Five contracts for the construction of rural private self-built houses

Every labor service must sign a contract, which is also a guarantee for our workers. What about the labor contract? Let me sort out the construction contract of private self-built houses in rural areas, I hope you like it!

Rural private self-built housing construction contract 1

Party A: _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _

Party A plans to build a house in _ _ _ _ _ _ _.

I. House structure and contract scope:

Party A plans to build a one-story bungalow with brick-concrete structure. Party A has completed the laying of ring beams on the foundation and the bottom floor, and now the ground construction of the house is contracted to Party B. The contracting scope includes the building main body, ring beam laying, roofing, indoor painting, porcelain pasting (porcelain pasting on the front wall, sanitary porcelain pasting on the living room wall, sanitary porcelain pasting on the kitchen and bathroom), ground cement calendering, and cement external powder wall on the east side of the house.

II. Valuation area and payment method of the house:

1. Calculation method of area: After the building is completed, both parties shall first measure the length and width of the built building, from the time when the eaves of one building dripped to the time when the eaves of the other building dripped, the area obtained by multiplication minus the bright sky area in the courtyard is the house pricing area. The appraised area of the house is _ _ _ _ square meters;

2. Price: both parties agree that the unit price is _ _ _ _ _ _ Yuan/m2 (in words _ _ _ _ Yuan/m2), and the total price (multiplied by the unit price of the house) is _ _ _ _ _ _ _ _ _ _;

3. Payment method: Before the signing date of this contract, Party A shall pay Party B _ _ _ _ _ _ _ _ _ (in words _ _ _ _ _ _ _ _) as a deposit, and Party A shall pay _ _ _ _ _ _ _ _ _.

Three. Term of contract:

The term of this contract starts from _ _ _ _ _ _ _ _ _ _ _ _ _ _. Among them, the main body of the wall building and the upper roof of the beam will be completed before _ _ _ _ _ _ _ _ _ _.

Four. Rights and obligations of both parties

1. Party A shall pay the price to Party B as agreed, and provide the building materials such as cement, sand, steel bars, etc. required for the building according to Party B's construction progress;

2. Party A shall provide water and electricity for Party B's use and ensure that water and electricity can be used normally;

3. Party B shall ensure that the project is completed as scheduled according to the design intention of Party A to build the house, and ensure that the quality of the house meets the industry requirements and overall requirements, and the required professional equipment such as mixers, scaffolding, pipes, etc. shall be provided by Party B;

4. During the construction, Party B shall be responsible for the personnel employed by its own headquarters, organize and supervise the construction, and be responsible for the quality of the house. Party B shall actively take safety measures to ensure safe production. In case of any safety accident during construction, all the injuries caused shall be borne by Party B, and Party A shall not bear any responsibilities.

5. Party A does not participate in the construction organized by Party B, but has the right to supervise the construction process of Party B. If any quality problem is found in the house built by Party B, Party A shall communicate with Party B in time and have the right to ask Party B to correct it in time. After Party A accepts the quality of the house built by Party B, both parties sign it, and Party B completes the delivery obligation.

Verb (abbreviation of verb) liability for breach of contract:

1. Party A shall pay the salary to Party B within the agreed time limit. In case of breach of contract, Party A shall pay liquidated damages to Party B for every _ _ _ _ days overdue;

2. Party B shall complete the construction with good quality and quantity within the agreed time limit. In case of breach of contract, Party B shall pay liquidated damages to Party A for every _ _ _ _ days overdue;

3. If there is any problem with the quality of the house, Party A has the right to ask Party B to redo or repair it in time. If it fails to arrive within _ _ _ _ _ days after Party A notifies Party B, Party A has the right to ask others to repair or redo it, and Party B shall bear the expenses required for removal, repair and rework.

During the construction of intransitive verbs, matters not covered in this contract or changes in contract contents shall be settled through friendly negotiation between both parties and the intermediary agency, and a supplementary contract may be signed, which has the same legal effect as this contract.

7. This contract shall come into effect after being signed by both parties, in triplicate, one for each party and one for the intermediary, with the same legal effect.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Rural private self-built housing construction contract II

Employer (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

As Party A built a three-story building in the south of the city, it laid bricks, touched wood and bound steel bars (round nails, lead wires, etc. ), the sand screening, concrete pouring and scaffolding of this project are outsourced to Party B for construction in the form of cleaning. In order to clarify the responsibilities and facilitate the construction, both parties have reached an agreement through full consultation, and hereby sign the following terms of the construction contract:

I. Scope and form of contracting:

Party A will contract the construction of bricklaying, steel bar, wooden touch, steel bar binding, concrete pouring, sand screening and shelves in the building by Party B in the form of light industry.

Second, the opening and completion date:

Foundation excavation started from the date of the month to the date of the month.

Third, the contract payment:

The total project cost of this contract is RMB seventy-six thousand Yuan only (RMB 76,000 Yuan only), with one-time warranty.

Fourth, the project quality:

Party B shall ensure the quality of the project, and the construction shall meet the qualified standards according to the drawings. If the drawings are changed, Party B shall be contacted to design (or change) the construction according to the original drawings. The foundation should be watered by standing contact. It is required to connect elbows at each corner, brace every 50-60 cm, 15- 16 m frame reinforcement, and the foundation and floor thickness meet the standards. The film can only be folded within the specified time and with the consent of Party A, and each layer should be poured by machine to ensure that it is above 1 1 cm. Party A invited Comrade Ma to supervise the project quality management in the process of Party B's proposal, and asked Party B to cooperate.

Verb (abbreviation for verb) Material supply:

In order to ensure the engineering quality, Party A must purchase qualified materials, and Party B has the right to refuse to use unqualified materials. Two days before a certain material is used, Party B will inform Party A to prepare the material, so as not to affect the construction.

Six, project acceptance:

After the foundation, concrete belt and main structure are completed, Party A invites relevant personnel and himself to participate in the acceptance inspection and conduct self-inspection on the specifications, reinforcement, quantity and connection of reinforcement. If the completion acceptance is qualified, the project acceptance procedures shall be issued.

Seven, engineering advance payment and settlement method:

1, foundation and first floor completed:

2. Completion of the second floor:

3. Roof completion:

4, the interior and exterior wall powder is good:

5. After the project is completed, 5000 yuan will be withheld as the maintenance fund. After one year, if there is no quality problem, Party A will pay Party B. ..

Eight, safety in production:

During the construction, Party B shall abide by the operation rules, and it is forbidden to operate illegally to ensure the construction safety. Party A shall insure the safety of the project and life and property. Party B shall be responsible for all safety measures or liability accidents within its construction scope, and Party B shall be solely responsible for all safety accidents or other liability accidents, which has nothing to do with Party A. Party A shall assist Party B in handling the accidents.

Nine. Liability for breach of contract:

1. If Party B fails to complete the project on schedule (except for force majeure), such as rainy days, material shutdown, cement maintenance, floor installation, etc., and the construction period cannot be extended normally, Party B will be fined 5% of the total contract price.

2. If rework is caused by Party B's construction, Party B shall bear all material losses.

3. If Party A fails to pay in accordance with the provisions of Article 7, it will be fined 5% of the total contract price in addition to the extension of the construction period.

X. others:

Party B shall be responsible for the work shed. During the construction, Party B shall conduct civilized construction, keep the site clean and tidy, and save materials for Party A as much as possible on the premise of ensuring quality. Party B is responsible for screening unqualified materials, and Party A cooperates closely to provide various conveniences.

XI。 This contract is made in duplicate, one for each party. It will take effect immediately after being signed by both parties. Matters not covered shall be settled through consultation.

Party A (signature):

Party B (signature):

Date: Year Month Day

Rural private self-built housing construction contract 3

Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Mailing address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Mailing address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A needs to build a new house now, and both parties reach an agreement on the construction of this construction project based on the principles of equality, voluntariness, fairness and good faith, and hereby conclude this contract.

Rule number one. Project contracting form

This project is contracted to Party B in the form of general contractor, and Party B shall undertake the machinery, formwork (clear water wood), horse pole, safety rope, cutting machine and other tools required for the construction operation. Party A is responsible for dustpan, nails, iron wire, binding wire, covered electrode and other auxiliary materials.

Article 2. Scope of project contracting

1. Foundation works: subject to the design and construction drawings. The foundation shall be excavated to the hard soil layer recognized by Party A, and Party B shall also be responsible for backfilling and tamping the foundation.

2. Main works: Bricklaying, steel bar making, formwork (fair-faced formwork), concrete pouring and other sub-projects shall be carried out in strict accordance with the design and construction drawing and the modification scheme negotiated by both parties.

3. Plastering works: the interior and exterior walls are made of latex paint to the east and wall bricks to the south. Party B shall be responsible for putty and Party A shall be responsible for latex paint. In case of any change, Party A shall notify Party B in advance.

4. Door and window engineering: Party B shall keep the size of doors and windows in strict accordance with the construction requirements during the construction, and cooperate with the construction of related projects.

5. Water and electricity installation project: Party A proposes the scheme, Party A supplies the materials, and Party B is responsible for the installation. In case of any change, Party A shall notify Party B in advance.

6. Accessory and decoration works: septic tank and roof pool, full eaves, interior and exterior wall painting, floor tiles, doors and windows, large glass, exterior wall horseshoe, footstone, bathroom and kitchen decoration, ceiling, console and waterproofing shall be provided by Party A, and Party B shall carry out construction and laying according to the design and construction drawings and Party A's requirements.

7. According to the actual construction area, the price is 270 yuan per square meter (270 yuan /m2). Slope roofs and balconies are calculated at half price according to the national construction area calculation rules, that is, one hundred and thirty-five yuan per square meter (135 yuan /m2), and the gate and fence shall be negotiated separately.

Article 3, Quality Requirements

Party B must carry out the construction in strict accordance with the drawings and the agreement of both parties, and the construction quality shall meet the design requirements and the current national construction specifications and relevant standards. If the quality requirements are not met due to the reasons of the construction party, Party B shall bear all losses except working hours. Party B must save materials in the construction, and shall not cause waste artificially.

Article 4. Contract price and project payment method

Party A will contract Party B for _ _ _ _ _ _ _ _ _ _ _ _ _ at the price of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ After each layer is capped, each layer will pay _ _ _ _ _ ten thousand yuan; Pay _ _ _ _ ten thousand yuan after the completion of internal and external plastering; Pay RMB _ _ _ _ _ _ ten thousand yuan after the whole house is pasted, and accept the rest within one month after the completion, and settle the balance after it is qualified.

However, Party A shall deduct the expenses of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 5, construction safety

During the construction period, Party B must do a good job in the safety management and prevention of the construction site, as well as the safety of other personnel entering and leaving the construction area. Party B shall take full responsibility for the safety accidents and industrial accidents caused by Party B during the construction. Party B shall take full responsibility for the injured construction workers and other personnel, and Party A shall not take responsibility.

Article 6. Liability for breach of contract:

1. If one party fails to perform the contract without authorization, it shall pay liquidated damages of _ _ _% of the total project price to the other party. If the breach of contract causes losses to the other party, it shall also bear the corresponding losses.

2. Party B shall complete the project within the agreed time limit. If the construction period is delayed for more than _ _ _ _ days due to Party B's reasons, the salary will be deducted by _ _ _ _ yuan per square meter per day.

3. Party A shall pay the project funds to Party B on a regular basis as agreed, and pay Party B _ _ _ _% of the current payables as a late fee for every _ _ _ days of delay.

Article 7. Others: Party A shall actively cooperate with Party B to improve neighborhood relations. Party B must calculate the materials that Party A needs to purchase in advance and inform Party A. ..

Article 8. Construction period: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 9. Matters not covered: Party A and Party B shall settle through negotiation.

Article 10 This contract is made in duplicate, one for each party. This contract shall come into effect as of the date of signature and seal by both parties. After the completion of the project, this contract will be automatically terminated after the acceptance and settlement by both parties are completed and the project payment is paid.

Employer (signature): _ _ _ _ _ _ _ _ _ _ _ Contractor (seal): _ _ _ _ _ _ _ _ _ _ _ _

Legal representative (signature) on _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4 contracts for rural private self-built housing construction.

Employer (Party A):

Contractor (Party B):

After friendly negotiation between Party A and Party B, Party A decided to entrust Party B with decoration. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, following the principles of equality, voluntariness, fairness and good faith, this contract is hereby signed for * * * * to abide by.

I. Project: Decoration project.

Second, the contracting method is contractor.

Total project budget (excluding tax) in words:, (in figures: ￥)

3. If Party A requests to add or change the engineering design, it shall negotiate with Party B to implement it. If the construction period is prolonged as a result, Party A shall bear the responsibility.

4. Party B shall carry out the construction and finish it before, otherwise, Party B shall pay a penalty of one thousandth of the total project cost for each day overdue, which can be deducted from the project cost.

Verb (abbreviation of verb) Party A shall sign and seal the construction plan (drawing) for confirmation. Construction shall be carried out according to the drawings. When the actual size of the construction site is not in conformity with the drawings, Party A shall be notified to negotiate and modify it, and construction can only be started after confirmation and seal.

6. If Party A requests to change the engineering design, it shall notify Party B in writing to negotiate for implementation. Both parties shall negotiate the changed design, and evaluate and confirm the compensation for the losses caused by Party B's working hours and materials. In the process of construction, if the owner requests to add projects, both parties will confirm the quotation at that time.

Seven. The quantities of concealed works shall be measured on site by representatives of both parties, and Party A shall be notified two days in advance. However, when Party A's representative is not on site before the concealed works are needed, Party B has the right to conceal the works by itself, and settle the accounts according to the quantities provided by Party B. After Party A and Party B's representatives measure the concealed quantities on site, Party A's representative fails to sign for confirmation, and Party B shall keep the handwritten quantities data of Party A's representative for settlement.

Eight. Party B shall notify Party A within five days after the completion of this project and jointly accept it with Party B. Both parties shall jointly complete the acceptance within five days after Party A receives Party B's acceptance notice, and both parties shall sign the acceptance documents for confirmation. If Party A fails to accept or move in with Party B within five days after receiving Party B's notice, it shall be deemed that Party A's default project quality meets the requirements.

Nine, the project construction process, in case of force majeure, the time limit for a project is interrupted, and the time limit for a project will be restored after the force majeure factors are eliminated.

X. The quality warranty period of this project is three years, counting from the date of acceptance by both parties (note: Party A shall be responsible for man-made damage).

XI。 Settlement of this project: according to the actual workload completed on site, the unit price is area.

12. Payment method: 40% of the project payment shall be paid in advance before entering the site, 30% for the second time, 20% for the completion of the top coat, and the remaining 5% shall be paid in one lump sum within 10 days after the project is accepted. In addition, 5% is reserved as the quality deposit, and Party A will return the quality deposit after the expiration.

13. If Party B violates the construction specifications, safety operation specifications, fire prevention regulations, environmental protection regulations and other agreements of both parties, Party B shall bear all economic losses caused thereby.

Fourteen Other attached pages of this contract shall come into effect after being signed by both parties.

15. This contract is made in duplicate and will come into effect after being signed by both parties.

Party A: Party B:

Representative: Legal Representative:

Agent:

Address: Address:

Tel: Tel:

Fax; Fax:

Account number:

Date: Year Month Day

Date: Year Month Day

Rural private self-built housing construction contract 5 pages

Party A:

Party B:

Based on the principles of equality, mutual benefit, fairness, justice, honesty and credit, and in order to clarify the responsibilities, obligations and rights of both parties, Party A and Party B have voluntarily reached the following terms and conditions on the construction, materials and employment of private houses undertaken by Party A through friendly negotiation for common compliance.

I. Overview of the Project:

1, project name: private house

2, the structure level:

3. Construction site: West xie cun, Xia Shu Town.

4. Building area: square meters

Second, the way of contracting:

Cleaning workers, machinery, equipment and materials, building materials.

Three. Scope and content of the project:

1. Cushion, corner, foundation, main body, roof, indoor and outdoor decoration painting, concrete floor upstairs and downstairs.

2, all materials handling.

Four, building materials requirements:

1, porous brick:

2. Cement:

3, steel bar:

Five, quality management:

Quality standard: The quality of the project constructed by Party B shall meet the relevant national and local construction and acceptance standards and Party A's requirements.

Six, the progress of the project:

Term of the contract: from year to year, with a total of calendar days.

Seven, safe and civilized construction:

In the process of construction, Party B shall be responsible for the safety accidents of its construction personnel, which has nothing to do with Party A. (The project cost includes the insurance premium of Party B's workers. )

Eight. Settlement price and method:

1, fixed unit price lump sum: RMB/m2, calculated according to the actual construction area (the construction area is calculated according to national standards).

2. After the completion of the project, the project cost shall be reserved as the project quality deposit, and all quality and safety issues such as maintenance shall be paid within one year after the project completion acceptance.

Nine. Payment terms:

According to the progress of the project, Party A will pay when the foundation ends, the main body ends, painting ends, the project is completed and accepted, and there is no quality problem after one year.

X. field power consumption:

Party A shall be responsible for the expenses.

Xi。 Construction water:

Party A shall be responsible for the expenses.

Twelve. Dissolution and termination of the contract:

1. Termination of the contract: If Party B's labor arrangement and the quality, progress and safety of the construction project can't meet Party A's requirements, Party A has the right to notify Party B to terminate the contract, order Party B to quit, and settle 70% of the completed projects. Year-end settlement

2. Termination of the Contract: This Contract shall be terminated after Party A and Party B exercise their rights and reasonably perform their respective obligations according to the terms of the Contract.

3. For matters not covered in the above contract terms, both parties may sign a supplementary agreement separately, and the supplementary agreement has the same effect as this agreement.

4. This contract is made in duplicate, one for Party A and one for Party B, and shall come into effect after being signed by both parties.

Party A (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Five items related to the construction contract of rural private self-built houses;

★ The latest three private building contracts.

★ Model rural individual housing construction contract

★ 5 samples of individual self-built house sales contract.

★ Model of individual self-built house contract

★ 4. Model contract for private self-built houses

★ 6 Model contract for the sale of rural self-built houses

★ Template and materials of farm house contract.

★ Template of Rural Self-built House Agreement

★ Ten commonly used sales contracts for self-built houses.

★ 3 templates of private self-built housing contracts