Traditional Culture Encyclopedia - Hotel accommodation - Electrical contract
Electrical contract
Electrical contract 1 party a:
Party B:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Labor Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credit, in order to clarify the responsibilities, rights and obligations, ensure the project quality and construction safety, and make this project realize civilized construction and be completed on schedule. Both parties sign this contract on the principle of voluntariness and mutual benefit.
I. General situation of the project, contract contents and price:
1. 1 project name:
1.2 project site:
1.3 engineering structure: the construction area is about M2. (subject to actual area)
1.4 contracted project contents: lighting system: contents included in construction drawings such as pipeline embedment, threading, lighting, socket, switch, distribution box, instrument, installation and debugging of lightning protection and grounding. Power system: the contents required by the construction drawings, such as pipeline and casing embedment, cable tray installation, cable laying, installation and debugging of power distribution equipment, etc. Weak current system (TV, telephone, broadband, etc.). ): Pre-embedded pipes and sleeves are reserved, pre-embedded pipes are reserved for fire fighting system, and emergency lighting is installed and debugged.
1.5 contract price: 18 yuan /m2 (excluding temporary electricity consumption) 18.5 yuan /m2 (including temporary electricity consumption) (calculated by construction area).
1.6 mode of contracting: labor costs, auxiliary materials (iron wire, nails, insulating tape, plastic tape, etc. ), tools (hand-held power tools and steel tape measure, marker pen, wire cutters, etc. ), quality, safety, time limit for a project and civilized construction.
1.7 payment method:
1. Pay or borrow money according to the project image progress.
2. When collecting or borrowing the project progress payment, Party B shall truthfully provide the payroll for employees. I must sign when I get my salary, and I can't get it on my behalf, let alone misappropriate my artificial salary. If the contractor is found to misappropriate labor wages, Party B shall bear all the responsibilities by itself.
Second, the rights and obligations of both parties to the contract:
1. Party A is responsible for the supply of main materials.
2. Party B must carry out the construction according to the requirements of design documents, current construction and acceptance specifications, construction organization design, construction technical disclosure and safety disclosure. Timely report the material quality problems found in the construction.
3. Party B shall put forward the material plan one week in advance, and the material plan shall be accurate. Party A shall supply materials according to the material plan provided by Party B. If the actual consumption exceeds Party B's material plan, Party B shall be responsible for the excess, and Party A has the right to deduct the excess material cost from the project contracting fee.
4. Party B is responsible for the erection, maintenance and removal of temporary electricity facilities on site. All kinds of electrical holes are reserved for plugging.
5. The keeper of Party A shall check and accept the incoming materials (including models and specifications) and report the quality problems, models and specifications of the materials in time.
6. Party B shall be responsible for unloading and warehousing the incoming materials and cooperate with Party A to keep the incoming materials. Avoid loss and damage.
Third, the time limit for a project:
Organize the construction on time according to the time limit specified by Party A, and complete the construction within the time limit specified by Party A from the actual commencement date.
Four. Party A's responsibilities:
1. Make technical and safety disclosure to Party B. Provide temporary warehouse for Party B at the construction site.
2, responsible for providing a set of construction drawings and related design change notice.
3. Allocate the project payment to Party B according to the progress of the project.
4. Supervise and inspect Party B's quality, safety, progress, use of materials and machinery, put forward rectification requirements for existing problems, and punish them according to the seriousness of the case.
5, responsible for the overall progress of the project and the progress of the subcontractors, responsible for the project meeting, coordinate the contradictions in the construction of the cooperative units.
6. Check the operation of Party B's construction equipment, the storage and use of materials at any time, and check the valid certificates and certificates of Party B's on-site management personnel and operators. When Party B violates the regulations or fails to meet the required standards, Party B is required to make rectification and repair.
Verb (abbreviation of verb) Party B's responsibilities:
1. Party B shall carefully check the construction drawings provided by Party A, and shall be obliged to point out the possible defects and omissions in the construction drawings provided by Party A, and inform Party A of the errors and omissions found in the drawings in time before construction, so as to avoid losses, otherwise, all changes caused by Party B's failure to perform its responsibilities during construction will not increase the cost.
2. When Party B's construction personnel enter the construction site, they must obey Party A's safety production management, unified management and command, abide by various rules and regulations, and put an end to illegal construction.
3. Strictly implement Party A's technical disclosure, carry out construction according to disclosure and design practices, and carefully understand and implement Party A's disclosure and notice (including oral notice).
4. Strictly abide by the management system of Party A's construction site, and accept Party A's reasonable punishment for the construction period, quality, safety, civilized construction and the use of materials and machinery.
5. Party B must establish a sense of economy, so as to clear up the site after work. Party A will fine Party B according to the actual situation.
6. Party B shall immediately rectify the rectification requirements and notices put forward by the supervision company and Party A without negative delay. If Party B fails to make rectification after Party A raises the question, Party A will impose a fine of not more than 500 yuan depending on the seriousness of the case. If the circumstances are serious, Party B will clean up the site, and Party B must organize enough high-quality labor to carry out the construction. After Party A proposes, Party B must replace the inferior labor force in time.
7. Party B must ensure safe and civilized construction, organize the construction in strict accordance with Party A's requirements, and workers must wear safety helmets. Seat belts must be used correctly when working at height. Materials should be carefully stacked, and garbage should be cleaned up in time. For Party B's violation of operating rules and site management requirements, Party A will punish Party B according to the seriousness of the case: each person who does not wear a safety helmet will be fined 100 yuan, and each person will be fined 100 yuan for not carefully stacking materials to ensure the creation of a civilized construction site.
8. If Party A finds potential safety hazards during the construction, it shall promptly propose rectification to Party B. If Party B fails to rectify, Party A has the right to stop work. Party B violates the safety operation rules and relevant regulations, and carries out brutal construction, resulting in casualties at its own risk.
9. Party B must implement Party A's schedule. If it cannot be completed on schedule due to Party B's reasons, 500 yuan will be fined for each day of delay.
10. Party B's personnel must submit the roster of personnel entering Party A's construction site for the record within 7 days, and each person shall submit two 1 inch color front photos and a copy of their ID cards; And ensure that the workers entering the site are free from criminals. Take all the responsibilities arising therefrom. If the roster, photos and ID cards are not submitted to Party A, Party A will not recognize their working relationship ... According to Party A's requirements, organize enough trained construction personnel to enter the site and obtain some post operation certificates for special jobs.
1 1. Party B is not allowed to gamble, drink too much or fight at the construction site. Party A will impose a fine of 1000 yuan on Party B every time it happens. Fight with other subcontractors, if the circumstances are minor, the responsible party will be fined 1000 yuan each time, and the public security organ will handle it according to law, and the project department will not bear any responsibility.
12, ensure the cleanliness of the working face and the construction site, and achieve Nissin; After the completion of the project, the turnover materials, tools and mechanical equipment of the project will be dismantled. Before the completion of the project, do a good job in protecting semi-finished products and finished products, and be responsible for repairing the damage caused. (especially the damage caused by the rerouting to the plastered wall) Participate in the completion acceptance, be responsible for the defects raised during the completion acceptance, and carry out free maintenance until the completion acceptance is qualified.
Liability for breach of contract of intransitive verbs:
1. If Party B fails to meet the requirements due to breach of contract, it shall be responsible for free maintenance or rework until it meets the requirements, and bear the losses or responsibilities caused thereby. If the acceptance fails to meet the quality requirements due to Party B's construction, the labor cost of each single project shall be deducted according to the actual loss value. If the completion of a single project is delayed, 500 yuan will be fined for each day of delay.
2. During the construction, the quality of Party B's team is too low to meet the requirements of the construction contract, the construction period cannot be guaranteed, and there are few skilled workers. When the quality and duration of the project can't meet the requirements, Party A can ask Party B to leave at any time, and can't ask Party A to increase the price or stop work during the construction, otherwise Party A has the right to change the construction team, and Party A can only settle accounts at 60% of Party B's workload.
3. Party B shall prepare enough labor force when entering the construction site to ensure that the labor force is not affected by seasons and holidays. Party A has the right to terminate the contract at any time in case of work stoppage due to insufficient labor force or other reasons. The economic consequences caused by Party B's abandonment of completing the contract content of this project shall be borne by Party B, and Party A will only pay Party B 60% of the completed project amount.
4. If Party B subcontracts the project, Party B's personnel do not obey Party A's dispatch arrangement, and the technology, quality, progress and safe and civilized construction can't meet the requirements of this contract, or Party A has the right to terminate the contract unilaterally if it violates laws, regulations or steals or damages Party A's machinery, facilities and waste materials; If Party B's personnel do not leave after the termination of the contract and make trouble, Party B must bear all the economic losses and related responsibilities caused thereby.
Seven, the construction quality
1, according to the national engineering quality inspection and evaluation standards, all projects within the scope of this contract must meet the qualified standards, and the engineering quality must be accepted by Party A and the supervisor;
2. Party B must carefully organize the construction in strict accordance with the construction acceptance specifications, design drawings and related requirements to ensure the realization of quality objectives. If the parts do not meet the quality standards, Party B shall repair them in time according to Party A's requirements until they meet the quality requirements.
3. Both parties have objections to the project quality, which shall be decided by the project quality supervision department. The arbitration fee and the losses caused thereby shall be borne by the responsible party.
4. Quality inspection: When completing the agreed project, Party B shall adhere to the system of self-inspection, mutual inspection and handover inspection in accordance with the requirements of standards, specifications and design and the instructions of Party A's representative, provide convenient conditions for inspection, accept the inspection and inspection of Party A and quality inspection departments at all levels at any time, rework and modify as required, and bear the cost of rework and modification caused by its own reasons.
5. Acceptance of concealed works: After Party B passes the self-inspection, it shall notify Party A to organize the acceptance 24 hours before the acceptance. After the acceptance of the supervision unit, the concealed work can be carried out and the construction can continue after the acceptance record is signed. If the acceptance does not meet the quality requirements, Party B shall carry out repair self-inspection according to the rectification opinions put forward by the acceptance, and notify the acceptance again after passing the inspection. Party B shall bear the maintenance costs and shall not conceal them without acceptance. If yes, Party B must peel the mouth according to the acceptance requirements of Party A or relevant units, and be responsible for recovery and bear the expenses and losses arising therefrom.
Eight, safety and civilized construction:
1. According to the current safety inspection standards and civilized construction standards on site, Party B must wear labor protection articles required to enter the site according to regulations, and the safety helmet and safety belt required for aerial work on site shall be collected by Party A in a unified way and returned to Party A in full after the project is completed. If Party B loses it, Party A shall compensate at the original price. If Party B fails to wear labor protection articles according to regulations and uses labor protection articles incorrectly, Party A has the right to impose penalties, and all fines will be deducted from Party B's total labor costs. ..
2. Party B must carry out the construction in a civilized and safe manner. During the construction process, Party B shall be responsible for all major and minor safety accidents on the way to and from work and on the construction site, and Party A shall not bear any expenses and responsibilities. The person in charge of Party B must stick to the construction site, otherwise, Party A has the right to fine 500 yuan for every day of absenteeism. (No penalty will be imposed without affecting the consent of working leave).
Nine, logistics:
Party B is responsible for accommodation, and Party A does not bear the expenses.
X. others:
1. Matters not covered in this contract shall be settled by both parties through friendly negotiation. When both parties have fulfilled all their obligations and paid the labor remuneration, other terms will be terminated except the warranty terms. After the warranty period expires, the warranty items are completed and the warranty payment is settled, the relevant warranty terms are terminated.
2. Party B must carefully read and abide by the project quality warranty agreement.
XI。 Dispute settlement: If both parties fail to reach an agreement, they can submit the dispute to the arbitration commission in the place where the contract is signed, or bring a lawsuit to the local people's court.
This contract is made in triplicate, with Party A holding two copies and Party B holding one copy, which shall come into effect after being signed by both parties and have legal effect.
Party A:
Party B:
Date of signing:
Electrical Contract II (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
In order to ensure the project quality and complete the construction task on schedule, according to the relevant provisions of the Contract Law and the Construction Law of the State and following the principles of equality, voluntariness, fairness, honesty and credibility, the two parties reached the following agreement through consultation:
I. Overview of the Project:
1. Project location: Yijing West Street, Taiyuan City
2. Project Name: Multi-storey Residential Building of Shanxi Institute of Chemical Technology
3. Engineering structure: frame-shear structure
4. Building area: based on the construction drawings, the settlement shall be made according to the calculation rules of the building area of the 20xx annual budget quota "Shanxi Construction Project Consumption Quota" (the basement is the whole area, and the balcony is calculated according to the regulations).
Second, the scope of contracting.
1. Construction works: all installation works such as water supply and drainage, heating, electrical lightning protection and grounding. (all mechanical and hand tools required for installation works), and all fire-fighting reserved holes, reserved holes and sleeves.
2. Party A shall contract to Party B in the form of labor and materials, with one-time guarantee. Party B shall organize material procurement by itself, and submit inspection reports and certificates of main materials to Party A before construction. Construction can only be started after approval. (Party B includes all water heating and electrical test fees) Water supply and drainage, heating, electrical lightning protection and grounding contracting and material installation works, including all contents of design and joint review drawings.
III. Opening and Completion Dates
20xx started on August 15 and was completed on May 15.
Four. Contract price and payment method
The price of xx yuan is contracted out to Party B for construction. Payment method: after the completion of the three-story structure, Party A shall pay the construction area per square meter 155 (installation of heating, water and electricity).
The employer shall pay 13% of the total contract price to the contractor, 25% of the total contract price after the acceptance of the main project of the unit project, 50% of the total contract price after the completion of the pipeline project (including the floor heating coil), 80% of the total contract price after the completion of the project, 95% of the total contract price after the acceptance of the project, and 5% of the quality deposit after the project is delivered one year.
Verb (abbreviation of verb) performance bond
When the Employer pays the progress payment for the first time, Party A shall return 50% of the performance bond paid by Party B; When the construction unit pays the progress payment for the second time, Party A will return the performance bond in full.
Liability for breach of contract of intransitive verbs
Compensation for liquidated damages of 10% of the total project price of the other party; If Party B withdraws from the project halfway, it shall be settled according to 50% of the actual completed project amount.
Seven. Responsibility of both parties
1. Party B's responsibilities:
(1) The warranty period shall be implemented in accordance with relevant state regulations. During the warranty period, the labor cost and material cost caused by Party B shall be borne by Party B, and the economic loss caused by other external man-made damage shall be borne by the personnel designated by Party A, and Party B may carry out paid maintenance.
(2) Party A shall be responsible for the construction electricity and water consumption, and Party B shall be responsible for other expenses.
(3) During the construction, Party B must ensure the quality of the project and meet the acceptance criteria.
(4) Party B must abide by the rules and regulations of Party A, obey the leadership and command, and achieve civilized construction and safety first. If Party B causes accidents such as machine damage to Party A, Party B shall bear the responsibility according to the degree of damage.
2. Party A's responsibilities:
(1) Party A shall be responsible for the economic losses caused by Party B's shutdown due to Party A's failure to timely allocate the project payment, which affects the construction progress and leads to the failure to complete the project on schedule. Party B shall bear all responsibilities and compensate Party A for the losses caused by the delay of the construction period due to the unfavorable organization of construction by Party B..
(2) During the construction process, if Party A proposes design changes temporarily, it shall issue a written notice of change to Party B. If the amount involved is less than 5,000 yuan, Party A will not settle the account, but will verify it according to the actual amount.
Eight. Other agreed matters.
1. During the construction, Party B must carry out the construction in strict accordance with the acceptance standards and construction drawings of the current national construction specifications. Those that do not meet the requirements of specifications and standards must be reworked, and Party B shall bear all material losses and delays caused by rework;
2. During the construction process, Party B must ensure that the construction site is clean and tidy, materials are neatly stacked, and finished products and semi-finished products are stacked in categories;
3. Party B's illegal operation is strictly prohibited, and Party B shall bear all responsibilities for personal injury or death caused by illegal operation;
4. Party B must obey the command of the employer to prevent fighting, and offenders shall be dealt with according to the relevant provisions of Party A's construction site management system;
Nine, engineering safety production requirements
1. Party B must carry out necessary safety training for all workers it employs and participates in the project construction, and they can only take up their posts after passing the training. Operators in special positions (such as tower cranes, mechanics, electricians, etc.). ) must hold relevant certificates and submit my valid certificates to Party A for the record.
2. Party B shall provide necessary labor protection articles (such as gloves, helmets, safety belts and safety ropes). ) All workers employed by Party B to participate in the project construction.
3. Party A shall make safety technical disclosure to Party B for major sub-projects, and both parties shall sign the disclosure sheet, and Party B shall carry out the construction according to the safety operation regulations.
4. Party B must abide by the regulations on production safety in engineering construction, organize the construction in strict accordance with safety standards, and accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents. Party B shall bear the responsibilities and expenses of accidents caused by its own reasons.
5. Any safety facilities provided by Party A to Party B shall not be damaged or lost, otherwise, in addition to the original compensation, Party B will be fined more than twice.
Ten, engineering civilization construction requirements
1. Party B shall abide by the safety and civilized construction system of Party A and Party A's project department, obey the safety and civilized guidance and supervision of Party A's project department management personnel, ensure safe production and civilized construction, and resolutely put an end to uncivilized incidents.
2. Party B shall be responsible for the rights and obligations of hiring, dismissing and other management of workers needed at the site. Party B shall not employ persons with unknown identities or obvious bad habits to enter the construction site. Party B shall submit copies of ID cards or photos (fingerprints) of all personnel to Party A for filing. Party B shall bear joint and several economic liabilities and joint and several civil liabilities if the employees employed by Party B violate the law.
3. Party B is responsible for cleaning the responsibility area regularly, creating a civilized construction site, and keeping the living area clean and orderly. If Party B fails to meet Party A's requirements, Party B shall bear 80% of Party A's rectification expenses. ..
4. For other matters, please refer to the safety and civilized construction card.
XI。 Responsibility for rework in engineering construction
1. Party A has the right to ask Party B to stop work, dismantle or rework the parts whose engineering quality fails to meet the agreed standards. All shutdown, rework and loss of Party A's materials and image shall be borne by Party B, and Party B shall be liable for breach of contract.
2. After rework and rectification, if Party B's engineering quality fails to meet Party A's requirements, Party A has the right to punish Party B or order it to quit the construction site, and all losses caused thereby shall be borne by Party B. Before that, Party A will deduct 30% of the workload and Party B will accept it unconditionally.
XII. Ways to settle contract disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, it can also be settled through mediation by the local administrative department. If mediation fails, it may apply to the Arbitration Commission of the court for arbitration or bring a lawsuit to the people's court.
Thirteen. This contract is made in quadruplicate, with each party holding two copies, which shall come into effect after being signed.
Party A:
Party B:
Date of signing:
Electrical Contract III (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
In order to ensure the project quality and complete the construction task on schedule, according to the relevant provisions of the Contract Law and the Construction Law of the State and following the principles of equality, voluntariness, fairness, honesty and credibility, the two parties reached the following agreement through consultation:
I. Project Location: Songyuan City, Jilin Province
2. Project name: Chunxing Garden Residential Building.
3. Construction engineering: water supply, drainage, heating, electrical contracting and material installation.
Four. Building area: (about) square meters. (Note) The actual construction area shall prevail in settlement.
5. Commencement and completion date: commencement date and completion date.
6. Contracting method: Party A contracts to Party B in the form of contract work and materials, once and for all. Party B shall organize the procurement of materials by itself, and submit the inspection report and quality certificate of main materials to Party A before construction, and the construction can only be started after approval.
Seven. Contract price and payment method: Party A contracts to Party B for construction (installation of heating and water and electricity contracting materials) at the price of RMB yuan per square meter of construction area, and Party A allocates funds to Party B according to the progress of the main civil works and 75% of the total progress of Party B's third floor. When the remaining four floors are capped according to the civil construction progress, Party B will get 75% of the total progress of the four floors. After the completion of the project, in addition to the 5% quality deposit reserved according to the total cost, the balance will be paid in full.
Eight, the warranty period according to the relevant provisions of the state. During the warranty period, the labor cost and material cost caused by Party B shall be borne by Party B, and the economic loss caused by other external man-made damage shall be borne by the personnel designated by Party A, and Party B may carry out paid maintenance.
9. If Party A fails to timely allocate the project payment according to Article 7 of this contract, which affects the progress of the project, the project can't be completed on schedule, and Party B stops work, so Party A shall be responsible for the economic losses caused ... Party B shall bear the losses caused to Party A due to improper construction organization and time delay.
10. In the course of construction, if Party A proposes a design change temporarily, Party A shall issue a written notice of change to Party B. If the amount involved is less than 10000 yuan, Party A will not settle the account, otherwise it will be written off according to the actual amount.
Eleven, water supply and drainage, heating and electrical contracting materials installation project, including all the contents of the design and the blue prints.the design.
Twelve, about the construction of electricity and indoor problems:
13. During the construction, Party B must ensure the project quality and meet the acceptance criteria.
14. Party B must abide by the rules and regulations of Party A, obey the leadership and command, and achieve civilized construction and safety first. If Party B causes accidents such as machine damage to Party A, Party B shall bear the responsibility according to the degree of damage.
Fifteen. Matters to be explained:
(1) This project does not include external water supply, drainage and heating pipe networks.
(2) excluding heat meters and cassette water meters. The electric meter is of the ordinary type.
(3) Oil separator and three boxes are not included.
This contract is made in duplicate, one for each party, and shall come into effect after being signed.
Party A:
Party B:
Date of signing:
- Previous article:Li Chuang's acting experience
- Next article:Are there any good TV plays? Either TVB or ATV will do. If it's modern, you'd better post it.
- Related articles
- World famous hotel
- What are the ten principles of employee code of conduct?
- What exactly does "Grand Hyatt" mean and where does it come from? Many hotel buildings are named after them.
- How to build a financial sharing service center
- Can a hotel maintenance electrician in Wuxi City not have an electrician certificate?
- What is the star rating of Hampton Hotel Shenzhen?
- What are some good Cantonese songs?
- Introduction to Yunyang Wonderland Natural Scenic Area Beijing Yunyang Wonderland Natural Scenic Area
- How to get to Beijing Time Walk Nostalgia Theme Hotel from Capital Airport?
- The Story Prototype of Song of Coconut Grove