Traditional Culture Encyclopedia - Hotel reservation - Catering industry contract
Catering industry contract
With the enhancement of legal awareness, there are more and more occasions where contracts can be used, and signing contracts can balance the equal status of both parties. So, have you mastered the format of the contract? The following are three catering contracts I collected. Welcome to reading. I hope you will like them.
Catering Industry Contract 1 Name of Party A (Employer): _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _
Tel: _ _ _ _
Name of Party B (laborer): _ _ _ _ _ _ _
Home address: _ _ _ _ _ _
Resident ID number: _ _ _ _ _ _
Tel: _ _ _ _
Printed by Jiangxi Provincial Department of Labor and Social Security
According to the Labor Law of People's Republic of China (PRC) and relevant national regulations, Party A and Party B sign this Labor Contract on the principle of equality, voluntariness and consensus through consultation.
I. Term of Labor Contract
(1) This Labor Contract starts from _ _ _ and ends at _ _ _ _. Among them, the probation period is from _ _ _ _ to _ _ _ _.
Second, the work content and working hours
(II) According to Party A's work needs and post requirements, Party B agrees to work in the post of _ _ _ _. With the consent of both parties, the post can be changed, and the change agreement signed by both parties is an annex to this contract.
(3) Party B shall, according to the requirements of Party A, complete the specified quantity of work on time and reach the specified quality standards.
(4) Party B's working hours shall not exceed 8 hours per day, with an average of 40 hours per week. Party A shall ensure that Party B has at least a weekly rest 1 day.
When Party A is unable to implement the preceding paragraph due to production characteristics, with the approval of the administrative department of labor and social security, it may implement a comprehensive working hour system or an irregular working hour system.
Third, labor remuneration.
(5) Party A shall pay Party B's salary on a monthly basis in the form of currency, and pay the salary on _ _ days of each month, which shall be signed by Party B for confirmation.
(6) The salary during the probation period is _ _ _ _ yuan/month.
(VII) If Party A implements hourly wage or post wage, the monthly wage for normal working hours is RMB/month.
If piecework wage is implemented, the monthly basic salary is _ _ _ _ yuan, and the piecework unit price is _ _ _ _ _ yuan or _ _ _% of the completed workload.
Where Party A provides accommodation or is equivalent to providing accommodation, it will not be included in Party B's salary.
(VIII) If Party A arranges Party B to extend the working hours according to the requirements of relevant laws and regulations, it shall pay Party B a salary not less than 150% of the salary; Where Party B is arranged to work on the rest day and cannot make up the rest day, Party B shall be paid no less than 200% of the salary of Party B; Where Party B is arranged to work on legal holidays, Party B shall be paid no less than 300% of Party B's salary.
Four. Labor protection and working conditions
(IX) Party A shall implement special labor protection for female workers and underage workers in accordance with relevant state regulations.
(X) The basic living conditions such as dormitories provided by Party A for Party B must meet the safety and health requirements.
(1 1) Party A must educate and train Party B in professional ethics, business technology, labor safety and health and relevant rules and regulations.
Verb (abbreviation of verb) social insurance
(XII) Party A shall pay the basic pension, medical care, unemployment, work injury and maternity insurance fees for Party B according to national and local laws, regulations and policies on social insurance; Party A may withhold and remit individual social insurance contributions from Party B's salary.
(XIII) The treatment of Party B during pregnancy, childbirth and lactation shall be implemented according to the relevant national and local maternity insurance policies.
Six, labor discipline
(XIV) Before signing this labor contract with Party B, Party A shall inform Party B of the labor rules and regulations that should be observed according to law, and Party B shall sign it as evidence.
(15) Party B consciously abides by relevant labor laws and regulations and various rules and regulations formulated by Party A according to law, strictly abides by safety operation rules, obeys management, and completes work tasks on time.
(XVI) If Party A arranges Party B's work illegally, immorally or impairs Party B's physical and mental health, Party B has the right to refuse.
(XVII) Party B has the obligation to keep Party A's business secrets. Without Party B's consent, Party A shall not disclose or divulge Party B's personal data.
(XVIII) If Party B violates labor discipline, Party A may handle it according to the rules and regulations of the unit.
Seven. Dissolution and termination of labor contract
(XIX) The unilateral dissolution of this Contract by Party A and Party B shall comply with the provisions of Articles 25, 26, 27, 30 and 32 of the Labor Law. In case of any of the circumstances specified in Article 29 of the Labor Law, Party A shall not terminate the Contract at will.
(20) This Labor Contract shall be terminated upon expiration. Party A and Party B can renew the Labor Contract through negotiation.
(XXI) After the dissolution or termination of this Labor Contract, Party A and Party B shall handle the relevant procedures for dissolution of this Labor Contract within seven days.
Eight. Economic compensation and compensation
(XXII) When Party A dissolves Party B's labor contract according to law, it shall implement the provisions of the Ministry of Labor [1994] No.481on payment of economic compensation. If Party B dissolves this Contract according to the provisions of Item (2) and Item (3) of Article 32 of the Labor Law, Party A shall pay economic compensation to Party B according to the provisions of DocumentNo.. [1994]48 1 issued by the labor department.
(23) If the salary paid by Party A to Party B is lower than the local minimum wage standard, it shall make up the part below the standard and pay compensation according to law.
Nine. Other agreements
(XXIV) Other contents agreed by Party A and Party B are as follows: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
X. Handling of labor disputes
(25) In case of any dispute between Party A and Party B during the performance of this Labor Contract, it can be settled through negotiation first; Unwilling to negotiate or failing to do so, they may apply to the Labor Dispute Mediation Committee for mediation; Unwilling to mediate or failing to mediate, you may apply to the local labor dispute arbitration committee for arbitration within 60 days from the date of the dispute. If you are not satisfied with the arbitration award, you can bring a lawsuit to the local people's court within 15 days.
This Labor Contract is made in duplicate, each party holds 1 copy.
This labor contract shall come into effect as of the date of signature and seal by both parties.
Part II of Catering Industry Contract Party A: (Ganfeng Express Hotel)
Party B: (Construction Party)
Article 1 General situation of the project
1. 1 Project location: _ _ _ _ _ _ _ _ _ _.
1.2 project contents and practices (see attached table 1: hotel decoration project confirmation sheet. Schedule 2: List of contents and practices of hotel decoration works).
1.3 project contracting mode: both parties agree to adopt the following contracting mode.
(1) contracting and materials.
1.4 The construction period is _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _.
1.5 contract price: the project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2 Obligations of Party A
1 Create conditions for Party B to enter the construction site _ _ _ days before the construction starts, including: demolishing indoor furniture and furnishings or stacking and covering indoor furniture and furnishings that are difficult to move without affecting the construction;
.2 Provide water and electricity supply during construction;
Responsible for coordinating the relationship between the construction team and the hotel departments;
4 During the construction period, Party B shall be responsible for public security and fire control at the construction site;
Participate in the supervision of project quality and construction progress, and be responsible for the material entry and completion acceptance.
Article 3 Obligations of Party B
1 During the construction process, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule; 5.2 Strictly implement the management regulations of the construction site, without disturbing the people and polluting the environment;
3. Protect the furniture and furnishings in the original hotel and ensure the smooth flow of water pipes in the hotel;
Ensure the cleanliness of the construction site and be responsible for the cleaning of the construction site after the project is completed.
Article 4 Engineering Changes
If it is necessary to change the project and construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see the Annex Change Order for Hotel Decoration Project).
Article 5 Time limit for a project is delayed
1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by Party B:
(1) engineering quantity change and design change;
(2) Force majeure;
(3) Other circumstances in which Party A agrees to postpone the construction period.
2. If the construction period is affected by Party B's failure to start work on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.
Article 6 Quality standards
Both parties agree that the construction quality standard of this project is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer.
Article 10 Project Acceptance and Warranty
10. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:
( 1)_________________________;
(2)_________________________; (3)_________________________.
10.2 After the completion of the project, Party B shall notify Party A for acceptance, and the Employer shall organize acceptance and fill in the work within two days after receiving the acceptance notice.
Cheng acceptance form, after the project payment is settled, go through the handover formalities.
10.3 The warranty period of this project is _ _ _ months from the date of acceptance and signature by both parties. After acceptance and signature, fill in the project warranty form. Article 11 Method of payment for project funds
1 1. 1 Both parties agree to pay the project payment according to the following method:
(1) After the contract comes into effect, Party A shall directly pay the project payment to the contractor according to the following table:
| First Commencement Date| Payment Yuan |
| Both parties pass the second acceptance | Pay RMB |.
1 1.3 After all the project payment is settled, Party B shall issue a receipt for the project payment to Party A. 。
Article 12 Liability for breach of contract
12. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for the economic losses.
12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses. ..
12.5 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the construction period will not be postponed. 12.6 If the construction period is delayed due to Party B's reasons, Party B shall pay the other party RMB as liquidated damages for each day of delay.
Article 13 Settlement of Contract Disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:
(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;
(two) to bring a lawsuit to the people's court according to law. Some specific provisions of article 14
14. 1 The garbage generated by the project construction shall be transported out of the construction site by Party B and transported to the designated place. Other matters agreed in article 15.
Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
16. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.
16.2 after the signing of this contract, the project shall not be subcontracted.
16.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract.
Party A Party B
Part II: Hotel renovation contract
Renovation contract
Employer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
According to the Contract Law of People's Republic of China (PRC), Trial Measures for Decoration Management and other relevant laws and regulations, in order to protect the legitimate rights and interests of both parties, combined with the specific conditions of this project, the two parties reached the following agreement, which shall be abided by by * * *.
I general situation and requirements 1. Decoration construction site: 2. Decoration construction content: 3. Signing method: _ _ _ _ _ _ _ _
4. Total price: _ _ _ _ _ _ yuan, in words (RMB): _ _ _ _ _ _ yuan.
5. Duration: This project starts on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party A requires:
1, the decoration requirements shall be subject to the drawings, and the drawings must be accepted; 2. The decoration renderings shall prevail;
3, materials must use the materials provided by the construction drawings; 4. Complete the renovation according to the time specified by Party A; The second is the agreement on material supply; 1. Materials provided by Party B.
2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, Party B shall be responsible for the losses caused to the project. If the materials and equipment provided by Party B are fake and shoddy goods, compensation shall be made according to the price of the materials and equipment.
Give it to party a.
Three. Project quality and acceptance agreement: 1. Dbj08-62-97 Technical Specification for Building Decoration Engineering, db3 1/t30- 1999 Decoration Acceptance Standard and other local standards and quality evaluation acceptance standards formulated by the municipal construction administrative department are implemented in this project.
2, this project by
3. In case of quality accident due to Party B, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged. 4. In the process of construction, when Party A puts forward design modification opinions and adds or subtracts engineering projects, it should contact Party B in advance, and the construction of this project can only start after signing the engineering project change order, which will affect the completion date agreed by both parties. If Party A agrees with the workers to change the construction content privately, all consequences shall be borne by Party A, and if losses are caused to Party B, Party A shall compensate.
5, project acceptance. The project acceptance shall be subject to the renderings and Party A's acceptance, and payment shall be made after acceptance. Four, about the project price and settlement agreement:
The payment method of the project payment is shown in the following table: payment time: 60% of the first payment after signing the contract; Amount: in words:
Pay 35% of the progress payment for the second time; Capitalize; Pay the remaining 5% after the completion acceptance; In words: V. Liability for breach of contract:
1. The construction period will be postponed if the construction starts to be delayed or stops halfway due to Party A's reasons.
2. If the completion is delayed due to Party B's reasons, Party B shall pay% of the project payment to Party A for each day overdue.
3. If the construction is not carried out according to the quality of Party A, all losses shall be borne by Party B, and 20% of the corresponding processing fee shall be paid to Party A as penalty. Party A has the right not to pay the subsequent project funds.
4. If Party B breaches the contract halfway, it shall return the advance payment to Party A and compensate 20% of the corresponding liquidated damages. On the dispute resolution of intransitive verbs;
1. In case of any dispute over the quality of the project, both parties may consult and mediate with the Decoration Committee of the Building Decoration Association, or complain to the district and county construction administrative departments or consumers' associations based on the text of this contract. 2. If the parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, they may apply to the Municipal Arbitration Commission for arbitration according to this contract and bring a lawsuit to the people's court. (Underline the unselected solutions).
Seven. Modification and dissolution of the contract:
1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay 0.03% of the total contract price as liquidated damages, and go through the termination procedures.
2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.
Eight. Other agreements:
Nine. This contract is made in triplicate, one for each party, with the same legal effect. The annex to the contract is an integral part of this contract.
Party A (signature and seal):
Legal Representative: Address: Tel: Postal Code:
Date of signature: year month date of signature:
Authorized Agent: Address: Tel: Postal Code:
Party B (signature and seal): Chapter III: Hotel renovation contract Model.
Hotel renovation contract
If either party fails to perform the contract or violates national laws, regulations and relevant policies, and is fined or causes losses to the other party, the responsible party shall bear the responsibility.
ContractNo.: _ _ _ _
Employer:
Telephone:
Contractor: Tel: Tel: Legal Representative: Construction Team Leader: Legal Representative:
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of family room decoration project construction, on the basis of equality, voluntariness and consensus, both parties reached the following agreement on matters related to the decoration project of the Employer (hereinafter referred to as the project):
Article 1 General situation of the project
1. 1 Project location: _ _ _ _ _ _ _ _ _ _.
1.2 project contracting mode: both parties agree to adopt the contracting mode of contractor and owner.
Article 2 Project supervision
If the project is supervised, the employer and the supervision unit shall sign a project supervision contract separately and notify the contractor of the name, unit, contact information and responsibilities of the supervision engineer.
Article 3 Construction drawings
The Employer shall design and provide the construction drawings in duplicate, one for the Employer and one for the Contractor (see the engineering design drawings for details);
Article 4 Obligations of employers
4. 1 _ two days before construction, create conditions for the contractor to enter the site for construction. Furniture should be stacked and covered on the principle of not affecting construction;
4.2 Provide water and electricity supply during construction;
4.3 Responsible for coordinating the relationship between the construction team and the neighborhood;
4.4 The indoor load-bearing structure shall not be dismantled. If it is really necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments;
4.5 During the construction period, if the Employer still needs to use the bedroom partially, it shall be responsible for the public security and fire control of the construction site.
4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance.
Article 5 Obligations of the Contractor
5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;
5.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment;
5.3 Ensure that the indoor plumbing is unblocked;
5.4 Ensure the cleanliness of the construction site and be responsible for the cleaning of the construction site after the project is completed. Article 6 Engineering changes
If it is necessary to change the project and construction method, both parties shall reach an agreement through consultation, sign a written change agreement, and adjust the related project cost and construction period.
Article 7 Time limit for a project is delayed
7. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by the Employer:
(1) engineering quantity change and design change;
(2) Force majeure;
(3) Other circumstances in which the Employer agrees to postpone the construction period.
7.2 If the time limit for a project is affected by the failure of the Employer to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the quality of the project is affected by the unqualified materials and equipment provided by the employer, the cost of rework shall be borne by the employer, and the construction period shall be postponed.
7.3 If the Employer fails to pay the project payment on schedule, the contract period shall be postponed accordingly.
Article 8 Quality standards
Both parties agree that the construction quality standard of this project is _ _ _ _ _ _ _ _ _ _.
In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer.
Article 9 Project acceptance
9. 1 The contractor shall notify the Employer for acceptance two days in advance, and fill in the project acceptance form after the stage acceptance is qualified.
9.2 After the completion of the project, the contractor shall notify the Employer for acceptance, and the Employer shall organize acceptance within two days after receiving the acceptance notice, fill in the project acceptance form, and go through the handover formalities after the project payment is settled.
9.3 The warranty period of this project is months from the date when both parties sign the acceptance certificate. After the acceptance certificate is signed, fill in the project warranty form.
Article 10 Payment method of project funds
10. 1 After the contract comes into effect, the employer shall directly pay the project payment to the contractor according to the agreement reached:
10.2 After the completion of the project, pay 15% of the total project amount upon acceptance.
10.3 after the acceptance of the project, the contractor shall submit the project settlement to the employer and send the relevant information to the employer. If the Employer has no objection within 3 days after receiving the materials, it shall be deemed as consent. Both parties fill in the project settlement form and sign it, and the employer will settle the final payment of the project to the contractor when signing it.
Article 11 Liability for breach of contract
1 1. 1 If either party to the contract is fined or causes losses to the other party due to non-performance of the contract or violation of national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for the resulting economic losses. 1 1.2 The Employer uses the completed project in advance or uses it without authorization, thus causing losses.
1 1.3 If one party cannot continue to perform the contract due to reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses. 1 1.4 if the employer fails to pay the project payment on time, the contractor has the right to stop work and ask the employer to pay the project payment. For each week of delay, the employer shall pay the other party RMB as liquidated damages.
1 1.5 If the project quality fails to meet the quality standards agreed by both parties due to the contractor, the contractor shall be responsible for the repair, and the construction period will not be postponed.
Article 12 Ways of settlement of contract disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:
(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;
(2) bring a lawsuit to the people's court according to law.
Some specific provisions of Article 13
13. 1 The contractor is responsible for transporting the garbage out of the construction site and to the designated place, and the employer is responsible for paying the garbage removal fee (in words) _ _ _ _ _ _ _ _ _ (this fee is not included in the project price).
13.2 during the construction period, the employer will give the key of the outhouse to the contractor for safekeeping. After the project is completed and accepted, the employer is responsible for providing new locks, and the contractor is responsible for on-site installation and delivery.
During the construction period of 13.3, the contractor's daily working hours are: from _ _ _ to _ _ _ and from _ _ _ to _ _ in the afternoon.
Article 14 Other agreed matters _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
15. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.
This contract is made in duplicate, with each party holding one copy.
15.3 the annex to this contract is an integral part of this contract and has the same legal effect as this contract.
Attachment: decoration project budget table (one for the owner and one for the contractor)
Employer (signature): Contractor (seal):
Legal representative:
Entrusted agent:
Year, month, sun, moon, sun.
Catering Industry Contract No.3 _ _ _ _ _ _ _
Party A _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Business address _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B's _ _ _ _ _ _ _ ID number _ _ _ _ _ _ _ _ _ _ _
Date of birth _ _ _ _ _ _ _ _ _ _ _
Home address _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Postal code _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The registered permanent residence is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Labor Law and relevant regulations, Party A and Party B voluntarily sign this contract through equal consultation and jointly abide by the terms listed in this contract.
Article 1 This Contract shall come into effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2 Party B works in the post (type of work) of _ _ _ _ _ _ _ _.
Party B shall report to Party A in time and leave the post immediately if he suffers from the contraindication diseases of this post.
Other agreements between Party A and Party B on Party B's post (type of work): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 3 Party A shall train Party B in occupational safety and health, food safety and health, clothing standards, professional ethics, professional skills and Party A's rules and regulations before taking up his post.
Article 4 Party A must organize a health examination for Party B every year according to the national regulations. Party A shall provide Party B with necessary safety protection facilities and distribute necessary labor protection articles in accordance with relevant national regulations on labor safety and health.
Article 5 Party A shall strengthen the management of production safety, establish and improve the responsibility system for production safety and improve the conditions for production safety. Improve the internal service and food quality management system, and strictly implement post quality norms, quality responsibilities and corresponding assessment methods.
Party B shall strictly abide by Party A's rules and regulations to prevent service quality accidents.
If Party B violates the service standard, labor discipline and Party A's rules and regulations, Party A can handle the service quality accident according to the rules and regulations.
Article 6 Party A shall pay Party B's salary in the following ways:
(1) The monthly salary is _ _ _ yuan, and the monthly salary during the probation period is _ _ _ _ yuan. Party A shall pay the salary to Party B before _ _ _ every month.
(2) The daily wage is _ _ _ yuan, and the daily wage during the probation period is _ _ _ _ yuan. Party A shall pay Party B's salary for _ _ _ _ days every month.
Where Party A makes Party B wait for work due to insufficient business tasks, the living expenses paid by Party A to Party B shall be _ _ _ _ _ _ _ _ _.
Article 7 The working hours of Party B shall not exceed 8 hours per day and 40 hours per week on average.
Due to the needs of production and operation, Party A may extend the working hours after consultation with the trade union and Party B, which shall generally not exceed 1 hour per day; Where it is necessary to extend the working hours for special reasons, the extended working hours shall not exceed 3 hours per day and 36 hours per month under the condition of ensuring Party B's health.
Where Party A implements a special working hour system due to work needs, it shall report to the labor administrative department for approval in advance.
Where Party A arranges Party B to work overtime or Party B needs to extend working hours due to customer service, Party A shall pay Party B overtime wages according to national regulations.
Article 8 Party A shall provide Party B with medical and social insurance for work-related injuries and major diseases in accordance with the regulations of Beijing.
Article 9 If Party B violates the service standards, quality management regulations, operating rules and other rules and regulations, it shall be liable according to the corresponding regulations of Party A..
Article 10 In case of any of the following circumstances, Party A may terminate this contract at any time:
(a) during the probation period, it is proved that it does not meet the employment conditions;
(two) theft of property, gambling, drug abuse, fighting;
(3) Serious dereliction of duty and graft, which has caused great damage to the interests of Party A;
(4) Party B seriously violates the labor discipline and Party A's rules and regulations, and meets the conditions for Party A to terminate the labor contract;
(five) serious violation of service standards, damage the legitimate rights and interests of consumers;
(6) Selling food and beverages prohibited by laws and regulations to customers without permission;
(seven) being punished, detained or reeducation through labor in violation of laws and regulations;
(8) Being investigated for criminal responsibility according to law.
Article 11 If Party B suffers from post type and industry taboo diseases, and fails to meet the requirements of the state and this Municipality for engaging in relevant industries and jobs after the medical treatment expires, and Party A cannot arrange another job, it may notify Party B in writing 30 days in advance to terminate this contract and pay economic compensation to Party B. 。
Article 12 If Party B terminates this contract, it shall notify Party A in writing 30 days in advance. If Party B resigns without authorization, it shall bear the economic losses caused to Party A. 。
Article 13 If Party B causes losses to Party A due to personal negligence during the performance of the labor contract, it shall be liable for compensation.
Article 14 Other matters agreed by both parties.
Article 15 In case of any dispute arising from the performance of this Contract, both parties shall apply to the county labor dispute arbitration committee where Party A is located for arbitration within 60 days from the date of the labor dispute. If you are not satisfied with the arbitration award, you can bring a lawsuit to the people's court within 15 days from the date of receiving the award.
Article 16 If the matters not covered in this contract are inconsistent with the relevant provisions of the state and Beijing, the relevant provisions shall prevail.
Article 17 This contract is made in duplicate, with each party holding one copy.
Article 18 The annexes to this contract are as follows, which have the same legal effect as this contract. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (official seal) and Party B (signature or seal)
Legal representative or entrusted agent
(Signature or seal)
Date of signature: year month day.
- Previous article:What are the skills for washing hotel sheets?
- Next article:How much is the embroidery machine on the hotel sheets?
- Related articles
- Traveling to Jiuhua Mountain, I want to live better and have characteristics. I don't want to stay in a star hotel or a farmhouse.
- Dear, the location arrangement of love
- Maintenance method of gas water heater
- How many kilometers is it from Dawukou in Yinchuan to Jiaokou River in Yan 'an?
- 6 general manager speeches
- The price of pork has gone up so much, why haven't the prices of some hotels gone up yet?
- Why are there so many Russians in Beidaihe and there are Russian names everywhere?
- Travel to Shanghai Haining Shanghai to Ningbo
- Excuse me, what hotels are there near Tanggu Binhai New Area and Taifeng Jiayuan, and the best ones are cheaper?
- Why is the Limbo Hotel in Boxing closed?