Project Quality Commitment Letter

In the era of continuous progress, there are more and more occasions where commitment letters need to be used, and there are certain standards for writing commitment letters. Come and refer to the commitment letter you need! The following are 8 project quality commitment letters that I have collected and compiled. They are for reference only. You are welcome to read them. Project Quality Commitment Letter 1

Employer (full name):

Contractor (full name):

In order to ensure that the XX landscape project operates normally during the contract period To use, the contractor and the contractor agree to sign a project quality warranty. During the quality warranty period, the contractor shall bear the responsibility for project quality warranty in accordance with relevant regulations and the agreement between the parties.

1. Scope and content of project quality warranty

Greening part maintenance scope: seedling maintenance content in xx park: including seedling watering, pruning, pest and disease control, weeding, and timely clearing of dead branches , bad piles, broken piles, etc.; civil engineering

Project content: foundation engineering, main engineering, landscape wall building, garden road paving, etc.; steel structure, etc.

2. Quality warranty period

The green space maintenance warranty period starts from the date of completion and acceptance for one year. 1 year for civil engineering and 1 year for steel structure engineering.

3. Quality warranty responsibility

1. For items that fall within the scope and content of the warranty, the contractor should send someone to repair it within 7 days of receiving the repair notice. If the contractor does not send someone to repair within the agreed period, the contractor can entrust others to repair the problem, and the warranty fee will be deducted from the quality deposit.

2. In the event of an accident that requires emergency repair (such as water leakage from a pipeline, leakage of electricity, etc.), the contractor should immediately arrive at the accident site for emergency repair after receiving the accident notification. If the accident is not caused by the contractor's construction quality, emergency repair will be required. The cost shall be borne by the contractor.

3. Within the reasonable use period of the project stipulated by the state, the contractor shall ensure the quality of the foundation project and the main structure project. If the project causes personal or property damage during the reasonable period of use due to the contractor's fault, the contractor shall be liable for damages.

IV. Payment of quality warranty money

The project quality warranty money agreed upon in this project is 3% of the construction contract price. After the maintenance period expires, Party A shall pay the remaining balance.

5. Return of quality warranty money

The employer shall return the remaining warranty money to the contractor within 14 days after the expiration of the quality warranty period.

This project quality warranty is an attachment to the construction contract and is signed by both parties *** to the construction contract.

Employer (official seal):

Contractor (official seal):

Legal agent (signature):

Legal agent (Signature):

Year, month and day project quality commitment letter 2

This legal representative promises: This unit will be responsible for the Longxing Cultural Center-Literary Training Building project in Baisha Road Street, Cixi City Earnestly perform the following responsibilities and assume lifelong responsibility for the corresponding quality of the project.

1. Establish and improve the quality assurance system and quality responsibility system, select chief supervisory engineers and supervisory engineers with corresponding qualifications to station at the construction site, and fully staff relevant management personnel. In accordance with the provisions of relevant laws and regulations and As stipulated in the contract, we assume lifelong responsibility for corresponding quality. Provide support and cooperation to the supervision and inspections conducted by the construction administrative department and other relevant departments.

2. Carry out supervision business strictly in accordance with the project supervision qualification level and license scope obtained by the unit in accordance with the law, and do not supervise beyond the level or scope of supervision. Other units or individuals are not allowed to undertake supervision business in the name of the unit. Transfer of project supervision business. The project supervision contract is signed in accordance with the law, and there is no vicious price competition. This unit has no affiliation or other interests with the construction contractors and building materials, building components and equipment supply units of the project.

3. Strictly implement basic construction procedures and adhere to the principle of survey first, then design, and then construction. In accordance with laws, administrative regulations and relevant technical standards, design documents and construction project contract contracts that have been reviewed and approved by the construction drawing review agency and stamped with special seals, representatives of the contracting unit shall be responsible for the construction quality, construction period and use of construction funds. The construction unit shall implement supervision. Reject any request to reduce the quality of the project.

4. Carefully prepare a supervision plan, with clear quality requirements and standards in the plan. Carefully review the quality assurance technical measures of the construction unit. In accordance with the requirements of the project supervision specifications, we will take the form of side stations, inspections and parallel inspections to objectively and fairly perform supervision tasks, strictly supervise and inspect the quality of the entire construction process, ensure that all quality visas are timely, true and accurate, and assume the responsibility for quality supervision .

5. If it is discovered that the project construction does not meet the engineering design requirements, construction technical standards and contract stipulations, the construction unit shall be required to make corrections immediately. If it is discovered that the project design does not meet the construction project quality standards or the quality requirements stipulated in the contract, the construction unit shall be promptly reported to require the design unit to make corrections. If it is discovered that other parties responsible for the project construction violate laws and regulations or violate mandatory standards for project construction, they shall be promptly stopped and reported to the housing and urban-rural development authorities and their project quality supervision agencies.

6. The collection of this project data is true, accurate and complete, the signature procedures are complete, and they are promptly transferred to the construction unit for archiving.

7. If this unit fails to effectively fulfill the above quality responsibility commitments, it is willing to accept penalties and bear corresponding responsibilities in accordance with national, provincial and municipal laws and regulations.

8. This unit has undertaken the following supervision services in this project: Project Quality Commitment Letter 3

1. Subcontract the project to construction, supervision, and surveyors with corresponding qualification levels , design, inspection and construction drawing review and other units, do not divide construction projects into contracts, strictly conduct bidding for projects that require bidding in accordance with laws and regulations, select teams based on the best, do not force contractors to bid at lower than cost prices, and do not arbitrarily compress Reasonable construction period. Be overall responsible for the quality of sub-projects that are sub-contracted in accordance with the law but without designated general contractor management. Projects that require supervision shall be entrusted with supervision in accordance with the law.

2. Promptly handle the project construction drawing review and filing, quality and safety supervision, contract filing, safety production conditions review and other procedures for starting construction, and obtain the construction license (including sub-contracting projects in accordance with the law) before starting construction. Provide relevant design documents such as construction drawings and design changes that have been reviewed and approved by the construction drawing review agency and stamped with a special seal to the construction site.

3. Do not state or imply that the survey, design, construction, testing and other units violate the mandatory standards for project construction or use unqualified building materials, construction accessories and equipment, thereby reducing the quality of the project.

4. After the project is completed, organize survey, design, supervision, construction and other relevant units to conduct acceptance inspection, and accept the supervision of the project quality supervision agency. Projects that have passed the acceptance inspection must be delivered for use, and the completion acceptance filing procedures must be completed within fifteen days of the project passing the acceptance inspection.

5. Organize documents and information in a timely manner, establish and improve project archives, and transfer construction project archives to the urban construction archives management department within three months after completion and filing.

6. Other responsibilities prescribed by laws and regulations. This letter of commitment is made in triplicate. One copy shall be submitted to the competent department of housing and urban-rural development when the construction project receives the construction license. One copy shall be submitted to the urban construction archives management department for archiving together with the archives after the construction project is completed and accepted. The respective responsible entities shall be kept for reference.

Signature and seal of legal representative:

Project Quality Commitment Letter 4 on xx, xx, xx

(Full name of the quotation unit) Authorized representative to attend your center Organized the bidding and procurement activities for Wuzhong City's education primary and secondary school book projects and made bids and quotations. We have carefully studied all the responsibilities and obligations of bidders as stipulated in your bidding and procurement documents.

1. Willing to provide all goods and accessories in accordance with all requirements of the bidding documents

, and be responsible for the transportation, miscellaneous insurance, taxes, etc. of the goods. The total price is less than Please see the "Tender Quotation Form" for details;

2. If our bid is accepted, we will strictly fulfill every requirement stipulated in the bidding documents

and deliver the goods on time and according to the quality. , Fulfill supply obligations according to quantity. And provide a free one-year warranty;

3. We agree that according to the provisions of the bidding documents, the validity period of this bid is

30 days after the bid opening;

4. We are willing to provide all the information requested by the tenderer in the bidding documents; 5. We believe that you have the right to decide the winning bidder, and also believe that you have the right to accept or

reject all bidders;

p>

6. We are willing to abide by the bidding notice and the fee rates listed in the bidding documents; 7. The bid will remain valid during the process after the bid opening, and no changes will be made

;

8. We are willing to pay the security deposit in accordance with the provisions of the bidding documents;

9. If we win the bid, we are willing to pay the performance bond when signing the contract

< p> RMB 10,000; 10. Comprehensive description:

(1) Accompanying services and cooperation measures; (2) The cooperation required from the purchaser;

(3) For The bidding documents contain deviation instructions with different opinions; (4) Other explanations.

For all correspondence related to the tender documents, please contact us at the following address: Unit: Postal code: Contact person: Address: Bank of account: Telephone: Account number: Fax: Name of the plenipotentiary (signature):

< p>Full name of the bidding unit: (Official seal)

Contract reference book

Supplier: (hereinafter referred to as Party A) Demander: (hereinafter referred to as Party B) Procurement number: Wu Cai (public ) [20xx] No. 010

After the Wuzhong Municipal Government Procurement Center adopted an open bidding method for procurement, Party A was determined to be the winning supplier. After negotiation between the two parties, Party A and Party B agreed to sign this contract in accordance with the following terms and conditions. .

1. Name, quantity and specifications of the contract subject matter:

2. Total contract price:

The contract amount is: (uppercase) (￥:)

p>

3. Before the contract is performed, the quality deposit (performance bond) that the winning bidder must pay will be refunded without interest if the goods are accepted and accepted without quality problems.

4. Payment plan: 70% of the down payment will be made after the goods arrive and are accepted, and the remaining balance will be paid in three months.

5. Delivery time, location, acceptance:

1. Delivery time: before the year, month and day 2. Delivery location: Wuzhong Municipal Education Bureau

3. When Party A provides goods to Party B, it must provide the following information: packing list, product quality inspection certificate, factory inspection report, product installation and use instructions, warranty sheet, etc. 6. After-sales service and quality assurance: 1. Party A is responsible for the quality of the goods it supplies.

2. The quality guarantee period shall be based on the after-sales service terms or bidding documents provided by the manufacturer (other warranty preferential conditions provided by Party A must be specifically stated). The quality guarantee period is 3. If any quality problem occurs during the quality guarantee period, Party A is responsible for repairing, replacing or returning any problems, and shall bear all costs incurred therefrom; if there are problems caused by improper use by Party B, Party A shall actively cooperate to solve them, and the costs shall be borne by Party B. The maximum time for repair or replacement shall not exceed day.

4. If Party A does not reply within the date of receiving the notice from Party B, it will be deemed that Party A has admitted the quality problem, and Party B has the right to handle it on its own, and Party A will bear all the costs incurred.

5. If there is a dispute over the quality of the goods, the Wuzhong Municipal Quality and Technical Supervision Bureau or its designated and technical department will conduct a quality appraisal. The appraisal conclusion is final and must be accepted by Party A and Party B. 7. Liability for breach of contract

1. If Party B refuses to accept the goods or pay the payment without justifiable reasons, it must pay Party A a liquidated damages of 100% of the total payment.

2. If the brand, model, specification, color, and quality of the goods supplied by Party A do not meet the standards stipulated in the contract, Party B has the right to reject the goods, and Party A must pay Party B 0.0% of the total payment. liquidated damages. At the same time, the Government Procurement Center has the right not to return the performance bond (warranty deposit) prepaid by Party A.

3. If Party A delivers the goods overdue, Party A must pay Party B liquidated damages equal to 0.0% of the total payment for each overdue day. 8. Training plan:

1. Training time and content: 2. Training method: 3. Number of trainees: 9. Composition of contract documents: 1. Bidding documents

2. Bidding Documents (written commitment, bid quotation) 3. Notification of winning the bid

The above documents are components of the contract. Party A and Party B must fully abide by them. If there is any violation, they shall bear liability for breach of contract. 10. Force majeure:

During the contract performance period, if either party is unable to perform the contract due to force majeure, it shall immediately notify the other party and submit a certificate issued by the relevant authority, and the contract performance period may be extended. The extension period is opposite to the force majeure period. If the force majeure lasts for days or more, both parties shall decide through friendly consultation whether to continue to perform the contract matters. 11. Resolution of disputes:

Any dispute arising during the performance of this contract shall be resolved by negotiation between the parties; when the negotiation fails, both parties agree to arbitrate by the Wuzhong City Arbitration Commission, which shall be the final award. Binding on both parties. The arbitration fees shall be borne by the losing party unless otherwise determined by the arbitration authority.

12. This contract is made in five copies and will take effect after being signed and sealed by Party A and Party B. 13. Matters not covered in this contract shall be handled in accordance with the relevant provisions of the Contract Law. Project Quality Commitment Part 5

I solemnly promise to your company:

1. We guarantee to provide materials and construction in accordance with the quality requirements in the construction drawings and the signed "Decoration Construction Contract" , if you do not comply, we are willing to take full responsibility.

2. The project will be warranted according to the contract. The warranty period of the project is 2 years. If there are quality problems during the warranty period, our company will be responsible for free repairs.

Signature:

Year, month and day project quality commitment letter 6

1. Obtain the corresponding level of qualification certificate in accordance with the law, and within the scope permitted by the qualification level Undertake projects.

2. The person in charge shall be fully responsible for the unit’s production safety work in accordance with the law. Establish and improve the safety production responsibility system and safety production education and training system, formulate safety production rules and regulations and operating procedures, ensure the investment of funds required for the unit's safe production conditions, conduct regular and special safety inspections on the construction projects undertaken, and conduct Good safety inspection records.

The project leader shall be a person who has obtained the corresponding professional qualifications and shall be responsible for the safe construction of the construction project, implement the safety production responsibility system, safety production rules and regulations and operating procedures, and ensure the effective use of safety production expenses. We also organize and formulate safety construction measures based on the characteristics of the project to eliminate hidden dangers of safety accidents, and report production safety accidents in a timely and truthful manner.

3. Establish a production safety management organization and staff it with full-time production safety management personnel.

Full-time production safety management personnel are responsible for on-site supervision and inspection of production safety.

If potential safety accidents are discovered, report them to the project leader and production safety management agency in a timely manner; any command or operation that violates regulations shall be stopped immediately.

4. Vertical transport machinery operators, installation and disassembly workers, blasting workers

Special operations personnel such as lifting and signal workers, climbing and erection workers, etc., must undergo specialized training in accordance with relevant national regulations. After receiving safe operation training and obtaining the special operation qualification certificate, you can start working.

5. Prepare safety technical measures and temporary power supply plans for the construction site in the construction organization design. For sub-projects with greater risks, special construction plans shall be carried out in accordance with relevant national, provincial and municipal regulations. Compilation, review and expert demonstration, and organization and implementation after meeting the requirements.

6. Before the construction of the construction project, the technical personnel responsible for project management shall explain the technical requirements for safe construction in detail to the construction work team and operators, and have them signed and confirmed by both parties.

7. At the entrance of the construction site, construction hoisting machinery, temporary electrical facilities, scaffolding, entrances and exits, stairwells, elevator wellheads, hole mouths, bridge mouths, tunnel mouths, foundation pit edges, Set up obvious safety warning signs in dangerous locations such as storage areas for explosives and hazardous gases and liquids.

According to different construction stages, surrounding environment, seasonal and climate changes, corresponding safety construction measures should be taken at the construction site. If construction is temporarily suspended at the construction site, on-site protection must be provided.

8. Separate the office and living areas from the work area at the construction site and maintain a safe distance; the location of the office and living areas meets safety requirements. Employees’ meals, drinking water, resting places, etc. must comply with hygienic standards. Do not set up dormitories for employees in unfinished buildings.

9. Take special protective measures for adjacent buildings and underground pipelines of structures that may be damaged due to construction projects.

Comply with relevant environmental protection laws and regulations, and take measures at the construction site to prevent or reduce the harm and pollution to people and the environment caused by dust, exhaust gas, waste water, solid waste, noise, vibration and construction lighting.

10. For construction projects in urban areas, the construction site should be enclosed and fenced.

Establish a fire safety responsibility system at the construction site, determine the person responsible for fire safety, formulate fire safety management systems and operating procedures for the use of fire, electricity, flammable and explosive materials, etc., and set up fire escapes , fire-fighting water sources, equipped with fire-fighting facilities and fire-extinguishing equipment, and set up obvious signs at the entrance to the construction site.

11. Provide workers with safety protective equipment and safety protective clothing, and inform them in writing of the operating procedures for dangerous positions and the hazards of illegal operations.

12. Operators must abide by the mandatory standards, rules and operating procedures for safe construction, and correctly use safety protection equipment, mechanical equipment, etc.

13. Purchase and lease safety protection equipment, mechanical equipment, construction tools and accessories with production (manufacturing) licenses and product certification certificates, and inspect them before entering the construction site.

The safety protection equipment, mechanical equipment, construction tools and accessories at the construction site are managed by dedicated personnel, regularly inspected, repaired and maintained, corresponding archives are established, and they are promptly scrapped in accordance with relevant national regulations.

14. Before using construction hoisting machinery and overall lifting of self-elevating erection facilities such as scaffolding and formwork, organize relevant units to conduct acceptance inspection, or entrust a testing and inspection agency with corresponding qualifications to conduct acceptance inspection; use rented Mechanical equipment, construction tools and accessories shall be used after passing the inspection.

15. The main person in charge, project person in charge, and full-time safety production management personnel shall take office after passing the assessment of the construction administrative department or other relevant departments. Provide production safety education and training to managers and operators at least once a year, and their education and training status will be recorded in personal work files.

16. Apply for accident insurance for personnel engaged in dangerous operations at the construction site. Project Quality Commitment Part 7

Project Name:

I promise to be responsible for project quality accidents or quality problems caused by the design during the construction process of the project and within the design service life of the building. responsibility. During the project construction process, the following responsibilities shall be conscientiously performed:

1. Strictly abide by relevant laws, regulations and standards, and conscientiously perform the responsibilities and obligations stipulated in the construction project contract.

2. Carry out design business strictly in accordance with the approved engineering design qualification level and business scope, do not contract projects beyond the scope permitted by the qualification level, and do not subcontract or illegally subcontract the design business contracted.

3. Carry out engineering design strictly based on the survey results documents, ensure that the design documents meet the mandatory standards for engineering construction, meet the national document preparation depth requirements, and undergo strict internal proofreading and review. The design documents provided are stamped with the design unit's special drawing seal and the professional seal.

4. Make design changes in strict accordance with relevant regulations. Major design changes should be reviewed in accordance with regulations and procedures.

5. Make design briefings to the construction unit and supervisory unit before construction and participate in drawing review as required, solve design problems involved in the construction process in a timely manner, and actively participate in important sub-projects and unit projects Upon completion acceptance, sign the acceptance conclusion truly and objectively, actively participate in the investigation and handling of quality accidents, and submit project quality inspection reports as required.

6. Other quality responsibilities stipulated in laws, regulations and standards.

This letter of commitment is made in quadruplicate. One copy shall be submitted to the quality supervision agency when going through the supervision procedures. One copy shall be submitted to the urban construction archives management department for archiving after the completion and acceptance of the construction project. The construction unit shall retain a copy of the design unit.

Name of the unit

Project leader

Signature of the promisee:

Year, month and day

ID number

Practice Qualification Certificate Number

Design Unit (Official Seal):

Project Quality Commitment Letter ____Year____Month____Part 8

p>

Kunming City Construction Project Quota Station:

If our company can win the bid, our company will make the following commitments:

First, cooperate with the implementation of the Kunming City Construction Administrative Department Relevant management measures

After winning the bid, our unit will actively cooperate with the Kunming Municipal Construction Administration Department in terms of planning management, technical quality management, fund management, etc. The main measures are:

( 1) Select excellent construction teams, sign labor contracts with them in accordance with the law, pay workers’ wages on time, and never default on migrant workers’ wages.

(2) The project engineering department will be responsible for submitting the overall construction period network plan to the Kunming Municipal Construction Administrative Department, and actively assist the Kunming Municipal Construction Administrative Department to determine the advancement and retreat of various professional subcontracting teams and suppliers. For site and intermediate handover matters, we will cooperate with the Kunming Municipal Construction Administrative Department to reasonably resolve the vertical transportation equipment, construction water, electricity, material stacking, site division, etc.

(3) The monthly construction progress plan, labor force plan and material arrival plan shall be submitted to the Kunming Municipal Construction Administration Department for finalization after review by the supervisor.

(4) Regular project meetings will be held every week, chaired by the supervisor, and attended by the Kunming Municipal Construction Administrative Department and the Project Management Department. Through the system of regular project meetings, we will improve the relationship between construction, supervision, and Kunming City's construction administrative departments, coordinate various problems that arise during the construction process, and ensure the smooth progress of the project.

(5) When holding a regular project meeting, the project leader will submit a weekly work report and next week’s work plan to the Kunming Municipal Construction Administration Department. The report will detail the progress of the project. In the plan A detailed plan detailing schedule, materials, labor, equipment, funding, etc.

(6) Keep a construction diary carefully, record the number of workers and machinery used for each type of work on the construction site, the quantity of materials transported to the construction site, and the daily weather conditions, and keep it in the construction site office. So that the Kunming Municipal Construction Administrative Department can check it at any time.

(7) Pay full attention to the instructions of the Kunming Municipal Construction Administrative Department. On-site managers should record the instructions of the Kunming Municipal Construction Administrative Department in writing at any time and implement them.

Second, quality, safety and after-sales service:

Consciously accept the use of Kunming Municipal Construction Administrative Department, supervision units and relevant management departments to monitor the quality and safety of construction projects. Supervise and inspect and correct problems raised during inspections in a timely manner. We have made the following commitments in terms of quality (including warranty) and safety:

(1) Obtain the corresponding level of qualification certificate in accordance with the law, and undertake projects within the scope of its qualification level. Do not subcontract or illegally subcontract projects.

(2) Establish a quality responsibility system and be responsible for the construction quality of construction projects.

(3) Construction shall be carried out in accordance with the engineering design drawings and construction technical standards, and no unauthorized modifications to the engineering design shall be made, and no corners shall be cut. If errors are found in design documents and drawings during the construction process, comments and suggestions will be made promptly.

(4) Establish and improve the construction quality inspection system, strictly manage the process, and ensure the quality inspection and records of concealed projects.

(5) Establish and improve the education and training system, and strengthen the education and training of employees; personnel who have not received education and training or who fail the assessment will not be allowed to work.

(6) Fulfill construction project quality warranty obligations in accordance with the law.

(7) The person in charge shall be fully responsible for the unit’s production safety work in accordance with the law. Establish and improve the safety production responsibility system and safety production education and training system, formulate safety production rules and regulations and operating procedures, ensure the investment of funds required for the unit's safe production conditions, conduct regular and special safety inspections on the construction projects undertaken, and do a good job Safety inspection records.

(8) The project leader shall be a person with corresponding professional qualifications and shall be responsible for the safe construction of the construction project, implement the safety production responsibility system, safety production rules and regulations and operating procedures, and ensure the safety production expenses. Use it effectively, organize and formulate safety construction measures according to the characteristics of the project, eliminate hidden dangers of safety accidents, and report production safety accidents in a timely and truthful manner.

(9) Establish a production safety management organization and staff it with full-time production safety management personnel. Full-time safety production management personnel are responsible for on-site supervision and inspection of safety production. If potential safety accidents are discovered, report them to the project leader and production safety management agency in a timely manner; and immediately stop any illegal command or operation.

(10) According to different construction stages and changes in the surrounding environment and season and climate, take corresponding safety construction measures at the construction site. If construction is temporarily suspended at the construction site, on-site protection must be provided. Separate the office and living areas from the work area at the construction site and maintain a safe distance; the location of the office and living areas meets safety requirements. Employees’ meals, drinking water, resting places, etc. must comply with hygienic standards. Do not set up dormitories for employees in unfinished buildings.

(11) Establish a fire safety responsibility system at the construction site, determine the person responsible for fire safety, formulate fire safety management systems and operating procedures for the use of fire, electricity, and the use of flammable and explosive materials, and set up Fire exits, fire water sources, fire facilities and fire extinguishing equipment shall be equipped, and obvious signs shall be set at the entrance to the construction site.

(12) Operators must abide by the mandatory standards, rules and operating procedures for safe construction, and correctly use safety protection equipment, mechanical equipment, etc.

(13) Purchase and lease safety protection equipment, mechanical equipment, construction tools and accessories with production (manufacturing) licenses and product certificates, and inspect them before entering the construction site.

(14) Safety production education and training should be conducted for managers and operators at least once a year, and the education and training status should be recorded in personal work files. Apply for accidental injury insurance for personnel engaged in dangerous operations at the construction site.

(15) If there is a quality problem with the engineering equipment within one year, the company will repair and replace it free of charge;

(16) If the equipment fails within ten years of the project operation, the company will repair and replace it for free. We will rush to the site to carry out repairs within 24 hours after receiving the user's call;

(17) Provide lifelong tracking services for the stable operation of this project.

Promisor:

XXXXXXXXXX

xxx year and month 21 2nd