A contract to build a factory building

Factory building construction contract construction unit:? (hereinafter referred to as Party A) Construction unit:? (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, Party A and Party B reach an agreement on relevant matters and conclude this contract. * * * Same as compliance.

I. Overview of the Project

project name

Project location:

Second, the scope of project contracting

According to the needs of engineering construction, Party A and Party C are fully responsible for completing the construction of steel structure engineering, including all steel structure engineering (including embedded parts, doors and windows, etc. ) In the design drawings of 2# and 3# workshops, except for brick walls, floors, water and electricity, and fire protection. Party A has reached an understanding with Party B in this regard, and Party B will be fully responsible for the general contracting management of steel structure construction according to the provisions of the general contracting contract (Party B shall effectively manage Party C to ensure the smooth acceptance of this project).

3. Project contracting mode: Under the unified management of the general contractor, Party C shall contract materials, quality, construction period, safety and civilized construction, and materials (materials shall ensure that Party A can pass the quality acceptance), and Party C shall not subcontract them.

IV. Term of the contract:

Party C promises to complete the steel structure construction within 60 calendar days from the date of signing this contract on the premise of ensuring the construction period of the general contracting project. The completion date is September 20th, 20 1 1 year. Party C's construction according to this commitment will not affect the construction period of the general contracting project of this project.

Verb (abbreviation of verb) quality standard

The quality requirement standard of this project is: qualified.

Therefore, Party A and Party B require that the steel structure project subcontracted by Party C must meet the qualified standards and pass the acceptance of the quality supervision station.

6. The total contract price shall be guaranteed, including production, transportation, installation, loading and unloading fees, invoice tax and various unforeseen expenses arising therefrom (the total price shall not be adjusted without major design changes; If there is any major design change, it can be adjusted through negotiation if it exceeds 5% of the total price).

The total fixed contract price of this project is RMB 3.28 million Yuan only (i.e. RMB 3.28 million Yuan only).

(1) Take the design drawings of this project as the annex of this contract.

(2) If there is any major change, both parties shall take the visa as the settlement basis.

Seven. terms of payment

After signing this contract, the advance payment for the project is 328,000 yuan (65,438+00% of the total cost). Pay the project payment after the steel column and steel beam enter the site? 984,000 yuan (accounting for 30% of the total cost). Pay the project payment immediately after the plate enters the site? 656,000 yuan (accounting for 20% of the total cost). Pay 686,000 yuan immediately after the project is completed? Yuan (accounting for 20% of the total cost).

492,000 yuan (65,438+0.5% of the total cost) shall be paid immediately after the acceptance of the project.

The remaining 5% is used as the quality deposit, namely 164000? Yuan, pay off the balance after one year when there is no quality problem.

Eight. Party C promises that Party A and Party B will carry out the construction according to the contract, and undertake the project quality warranty responsibility during the quality warranty period. Within one year after the completion of the project, Party C shall be responsible for the free maintenance of the steel structure engineering quality problems not caused by Party A; Within five years, Party C will maintain the waterproofing of the existing projects free of charge (except for force majeure). After the project is handed over, Party C is responsible for the lifelong paid maintenance and service of the project, and Party C only charges fees and is responsible for the renovation of Party A's project.

Nine. Party A promises that Party B and Party C will pay the fees according to the time limit and method agreed in this contract.

X. Party C promises to Party B and Party A that it will fully perform the contents of this contract. If it cannot be completed on time, it shall voluntarily assume the liability for breach of contract to Party A at a daily rate of 5,000 yuan. If the quality fails to meet the requirements, Party B shall voluntarily assume the liability for breach of contract to Party A at RMB 10 yuan per square meter. Party C also promises that the payment of the above liquidated damages will not affect the other compensation requirements of Party A and Party B for the losses caused by the delay of construction period and quality problems of Party C's project.

XI. Is this project assigned by Party A? Comrade, Party B designates comrade as the person in charge of site construction to coordinate and solve relevant problems in construction. Page 1 XII. Carry out the relevant state regulations on production safety to ensure safe construction. Party C shall be responsible for the industrial accidents and economic losses caused during the construction.

13. The right to interpret this contract belongs to Party A.. Matters not covered can be settled through negotiation. In case of any dispute, it can be settled through arbitration by the arbitration commission in the place where the contract is signed or brought to the people's court.

Thirteen. Entry into force of contract

Date of conclusion of the contract: year month day.

Contract signing place:

This contract shall come into effect after being signed and sealed by Party A, Party B and Party C. ..

Employer (Party A):? General Contractor (Party B)

(official seal)? (official seal)

Legal representative:? Legal representative:

Entrusted agent:? Entrusted agent:

Page 2 Nominated Subcontractor (Party C): (Official Seal) Legal Representative: Entrusted Agent:

Production plant construction contract

Employer Party A (full name):

Contractor Party B (full name):

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of this construction project.

I. Overview of the Project

Project name: production workshop

Project location:

Project content: The building area is 20 10m2, and it is a two-story frame structure.

Second, the way and scope of project contracting:

Contracting method: in addition to the steel bars provided by Party A, contract projects and materials; Scope of contract: all civil works except painting works in the construction drawing.

1, the circular steel bars supplied by Party A shall be straightened by the contractor according to the specification requirements (the secondary steel shall be controlled within 3%, and the tertiary steel shall be controlled within 1%), regardless of the cost.

2. The contractor shall be responsible for unloading the steel bars supplied by Party A and stacking them in the steel yard, regardless of the cost.

3. The quantity of steel bars supplied by Party A shall be supplied according to the consumption of steel bar materials in the tender. If in the actual construction process, the number of steel bars is underestimated or omitted due to the bidder's mistakes, or the steel bars are in short supply due to excessive consumption, Party A will not increase the number of steel bars, and the missing part will be purchased by the construction unit at its own expense according to the brands (Shagang and Yonggang) confirmed by Party A..

4. Professional subcontracting is adopted for the coating project, and the scaffolding used in the exterior wall coating project can use the exterior wall scaffolding of the civil engineering unit, and the general contractor shall give the subcontractor free use. The interior wall coating scaffold shall be considered by the subcontractor, and the cost shall be included in the subcontract price.

5. As the coating works are subcontracted by professionals, the civil contractor shall ensure the smoothness of the brush provided for the walls, cylinders, beams and ceilings. Because the smoothness of the above working face provided by the contractor does not meet the requirements of the specification, the civil contractor should make rectification, and the rectification should meet the requirements of the specification.

III. Term of the contract:

Commencement date: 201September 15 (the specific commencement and completion date is subject to the commencement and completion report), completion date: 201February 14, and construction period: 90 calendar days.

Fourth, quality standards.

Engineering quality standard: qualified

Verb (abbreviation of verb) contract price and adjustment method:

1. After external bidding, the contract price of this project is RMB10,000 yuan; Amount (in words): RMB 1,185,000. (Note: the opening price for completion settlement is 10000 yuan+the amount of reinforcement materials, and the invoice for the amount of reinforcement materials is provided by Party A)

2. The contract price of this project adopts the contract method of total construction drawing price. (Note: The contract fee does not include the quantity of reinforcement materials provided by Party A and the coating engineering cost. )

3. No matter whether the quantities of construction projects included in the construction drawings are omitted or underestimated, the settlement will not be adjusted.

4. The contents included in the construction drawing but confirmed by Party A as unnecessary for construction shall be deducted from the contract price.

5. Due to design changes, visas and other new subheadings (the original contract has no corresponding unit price), the quantities are calculated according to the facts, and the unit price is calculated according to 09 expense quota and 04 pricing table. The measure fee is calculated according to the bid price, and other measure fees are calculated according to the actual occurrence. The total price falls according to the ratio of the negotiated price to the bid budget price, that is, the total price falls by 65,438+07.62% (65,438+0). The unit price of ground materials shall be implemented according to the information price during the construction period. If there is no information price, it shall be quoted by the construction unit and calculated after being confirmed by Party A..

Payment by intransitive verb: 65,438+00% of the contract price shall be paid after the foundation is completed to 0.00%. After the first floor structure is completed and accepted by Party A, pay 10% of the contract price; After the second floor structure is completed, Party A shall pay10% of the contract price; After the completion of building masonry, secondary structure and roof, Party A shall pay 10% of the contract price. After the building decoration is completed and accepted by Party A, Party A shall pay10% of the contract price; After the project is completed and accepted by Party A, Party A shall pay 10% of the contract price and return the project performance payment of 20,000 yuan. After the acceptance of the project, the contractor shall submit the complete completion settlement data on 15, which will be used as the settlement payment after being reviewed and confirmed by Party A. The final payment will be paid in installments within two years from the date of completion settlement confirmation (50% in the first year, 40% in the second year, 65,438+00% as the warranty payment, and paid in the third year), and the final payment will be paid without interest.

Seven, engineering construction requirements:

1 work to ensure the quality is qualified. If Party A finds that Party B fails to comply with the bid registration form (brand, specification, etc.). ), where there are Jerry-building and construction mistakes, Party A has the right to refuse to pay the project payment and ask Party B to make corrections according to the construction specifications and bidding requirements. All expenses arising therefrom shall be borne by Party B. If the construction period is extended, a fine of 1000 yuan shall be paid to Party A for each day of delay.

2, the project warranty measures according to the provisions of the Ministry of construction "construction engineering quality warranty measures".

Eight. Party B shall take full responsibility for all site safety responsibilities during the construction period, which has nothing to do with Party A, and Party A shall not bear any responsibility. The construction unit shall handle relevant insurance, and the expenses shall be borne by Party B. ..

Party B must complete all procedures and materials in the process of project construction, provide them to Party A for the record, and assist Party A in handling relevant procedures.

Nine. Liability for breach of contract:

1. After the winning bidder is determined, if the winning bidder abandons the contract without reason, the bid bond will not be returned.

2. This contract shall come into effect after being signed and sealed by both parties. If Party B breaches the contract and delays the construction period without reason, the bid bond will not be returned, and Party A has the right to claim the economic losses caused by the extension of the construction period from the contractor. For each day of delay, the penalty shall be paid at the rate of 1000 yuan/day.

X this contract is signed according to the requirements of the tender registration form. If there are any matters not covered in the contract, refer to the requirements of the Bidding Registration Form; Other matters not covered shall be negotiated separately by both parties. If negotiation fails, it shall be settled according to the litigation procedure. This agreement is made in quadruplicate.

Party A: (Seal)

On behalf of:

Party B: (Seal)

On behalf of:

Date of signature: 20 12 September.

Employer: Shiyan Beili Industry & Trade Co., Ltd. (hereinafter referred to as Party A)

Contractor: Shiyan Sanfeng Hui Jin Construction and Installation Engineering Company (hereinafter referred to as Party B).

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on this construction project and conclude this contract.

I. Overview of the Project

1. Project name: Shiyan Beili Industry and Trade Co., Ltd. Phase III Factory Building.

2. Project location: No.33 Bailang East Road, Shiyan High-tech Industrial Development Zone.

3. Project content: The list of the third-phase workshop (steel structure+civil work+decoration) is as follows:

Ground beam, ground and earthwork.

(2) The civil engineering quantity of the external wall of the building above 0.00 in the drawing includes: masonry wall of axis a-d* 1-12 * A and decoration of internal and external walls; Outdoor aproll and ramp;

(3) In steel structure engineering, in addition to external wall enclosure (including color steel plate, wall beam, etc. ) elevation of 4.65m below the axis 12*a-g, G * 5*d-g 1-5, and the rest shall be within the scope required by the drawings and the written notice of the blue prints.the design submitted by party a. ..

4、

Second, the construction period

From the third day after signing the contract, the total effective working days of this project are 60 days, and the specific construction period is as follows:

(1) foundation works for 30 days;

② Installation of main steel structure 15 days;

(3) Roof and roof drainage system shall be installed for 5 days;

(4) Installation of doors and windows and enclosure system 10 day.

⑤ Other auxiliary and finishing works are 10 days.

Party B must complete the project as scheduled within the agreed time limit, and delay for 65,438+0 days without reason, and be fined 65,438+0,000 yuan, with the upper limit of the fine being 65,438+0, 500 yuan. If the delay exceeds 15 days, Party A may find another unit for construction because Party B gives up the construction, and the completed project shall be settled according to 50% of the actual completed project quantity. Under the following circumstances, the extension can be extended after being signed by the on-site representative of Party A:

1, rainy and snowy weather is not suitable for installation.

2. Spring Festival.

3. Design errors, inaccurate data and engineering changes proposed by Party A. ..

4. Construction stops due to reasons of Party A and the third party.

5. Work consultation that may affect Party A's normal production.

Three. Contract price and payment method

1. Contract price:

The contract content of this project is RMB eight hundred and fifty thousand Yuan only (￥ 850,000.00).

2. Payment method:

Party A prepays 30% of the total project amount; Pay 20% of the total project amount after the completion of the roof and enclosure system; Pay 15% of the project cost after all the finishing work is completed and accepted; The balance (5% of the total project amount) is used as the quality guarantee.

3. Project price change: for new projects involving engineering technology changes other than the contract projects, the engineering technology change notice and construction visa jointly signed by the site representative and the project manager shall prevail, and the main raw materials shall be accounted based on the market price quotation. The change fees shall be agreed by both parties through consultation, and tax-related matters shall be implemented with reference to national regulations.

Fourth, material supply.

1. Party A has clear regulations on the supply of raw materials for the main steel structure and enclosure system, that is, the medium plate used for the main steel structure must be purchased from WISCO original factory, and the color plate must be produced by Baosteel. Before steel structure assembly and color plate rolling, Party B must provide Party A with the manufacturer's valid factory certificate, and promptly notify Party A to witness and sample the materials used in the main steel structure. Welded components of the main steel structure must be inspected by weld flaw detection according to national regulations, and a test report shall be issued. Solder, welding process, welder's technical grade certificate and inspection method used must meet the requirements of relevant national mandatory regulations.

2.？ The remaining materials shall be purchased by Party B itself, and all purchased materials must meet the requirements of the design and construction unit and various technical standards. Moreover, the quality certificate and factory certificate must go with the goods, and the materials must be witnessed and accepted by the on-site representative of Party A before they can be used. If the purchased materials are used by Party B without acceptance, and the quality of the project is unqualified, Party B shall be responsible for repairing or dismantling, and bear all the expenses arising therefrom. The delayed construction period shall not be postponed, and Party A shall be compensated for the economic losses caused thereby.

Verb (abbreviation for verb) project quality

1.。

2. Party B must carefully organize the construction according to the design drawings approved by Party A. In case of special circumstances, it needs to be changed, and it can only take effect after it is agreed and signed by the site representative of Party A and the project manager.

3. Party B must accept the quality supervision and normal work inspection of the on-site representative of Party A, and shall not obstruct it without reason. 4. Project acceptance: The project quality must meet the standards and specifications stipulated in the contract. If the acceptance is not organized within 30 days after the completion of the project (counting from the date when Party B submits the acceptance notice of the main project to Party A), the project shall be deemed as qualified.

5, project acceptance basis:

A. Construction drawings, notice of construction change, construction visa, atlas of relevant building standards and records of blue prints.the design signed by Party A ... B. Relevant national standards:

Unified standard for construction quality acceptance of building engineering (gb50300-200 1)

Code for Acceptance of Construction Quality of Building Foundation Engineering gb50202-2002

Code for Quality Acceptance of Masonry Engineering (gb50203-2002)

Code for Acceptance of Construction Quality of Concrete Structure Engineering (gb50204-2002)

Code for Acceptance of Construction Quality of Steel Structure Engineering (gb50205-200 1)

Code for quality acceptance of roofing engineering gb50207-2002

Code for Quality Acceptance of Underground Waterproofing Engineering (gb50208-2002)

Code for Acceptance of Construction Quality of Building Ground Engineering (gb50209-2002)

Code for Quality Acceptance of Building Decoration Engineering (gb502 10-2002)

C. For the parts not specified or detailed in the drawing specifications, the acceptance can be made with reference to the practices of Party A's existing first-phase workshop. Engineering projects that have not been confirmed by Party A's site representative and project manager are regarded as unqualified projects.

Six, safety in production

Party B shall strictly abide by the operating rules for safe production, hold relevant certificates, and put an end to safety and quality accidents. If Party B has a safety accident during the construction process, causing personal and property losses to himself and others, Party B shall be responsible. Seven. Rights and obligations of both parties

1. Party A

A. provide necessary construction conditions for party b. For example, on-site water supply and power supply, smooth roads, flat construction site, hoisting conditions, etc.

Party B shall provide Party B with two design drawings and technical data related to the project. Organize relevant units to participate in the joint review of construction drawings and project disclosure three days before commencement.

C. Be responsible for examining and approving the construction organization design (construction scheme) prepared by Party B, and have the right to stop Party B from violating the examined construction organization design.

D, responsible for handling the necessary construction site access certificates for Party B, and ensuring the passage of Party B's main and auxiliary materials, construction machinery and personnel. E, timely organize relevant parties to participate in the project acceptance.

F, timely draw project funds according to the schedule.

G. fields.

2. Party B

A. Party B foresees that some construction factors that restrict the entry and exit of Party A's subordinate members unrelated to this project may affect Party A's production, and shall immediately notify Party A and discuss solutions. If Party B fails to notify in time, all losses caused by Party A's production impact shall be borne by Party B. Unless it is necessary for construction, Party B's construction personnel and construction equipment shall not enter or leave Party A's production site at will.

B, prepare the construction organization design (construction scheme) three days before the start of construction, and submit it to Party A for approval in time. After examination and approval, the construction will be carried out in strict accordance with the construction organization design.

C, prepare the overall project schedule and Zhou Du schedule, and send the project to Party A.

Factory building contract project contract

Construction unit:? (hereinafter referred to as Party A) Construction unit:? (hereinafter referred to as Party B) In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, Party A and Party B reach an agreement on relevant matters and conclude this contract. * * * Same as compliance.

I. Overview of the Project

Project Name: Enterprise Exhibition Hall of Henan Fengyuan Hepu Feed Co., Ltd.

Project location:

Second, the scope of project contracting

According to the needs of engineering construction, Party A entrusts Party B with full responsibility for the construction of Fengyuan enterprise exhibition hall, subject to the actual drawings. (including civil works, floors, embedded parts, steel structures, doors and windows, etc.). ). The engineering steel structure is given priority to, the wall is filled with hollow bricks, painted inside and outside, and the front glass curtain wall.

Three. Project contracting mode: Under the unified supervision and coordination of Party A's supervision, Party B shall contract for the work and materials, guarantee the quality, duration, safety, civilized construction and qualification (materials shall ensure that Party A can pass the quality acceptance), and shall not subcontract.

IV. Term of the contract:

Party b promises to start work from the date of signing this contract? Complete the steel structure construction within calendar days. The completion date is 20 15.

Verb (abbreviation of verb) quality standard

The quality requirement standard of this project is: qualified.

Therefore, Party A requires Party B to use standard materials for all building construction, and the whole project conforms to national building standards. And should be able to pass the acceptance of relevant quality inspection departments.

Contract price of intransitive verbs

The project includes materials, labor, production, transportation, installation, loading and unloading fees, invoices and various unforeseen expenses (if there is no major design change, the total price shall not be

Adjustment; If there is any major design change, it can be adjusted through negotiation if it exceeds 5% of the total price).

The total fixed contract price of this project is RMB 10,000 Yuan only.

(1) Take the design drawings of this project as the annex of this contract.

(2) In case of major changes, both parties shall take signature as the settlement basis.

Seven. terms of payment

After the signing of this contract, the project advance payment shall be paid within one week after the completion of the civil works? Ten thousand yuan (65438+ 00% of the total cost).

Pay the project payment within one week after the steel column and steel beam enter the site? Ten thousand yuan (30% of the total cost). Pay RMB 10000 yuan (20% of the total cost) within one week after the wall painting is completed. Pay the project payment within one week after the project is completed? Wan? Yuan (accounting for 20% of the total cost). Pay 10000 yuan (65438+ 05% of the total cost) within one week after the project acceptance, and the remaining 5% will be used as the quality guarantee, that is, 10000 yuan. Yuan, pay off the balance after one year when there is no quality problem.

Eight, Party B promises to carry out the construction in accordance with the contract, and undertake the project quality warranty responsibility during the quality warranty period. Within one year after the delivery of the project, Party B shall be responsible for the free maintenance of the quality problems of the steel structure project not caused by Party A; Within five years, Party B will maintain the waterproofing of the existing projects free of charge (except for force majeure factors). After the completion of the project, Party B is responsible for the lifelong paid maintenance and service of the project, and only charges fees, and is responsible for the decoration of Party A's project.

Nine. Party A promises to Party B to pay the fees according to the time limit and method agreed in this contract.

X party b promises to party a that it will fully perform the contents of this contract. If it cannot be completed on time, Party A shall be liable for breach of contract at a rate of 2‰ per day. If the quality fails to meet the requirements, Party A will be liable for breach of contract voluntarily according to the 50 yuan per square meter. Party B also promises that the payment of the above liquidated damages will not affect Party B's other compensation requirements for losses caused by project construction delays and quality problems.

XI. Is this project assigned by Party A? Comrade, Party B designates comrade as the person in charge of site construction to coordinate and solve relevant problems in construction.

12. Implement the national regulations on production safety to ensure safe construction, and Party B shall be responsible for the work-related accidents during construction. Party B must purchase industrial accident insurance.

13. The right to interpret this contract belongs to Party A.. Matters not covered can be settled through negotiation. In case of any dispute, it can be settled through arbitration by the arbitration commission in the place where the contract is signed or brought to the people's court.

Thirteen. Entry into force of contract

Date of conclusion of the contract: year month day.

Contract signing place:

This contract shall come into effect after being signed and sealed by both parties.

Employer (Party A): Contractor (Party B)

(official seal)? (official seal)

Legal representative:

Authorized Agent: Authorized Agent:

Employer: Zheng 'an Milla Ren decorative coatings Co., Ltd. (hereinafter referred to as Party A)? Contractor: Guizhou Great Wall Architectural Design Co., Ltd. (hereinafter referred to as Party B)

Project Name: Zheng 'an Miracle decorative coatings Workshop Design Project.

Project location: Anchang Town Industrial Park, Zheng 'an County, Zunyi City.

Reasonable service life of the project design: 50 years.

Design certificate grade: Grade B..

Date of contract signing: 20 14? Month and day

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations on the Administration of Survey and Design of Construction Projects and the Measures for the Administration of Quality and Market of Survey and Design of Construction Projects in Guizhou Province, Party A and Party B reached an agreement through consultation.

Rule number one Party A entrusts Party B to undertake the engineering design of the above-mentioned plant construction project, and Party A pays the corresponding remuneration (design fee).

Article 2 The project design includes: 1, general layout design; 2. Architectural design of complex building, factory building and warehouse; 3, fire water and electricity construction design; 4. 1 Effections of wastewater treatment facilities design and workshop overall design.

Article 3 On the day of signing the contract, Party A shall provide Party B with the land red line map 1 copy approved by the competent government department. Article 4 Within 10 days after the signing of this contract, Party B shall submit all the design materials required for the first examination and approval, and ensure the approval of the planning department. After approval? Party B shall deliver all design materials (4 civil construction drawings, 4 fire-fighting and hydropower construction drawings, 4 standard design scheme binding texts, 1 workshop overall design renderings) approved by the planning department to Party A within 0/0 days. ..

Article 5 The design fee is based on the total construction area (including the construction area of workshop, complex building, warehouse and duty room) in the scheme adopted by the planning examination and approval department, and is calculated as 10 yuan/m2. Within 3 days after the signing of the contract, Party A shall pay Party B a design fee of 20,000 yuan in advance, and within 3 days after the design scheme is first approved by the planning approval department, Party A shall pay Party B a design fee of 24,000 yuan in advance, and all design materials shall be approved by the planning department.

Article 6. Party B is responsible for coordinating the planning examination and approval department to handle related matters, and ensuring that the design materials pass the examination and approval smoothly. The coordination fee shall be borne by Party B, and Party A agrees to compensate the coordination fee of RMB. If the planning approval department refuses to approve the documents and materials designed by Party B, Party A has the right to refuse to pay the design fees paid by Party B, and Party A has the right to claim the paid design fees.

Article 7? After the construction of this project starts, if Party A cannot solve the technical problems related to the design, Party B has the obligation to cooperate with Party A to solve them, and the relevant departments meet the specified requirements.

Party B shall send personnel to participate in activities related to the project. Article 8? During the performance of the contract, if Party A changes or adds design contents, which leads to Party B's design rework, Party A shall pay corresponding remuneration separately according to the workload previously consumed by Party B, and the payment amount shall be negotiated by both parties separately.

Article 9? During the performance of the contract, Party A shall provide necessary working and living conditions, transportation and other convenient conditions for the personnel sent by Party B to the site to deal with design problems. Article 10 Without the consent of Party B, Party A shall not modify the design data and documents delivered by Party B without authorization, nor transfer them to a third party or use them for projects other than this contract. In case of the above situation, Party B has the right to claim compensation from Party A. ..

Article 11

Party B shall not disclose or transfer the information and documents in this contract to a third party. In this case, Party A has the right to claim compensation from Party B. ..

Article 12? If Party A fails to pay the design fee according to Article 5 of this contract, and Party B has completed the design data according to Article 4 of this contract and submitted it to the planning department for approval, Party A shall pay Party B a penalty of 5,000 yuan, and have the right to require Party A to continue to perform this contract; If Party B has completed all the design materials agreed in Article 4 of this contract and passed the examination and approval of the planning department, but Party A has not paid the design fee, Party A shall pay Party B a penalty of 20% of the total design fee, and shall have the right to demand Party A to pay the balance of the design fee and the compensation specified in Article 6 of this contract.

Article 14 Party A agrees that Party B entrusts its Guizhou branch, Sichuan Meicheng Architectural Planning and Design Co., Ltd., Bijie Branch to perform this contract, and complete the design work and post-service with the invoice issued by Bijie Branch and the design fee charged by its account.

Article 15 During the performance of the contract, if either party requests to terminate the contract, it shall obtain the consent of the other party, otherwise the contract shall not be terminated. Article 16 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties can only choose to bring a lawsuit to the People's Court of Zheng 'an County where the contract is signed.

Article 17? For matters not covered, both parties may sign a supplementary agreement, which is an integral part of this contract.

Article 20? If due to Party A's reason (what reason? If the completion time of design results conflicts, the delivery completion time of related design results will be postponed.

Article 21? After the designer delivers the design data and documents, he shall participate in the relevant design review as required, and be responsible for making necessary adjustments and supplements to the contents not exceeding the original scope according to the review conclusion, and the review fee shall be drawn up by Party A (what other reviews will be conducted after the data is completed? )。

Article 22? This contract is made in sextuplicate, three for the Employer and three for the Contractor. The design fee paid by Party A to Party B in accordance with Article 4 of the Contract shall come into effect.

Employer: Decorative drawings of Zheng 'an Meilai people

Materials co., ltd? Name of Designer: Legal Representative:? Legal Representative: Authorized Agent:? Entrusted agent:? Address: Anchang Town Industrial Park, Zheng 'an, Zunyi Address: Postal Code:? Postal code:

Tel: Tel: 13902485306

Fax:? Chuan Zhen:

Bank of deposit: Bank of deposit:

Bank account number:? Bank account number: