Agreement for construction contract labor and materials (5 articles)

A contract is also called a "contract", or "Contract" in English. In legal theory, there are different understandings of the concept of contract. Below is the agreement letter (5 articles) for construction contract labor and materials that I compiled. I hope you like it.

Construction Contract Contracting Agreement for Labor and Materials 1

Party A:

Party B:

Identity Certificate No.:

After voluntary negotiation between Party A and Party B, Party A will hand over the demolition concrete floor, outbound gravel, ash ballast, pipe laying, and concrete floor work to Party B for construction. The specific matters will be approved by Party A and Party B. The two parties negotiated and signed the contract as follows:

1. The construction period of the above-mentioned project: 15 days from the year, month, and month of the construction period (extended in case of thunderstorms, Party B shall not delay the construction date of the construction period without reason, and must complete it according to the agreed time).

2. Construction location: The intersection of Dashan Road and Eleventh Road, East China Decorative Materials Market and Plywood Market.

3. The project should comply with national quality requirements and regulations. The materials used must comply with relevant national standards and certificates. The construction results must meet Party A’s requirements. Party B must do a good job in the construction project carefully and meticulously. For every project, the site must be clean after completion and no garbage should be piled up.

4. Verification and confirmation of project quantities: After the completion of the project, Party A and Party B *** will jointly inspect and accept the project (including project quality acceptance and actual acceptance of project quantities).

5. Project cost: breaking concrete, transporting crushed lime ballast, laying pipes, and pouring concrete, 700 yuan per meter (including labor and material costs). Mud sewers and sedimentation wells cost 2,000 yuan each (including labor and material costs). The sewer is predicted to be 96 meters long, and the number of sedimentation wells is tentatively determined to be 6 (calculated based on actual meters after construction). The total cost of the project is approximately 79,200 yuan, capitalized: 70,000,900,200 yuan.

6. Quality requirements: The quality of the project shall meet the requirements of the provincial and municipal construction committees for sewer laying projects and the requirements of Party A. If quality problems occur after the completion of the project (except quality problems caused by Party A during use), which are the responsibility of Party B, Party B will provide free warranty with a one-year warranty period. Party B will be responsible for any safety accidents that occur during the construction process.

7. Payment method: After Party B's material workers enter the construction site, Party A needs to pay 20% of the project cost to facilitate Party B's preparation of materials. After laying the pipeline, Party A pays 40% of the project cost. After Party A passes the acceptance inspection, Party A will pay 30%; 10% to be paid within 15 days after the warranty period expires.

8. Other matters not covered shall be resolved through negotiation between the two parties.

This contract is made in four copies, three copies for Party A and one copy for Party B, and shall become effective upon signature.

Party A:

Party B:

__ month __ day, 20__

Agreement on contracting labor and materials for construction contract 2

Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

According to the "Contract Law of the People's Republic of China" In accordance with the relevant spirit of the "Construction Project Contract Regulations", after negotiation between Party A and Party B, Party A agrees to contract the project to Party B. In order to clarify the rights and obligations of both parties, the following agreement terms are signed for both parties to abide by.

1. Project name:

Location:

2. Contracting method

3. Project contracting content

4. Contract price

5. Payment method

6. The total construction period requires three working days.

7. Party A’s Responsibilities

1. When Party A notifies Party B to enter the site, the construction site should have three connections and one equal access to start construction.

2. Party A shall pay Party B the project payment in a timely manner according to the contract payment method. If Party A fails to pay the project payment as stipulated in the contract, causing the construction to be unable to proceed, Party B may stop the construction and Party A shall bear the responsibility for the completed project. losses and all economic losses of Party B.

8. Party B’s responsibilities

1. Party B shall complete the construction within the construction period as stipulated in the contract and meet the acceptance requirements.

2. Party B shall bear the responsibility for project quality problems and construction delay caused by Party B: quality problems shall be repaired and solved by Party B until it is qualified, and a daily fine of RMB yuan will be imposed during the delay period.

9. Project Quality, Safety and Warranty

1. Party B shall carefully construct according to the drawings, and the project quality shall meet the acceptance standards.

2. Party B will be responsible for all safety accidents caused by Party B. Party A does not assume any responsibility.

3. After the project is completed and accepted, Party B is responsible for the quality of the construction project for one year.

10. Disputes and Solutions

Any matters not covered shall be resolved through negotiation between Party A and Party B. If reconciliation or mediation fails, the dispute shall be resolved in the following ways:

The first solution: both parties reach an arbitration agreement and apply for arbitration to the agreed arbitration committee;

The second solution : File a lawsuit with the people's court with jurisdiction.

11. This contract is made in triplicate, one for Party A and two for Party B. It will take effect after being signed and sealed by both parties.

Party A:

Party B:

__ month __ day, 20__

Agreement on contracting labor and materials for construction contract 3

Construction unit: (hereinafter referred to as Party A)

Contracting unit: (hereinafter referred to as Party B)

After Party A’s assessment of Party B’s professional qualifications for construction, It is agreed to entrust Party B with the toilet waterproofing project of the Yueyang Junlin International New City Project. In order to clarify the rights, obligations and responsibilities of both parties during the construction process, and in accordance with the principles of ensuring project quality, project progress, and project safety, the following contract terms are negotiated and determined*** Comply with the implementation.

1. General Principles

1. Project name: Yueyang Junlin International New City Project Building

2. Project content: According to the project construction contact sheet and design change notice According to the requirements, G waterproof coating should be used for kitchen and bathroom waterproofing projects.

2. Contracting methods:

Party B contracts for work, materials, quality, management, safety, progress and other contracting methods.

3. Project cost:

4. Bathroom waterproofing is RMB per square meter; settlement will be based on the actual area.

5. Quality standards:

Party B shall ensure that the waterproofing project reaches excellent standards and shall be constructed in strict accordance with the waterproofing project specifications and the current relevant standards of ____ City, as well as the design drawings and Party A’s requirements. It is guaranteed to have no skin, no hollowing, no delamination, no dew points, smooth and even, a certain bonding force with the base layer, and meet the design thickness and other quality requirements.

6. Responsibilities of both parties:

1. Party A’s responsibilities:

(1) The construction plan should be proposed in advance and the working surface should be arranged to meet waterproof construction standards Submit to Party B for construction.

(2) A construction period plan should be proposed, but unavoidable factors such as weather and manpower should be taken into account and the construction period will be postponed.

(3) Cooperate with Party B in construction, such as providing necessary vertical transportation, construction site accommodation for workers, etc.

(4) Party A has the right to supervise and inspect Party B’s project quality during the construction process, and if any problems are found, require Party B to make rectifications within a time limit.

2. Party B’s responsibilities:

(1) Wait for Party A’s notification, bring waterproofing materials to the site immediately, and submit waterproofing material certificates, test reports and ____ Municipal Construction Bureau issued The license shall be used after random inspection by Party A's on-site person in charge.

(2) Cooperate with the overall progress of the ____ City Junlin International New City project and carry out construction according to the construction plan proposed by Party A. Except for unavoidable factors, no artificial delays are allowed.

(3) All rules and regulations of the construction site must be observed, and no violations shall be allowed. Otherwise, Party A shall be subject to various forms of punishment.

(4) Construction should be carried out strictly in accordance with waterproofing engineering standards, and problems should be solved in a timely manner to ensure that the quality of the project reaches excellent standards, and the project should be guaranteed for _________ years.

7. Payment method:

There is no advance payment for this project. Party A will pay the progress payment according to Party B’s progress. Party A will pay the entire project after the project is completed and accepted to excellent standards. % of the payment will be given to Party B, and % of the project payment will be retained as warranty deposit. If Party B has no quality problems after the _________ year warranty expires, Party A will pay the balance.

8. This contract is made in triplicate. Party A holds two copies and Party B holds one copy. They have the same legal effect. When the _________ year warranty period expires and Party A pays the balance, the contract will automatically expire. . Unfinished matters will be resolved through consultation by both parties.

Party A (official seal): _________

Party B (official seal): _________

__month__day, 20__

Agreement on labor and materials contracting in the construction contract 4

Contract issuing party (full name):

Contractor (total name):

In accordance with the "People's *** of the People's Republic of China" "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws and regulations, following the principles of equality, voluntariness, fairness and honesty and trustworthiness, both parties reached consensus on the construction of this construction project and entered into this contract.

The contents of the contract are as follows:

1. Project Overview

Project Name: Vegetable Planting, Photovoltaic Power Generation

Project Location: Liang, Jiaxiang County Yanweihe Village, Baosi Town

Project content: Construction and design of all ancillary projects such as road hardening, greening, water supply and drainage, wires and cables, street lights, etc. in the park.

Project approval number: to be prepared by the end of 20__

Source of funds: Funds for the project have been prepared before the start of construction.

2. Project contracting scope: large contract, labor contract and materials, ensuring quality and safety, greening and design.

3. Contract period: Roads, water supply and drainage will be completed before the end of 20__ (that is, before December 30, 20__). The specific start date for wires and cables, street lights, greening, etc. will be determined according to the actual construction conditions on the construction site.

4. Quality Standard: Qualified Project

5. Fee Collection Standard: Road hardening, greening, water supply and drainage, street lighting, etc. are all charged according to the latest quota in Shandong Province.

6. Contract price: based on the actual amount of work (see budget statement). The budget statements for ancillary projects such as road hardening, greening, water supply and drainage, wires and cables, street lights, etc. are supplementary clauses to the construction contract of this project and have the same legal effect.

7. Payment method: Party B’s mechanical personnel will pay an advance payment of 35% of the total project price when they enter the site. 70% will be allocated to half of the construction of the project, 97% will be allocated to the completion, and the remaining 3% will be allocated after passing the completion acceptance. Payable within one year.

8. The contract takes effect:

Date, month, and year when the contract is concluded

Place of conclusion of the contract:

Both parties agree that this contract will take effect: .

9. This contract is made in two copies, with Party A and Party B each holding one copy. Unfinished matters shall be resolved through negotiation.

Employer (official seal):

Contractor (official seal):

20____month__day

Construction Contract Agreement for Labor and Materials 5

Construction unit: (hereinafter referred to as Party A)

Construction unit: (hereinafter referred to as Party B)

According to the " ***The Economic Contract Law of the People's Republic of China, the Regulations on Contracting Contracts for Construction and Installation Projects, and relevant provisions. After consensus reached between Party A and Party B, Party A is willing to contract the renovation project to Party B. In order to clarify the responsibilities of both parties and ensure the smooth completion of the project, this agreement is hereby entered into. The following contract terms are agreed upon by ***:

1. Project

1. Project name:

2. Project address:

3. Project scope:

4. Contracting method: Contracting work and materials.

5. Contracting cost: Yuan (in capital letters: ).

2. Project Duration

According to this project, upon mutual agreement between Party A and Party B, the total construction period is days. (Rainy days and special circumstances of force majeure need to be approved by Party A’s representative, and the construction period will be postponed accordingly)

The construction start date is from 20__ to 20__, with a total construction period of days.

3. The completed quality of this project is a one-time qualified project

1. Party B must strictly carry out construction in accordance with the construction engineering specifications, construction procedures and standards issued by the state;

< p> 4. Project Price Payment and Settlement

This project will be paid according to progress, and the specific amount shall be subject to negotiation between both parties.

V. Other Agreements

1: Safety responsibilities and rights assumed by Party A

(1) Party A is responsible for formulating safety production rules and regulations at the construction site and Operating procedures;

(2) Party A has the right to require Party B to strictly abide by production safety laws, regulations, standards, production safety rules and operating procedures, and be proficient in accident prevention measures and accident emergency response plans; < /p>

(3) Party A’s management personnel have the right to stop Party B’s personnel from operating in violation of regulations and impose penalties in accordance with regulations;

(4) Party A has the right to treat employees with poor safety awareness and disobeying safety regulations The commanding Party B personnel are ordered to leave.

2: Party B’s responsibilities and rights

(1) Party B is the person directly responsible for production safety during construction and must strictly implement Party A’s regulations and systems on production safety; < /p>

(2) Party B is responsible for handling medical and work-related injury social insurance for all Party B’s installation and construction personnel, and purchasing appropriate personal accident insurance as needed for personnel engaged in highly dangerous work. If any violation of regulations occurs during the construction process Party B shall be fully responsible for any personal injury or death caused by the operation;

(3) Party B shall be fully responsible for the on-site installation and construction activities. Party B's installation and construction personnel shall not operate in violation of regulations, shall not take risks, and shall not work fatigued. And carry out protective work in accordance with regulations;

(4) Party B’s personnel at the construction site must be equipped with complete safety protective equipment. If the safety construction needs cannot be met, personnel are not allowed to enter the construction site.

6. For other matters not covered, both parties can sign a supplementary agreement, which has the same legal effect as this contract.

Party A:

Party B:

__ month __ day, 20__

Agreement on contracting labor and materials for construction contract (5 articles) Related articles:

★ 5 professional construction project contracting contracts

★ 5 practical construction project contract contract templates

★ Labor and material contracting projects General version of the contract template

★ Construction project construction contract template (selected 5 articles)

★ 5 simple project contract templates

★ Contracting of labor and materials for construction Contract templates

★ Five articles on project construction agreements

★ 5 articles on contract contracts related to construction projects

★ Five articles on simple project contract contracts

p>

★ Construction Project Contract Agreement