):

Address:

Telephone message:

date month year

Three related clauses in the general contract of demonstration project;

★ The latest three model construction general contracting contracts in 2020.

★ Three demonstration construction general contracting contracts in 2020

★ 3 copies of the latest standards for general contracting of model projects.

★ Demonstration construction general contracting contract

★ 3 pieces of model construction general contracting.

★ General contracting for demonstration construction of engineering projects

★ 3 copies of model project contract.

★ Three general versions of engineering contract templates

★ 3 Model construction contract

★ 3 Model general contracting management contract